Damages definition

Damages means any loss, claim, damage, liability, costs and expenses (including, without limitation, reasonable attorney's fees and disbursements and costs and expenses of expert witnesses and investigation).

Damages has the meaning set forth in Section 9.2(a).

Damages means any loss, damage, claim or liability (joint or several) to which a party hereto may become subject under the Securities Act, the Exchange Act, or other federal or state law, insofar as such loss, damage, claim or liability (or any action in respect thereof) arises out of or is based upon: (i) any untrue statement or alleged untrue statement of a material fact contained in any registration statement of the Company, including any preliminary prospectus or final prospectus contained therein or any amendments or supplements thereto; (ii) an omission or alleged omission to state therein a material fact required to be stated therein, or necessary to make the statements therein not misleading; or (iii) any violation or alleged violation by the indemnifying party (or any of its agents or Affiliates) of the Securities Act, the Exchange Act, any state securities law, or any rule or regulation promulgated under the Securities Act, the Exchange Act, or any state securities law.

Examples of Damages in a sentence

In addition to recovery of the aforesaid cost, a sum equal to 20% (twenty per cent) of such cost shall be paid by the Concessionaire to the Authority as Damages.
The Damages payable hereunder shall be the sole remedy available to the Concessionaire for delay by the Authority.
In case the Damages and the interest thereof are more than the 1st Annuity payment then the balance Damages along with interest thereof shall be recovered from any further amount due and payable to the Concessionaire excluding O&M Payments but including interest to be paid on reducing balance of the Completion Cost remaining to be paid along with the 1st Annuity or from further Annuity payments.
Subject to the provisions of Clause 12.3, if COD does not occur prior to the 91st (ninety first) day after the Scheduled Completion Date, unless the delay is on account of reasons attributable to the Authority or due to Force Majeure, the Concessionaire shall pay Damages to the Authority in a sum calculated at the rate of 0.2% (zero point two per cent) of the amount of Performance Security for delay of each day until COD is achieved.
It should be noted that any delay in the project timelines shall attract Liquidated Damages to the selected Bidder(s).

Damages means all elements of relief or recovery of whatever nature, whether known or unknown, which are recognized by the law or equity of any jurisdiction. This term includes, without limitation, actual, incidental, indirect, consequential, compensatory, liquidated, exemplary, and punitive damages; rescission, attorneys' fees; interest; costs; equitable relief; and expenses.

Damages means any and all damages, liabilities, obligations, penalties, fines, judgments, claims, deficiencies, losses, costs, expenses and assessments (including without limitation income and other taxes, interest, penalties and attorneys' and accountants' fees and disbursements).

Damages shall have the meaning set forth in Section 14.1.

Damages shall include any loss, damage, injury, decline in value, lost opportunity, Liability, claim, demand, settlement, judgment, award, fine, penalty, Tax, fee (including any legal fee, expert fee, accounting fee or advisory fee), charge, cost (including any cost of investigation) or expense of any nature.

Damages shall have the meaning assigned to such term in Section 7.02.

Damages shall have the meaning set forth in paragraph (w) of Clause 1.2;