Utility Accommodation Rules definition

Utility Accommodation Rules means the Utility Accommodation Rules issued by TxDOT, at 43 Tex. Admin. Code, Part 1, Chapter 21, Subchapter C, as the same may be amended, supplemented or replaced by TxDOT from time to time.
Sample 1Sample 2Sample 3

Examples of Utility Accommodation Rules in a sentence

  • The Engineer shall develop each utility detail or accommodation in compliance with the State’s Utility Accommodation Rules.

  • DB Contractor shall use its best efforts to minimize costs for which DB Contractor is entitled to compensation pursuant to this Section 6.8.1, and to minimize any delay for which DB Contractor is entitled to an extension in the Completion Deadline pursuant to this Section 6.8.1, subject to DB Contractor's obligation to comply with all applicable requirements of the Contract Documents, including the Utility Accommodation Rules (UAR).

  • Developer shall use its best efforts to minimize costs for which Developer is entitled to compensation pursuant to this Section 6.8.1, and to minimize any delay for which Developer is entitled to an extension in the Completion Deadline pursuant to this Section 6.8.1, subject to Developer's obligation to comply with all applicable requirements of the Contract Documents, including the Utility Accommodation Rules (UAR) and the other requirements described in Section 6 of the Technical Provisions.

  • The Developer represents and warrants that the Plans conform to the most recent Utility Accommodation Rules issued by the Texas Department of Transportation (“TxDOT”), set forth in 43 Tex.

  • Facilities to remain in service and in place as a result of roadway design adjustments and meeting the current Utility Accommodation Rules (UAR).

  • Unless otherwise specifically stated in Attachment A to this contract, all work will be performed in accordance with the Utility Accommodation Rules as set forth in 43 Texas Administrative Code §21.31 et.

  • Developer shall use its best efforts to minimize costs for which Developer is entitled to compensation pursuant to this Section 3.13.1, and to minimize any delay for which Developer is entitled to an extension in the Completion Deadline pursuant to this Section 3.13.1, subject to Developer’s obligation to comply with all applicable requirements of the Contract Documents, including the Utility Accommodation Rules (UAR) and the other requirements described in Section 6 of the Technical Provisions.

  • In all cases, whether an excavation moratorium as described above applies, or as in the case of Light Capital Paving projects where no excavation moratorium applies, the Utility further acknowledges and agrees that all subsequent excavations and/or installations within the right-of-way of the Project limits shall be regulated and controlled in the manner specified by the most recent version of the Department’s "Utility Accommodation Rules", which are incorporated and made a part hereof by reference.

  • The proposed Utility plans conform to Title 43, Texas Administrative Code, Section 21.31 – 21.56 of the Utility Accommodation Rules.

  • Developer shall use its best efforts to minimize costs for which Developer is entitled to compensation pursuant to this Section 3.14.1, and to minimize any delay for which Developer is entitled to an extension in the Completion Deadline pursuant to this Section 3.14.1, subject to Developer’s obligation to comply with all applicable requirements of the Contract Documents, including the Utility Accommodation Rules (UAR) and the other requirements described in Section 6 of the Technical Provisions.

Related to Utility Accommodation Rules

  • U.S. Risk Retention Rules means the federal interagency credit risk retention rules, codified at 17 C.F.R. Part 246.

  • Arbitration Rules means the AAA’s Commercial Arbitration Rules and Mediation Procedures.

  • Public accommodation means each and every place, establishment, or facility of whatever kind, nature, or class that caters or offers services, facilities, or goods for a fee or charge to nonmembers of any organization or association utilizing the place, establishment, or facility, provided that any place, establishment, or facility that caters or offers services, facilities, or goods to the nonmembers gratuitously shall be deemed a public accommodation if the accommodation receives governmental support or subsidy. Public accommodation shall not mean any bona fide private club or other place, establishment, or facility which is by its nature distinctly private, except when such distinctly private place, establishment, or facility caters or offers services, facilities, or goods to the nonmembers for fee or charge or gratuitously, it shall be deemed a public accommodation during such period. “Public accommodation” includes each state and local government unit or tax-supported district of whatever kind, nature, or class that offers services, facilities, benefits, grants or goods to the public, gratuitously or otherwise. This paragraph shall not be construed by negative implication or otherwise to restrict any part or portion of the pre-existing

  • accommodation unit in relation to any premises, means a building or section of a building occupied or used or intended for occupation or use for any purpose;

  • UNCITRAL Arbitration Rules means the arbitration rules of the United Nations Commission on International Trade Law.

  • Auto-Renewal Letter of Credit has the meaning specified in Section 2.03(b)(iii).