100% Engineer’s Estimate of Probable Cost Sample Clauses

Open Split View

Download

Share

Cite

100% Engineer’s Estimate of Probable Cost. Engineer’s estimate of probable cost will be submitted in Master Bid List Format.

Sample 1

Save

Copy

Related to 100% Engineer’s Estimate of Probable Cost

• Opinion of Probable Cost Any opinions of probable Project cost or probable construction cost provided by Engineer are made on the basis of information available to Engineer and on the basis of Engineer’s experience and qualifications and represents its judgment as an experienced and qualified professional engineer. However, since Engineer has no control over the cost of labor, materials, equipment or services furnished by others, or over the contractor(s’) methods of determining prices, or over competitive bidding or market conditions, Engineer does not guarantee that proposals, bids or actual Project or construction cost will not vary from opinions of probable cost Engineer prepares.

• Cost Estimate The cost estimate shall set out the estimated costs for the proposed Change Order in such a way that a fair evaluation can be made. It shall include a breakdown for labor, materials, equipment and markups for overhead and profit, unless TxDOT agrees otherwise. If the work is to be performed by Subcontractors and if the work is sufficiently defined to obtain Subcontractor quotes, DB Contractor shall obtain quotes (with breakdowns showing cost of labor, materials, equipment and markups for overhead and profit) on the Subcontractor’s stationery and shall include such quotes as back-up for DB Contractor’s estimate. No markup shall be allowed in excess of the amounts allowed under Section 10.6. DB Contractor shall identify all conditions with respect to prices or other aspects of the cost estimate, such as pricing contingent on firm orders being made by a certain date or the occurrence or non-occurrence of an event.

• Cost Estimates If this Agreement pertains to the design of a public works project, CONSULTANT shall submit estimates of probable construction costs at each phase of design submittal. If the total estimated construction cost at any submittal exceeds ten percent (10%) of CITY’s stated construction budget, CONSULTANT shall make recommendations to CITY for aligning the PROJECT design with the budget, incorporate CITY approved recommendations, and revise the design to meet the Project budget, at no additional cost to CITY.

• Statement of Estimated Direct Expenses In addition, Landlord shall give Tenant a yearly expense estimate statement (the “Estimate Statement”) which shall set forth Landlord’s reasonable estimate (the “Estimate”) of what the total amount of Direct Expenses for the then-current Expense Year shall be and the estimated Tenant’s Share of Direct Expenses (the “Estimated Direct Expenses”). The failure of Landlord to timely furnish the Estimate Statement for any Expense Year shall not preclude Landlord from enforcing its rights to collect any Estimated Direct Expenses under this Article 4, nor shall Landlord be prohibited from revising any Estimate Statement or Estimated Direct Expenses theretofore delivered to the extent necessary. Thereafter, Tenant shall pay, with its next installment of Base Rent due that is at least thirty (30) days thereafter, a fraction of the Estimated Direct Expenses for the then-current Expense Year (reduced by any amounts paid pursuant to the last sentence of this Section 4.4.2). Such fraction shall have as its numerator the number of months which have elapsed in such current Expense Year, including the month of such payment, and twelve (12) as its denominator. Until a new Estimate Statement is furnished (which Landlord shall have the right to deliver to Tenant at any time), Tenant shall pay monthly, with the monthly Base Rent installments, an amount equal to one-twelfth (1/12) of the total Estimated Direct Expenses set forth in the previous Estimate Statement delivered by Landlord to Tenant.

• ESTIMATED / SPECIFIC QUANTITY CONTRACTS Estimated quantity contracts, also referred to as indefinite delivery / indefinite quantity contracts, are expressly agreed and understood to be made for only the quantities, if any, actually ordered during the Contract term. No guarantee of any quantity is implied or given. With respect to any specific quantity stated in the contract, the Commissioner reserves the right after award to order up to 20% more or less (rounded to the next highest whole number) than the specific quantities called for in the Contract. Notwithstanding the foregoing, the Commissioner may purchase greater or lesser percentages of Contract quantities should the Commissioner and Contractor so agree. Such agreement may include an equitable price adjustment.

• Estimated Cost Estimated costs by construction phases for Specified Roads listed in A7 are stated by segments in the Schedule of Items. Such estimated costs are subject to adjustment under B3.3, B5.2, B5.21, B5.212, B5.25, and B5.26. Appropriately adjusted costs shall be made a part of a revised Schedule of Items and shown as adjustments to Timber Sale Account. The revised Schedule of Items shall supersede any prior Schedule of Items when it is dated and signed by Contracting Officer and a copy is furnished to Purchaser.

• Operating Costs (a) Tenant shall maintain the Premises in their condition on the Effective Date at Tenant’s sole cost and expense. Landlord may inspect the Premises and, if Landlord reasonably determines that Tenant is not maintaining the Premises in their condition on the Effective Date, Landlord may provide Tenant with written notice of any such maintenance concern, and Tenant shall promptly make such repairs. If Tenant fails to complete such repairs within thirty (30) days of receipt of such notice, Landlord may undertake such repairs and Tenant shall be obligated to reimburse Landlord for its costs within ten (10) days of receipt of an invoice therefore. Landlord represents and warrants to Tenant that the exterior walls, foundation and roof of the Premises are in good working order on the Effective Date. Landlord will, at its cost, replace, restore, repair or maintain (as necessary) the roof until the first anniversary of the Commencement Date. Landlord will, at its cost, replace, restore, repair or maintain (as necessary) the exterior walls and foundation of the Premises until the fifth anniversary of the Commencement Date. Tenant shall be fully responsible for the replacement, restoration, repair and maintenance of the roof, exterior walls and foundation of the Premises thereafter. If Landlord fails to commence such repairs within thirty (30) days of receipt of any notice from Tenant, Tenant may undertake such repairs and Landlord shall be obligated to reimburse Tenant for its costs within ten (10) days of receipt of an invoice therefore; provided, however, that Tenant shall have no rights to offset or set off any such amounts against the Rent to be paid hereunder. If Landlord does not reimburse Tenant within ten (10) days from the date of notice, such charge shall bear interest at the rate of eighteen percent (18%) per annum until paid. Notwithstanding anything to the contrary herein contained (except for the provisions of paragraph 32 below), if Tenant makes any changes, additions or alterations to the roof of the Premises which involves penetration of the roof (other than those for telecommunications installations so long as the installation contractor has Landlord’s prior written approval which will not be unreasonably conditioned, delayed or denied), Landlord’s obligations to replace, restore, repair or maintain the roof shall cease. If Tenant undertakes any structural repairs in the Premises which impact, affect, or alter the walls or foundation of the Premises, Landlord’s obligation to replace, restore, repair or maintain that portion of the exterior walls and foundation of the Premises shall cease as of the date of such action by Tenant. Any Operating Costs that pertain to a period prior to or after the Lease Term will be pro rated between Landlord and Tenant in the proportion of the amount of the Lease Term that falls within the period to which the Operating Costs pertain. (b) Tenant shall pay all Operating Costs during the Lease Term.

• Estimated Costs The proposed GMP Change Order shall include separately identified dollar amounts, stated as fixed sums, for Actual Costs as estimated by the Design-Builder for the complete construction of the Project, which amount shall include the all Trade Contract and Subcontract Sums, costs of materials, and any Component Change Order Sums;

• Estimate The Engineer shall independently develop and report quantities necessary to construct the contract in standard State bid format at the specified milestones and Final PS&E submittals. The Engineer shall prepare each construction cost estimates using Estimator or any approved method. The estimate shall be provided at each milestone submittal or in DCIS format at the 95% and Final PS&E submittals per State’s District requirement.

• Initial Cost Subject to reimbursement as hereinafter provided, the cost of organizing the Trust and the sale of the Units shall be borne by the Depositor, provided, however, that the liability on the part of the Depositor under this Section 3.01 shall not include any fees or other expenses incurred in connection with the administration of the Trust subsequent to the deposit referred to in Section 2.01. At the earlier of six (6) months after the Initial Date of Deposit or the conclusion of the initial offering period (as certified by the Depositor to the Trustee), the Trustee shall withdraw from the account(s) specified in the Prospectus or, if no account is therein specified, from the Capital Account, and pay to the Depositor the Depositor’s reimbursable expenses of organizing the Trust in an amount certified to the Trustee by the Depositor. In no event shall the amount paid by the Trustee to the Depositor for the Depositor’s reimbursable expenses of organizing the Trust exceed the estimated per Unit amount of organization costs set forth in the Prospectus for the Trust multiplied by the number of Units of the Trust outstanding at the earlier of six (6) months after the Initial Date of Deposit or the conclusion of the initial offering period; nor shall the Depositor be entitled to or request reimbursement for expenses of organizing the Trust incurred after the earlier of six (6) months after the Initial Date of Deposit or the conclusion of the initial offering period. If the cash balance of the Capital Account is insufficient to make such withdrawal, the Trustee shall, as directed by the Depositor, sell Securities identified by the Supervisor, or distribute to the Depositor Securities having a value, as determined under Section 5.01 as of the date of distribution, sufficient for such reimbursement provided that such distribution is permissible under applicable laws and regulations. Securities sold or distributed to the Depositor to reimburse the Depositor pursuant to this Section shall be sold or distributed by the Trustee, to the extent practicable, in the Percentage Ratio then existing (unless the Trust is a RIC, in which case sales or distributions by the Trustee shall be made in accordance with the instructions of the Supervisor or its designees). The reimbursement provided for in this Section shall be for the account of Unitholders of record at the earlier of six (6) months after the Initial Date of Deposit or the conclusion of the initial offering period. Any assets deposited with the Trustee in respect of the expenses reimbursable under this Section 3.01 shall be held and administered as assets of the Trust for all purposes hereunder. Any cash which the Depositor has identified as to be used for reimbursement of expenses pursuant to this Section 3.01 shall be held by the Trustee, without interest, and reserved for such purposes and, accordingly, prior to the earlier of six (6) months after the Initial Date of Deposit or the conclusion of the initial offering period, shall not be subject to distribution or, unless the Depositor otherwise directs, used for payment of redemptions in excess of the per Unit amount payable pursuant to the next sentence. If a Unitholder redeems Units prior to the earlier of six months after the Initial Date of Deposit or the conclusion of the initial offering period, the Trustee shall pay the Unitholder, in addition to the Unit Value of the tendered Units (in the computation of which the expenses reimbursable pursuant to this Section shall have been deducted), unless otherwise directed by the Depositor, an amount equal to the estimated per Unit cost of organizing the Trust set forth in the Prospectus, or such lower revision thereof most recently communicated to the Trustee by the Depositor, multiplied by the number of Units tendered for redemption; to the extent the cash on hand in the Trust is insufficient for such payments, the Trustee shall have the power to sell Securities in accordance with Section 6.02. As used herein, the Depositor’s reimbursable expenses of organizing the Trust shall include, but are not limited to, the cost of the initial preparation and typesetting of the registration statement, prospectuses (including preliminary prospectuses), the Indenture, and other documents relating to a Trust Securities and Exchange Commission and state blue sky registration fees, the costs of the initial valuation of the portfolio and audit of a Trust, the costs of a portfolio consultant, if any, one-time licensing fees, if any, the initial fees and expenses of the Trustee, and legal and other out-of-pocket expenses related thereto, but not including the expenses incurred in the printing of prospectuses (including preliminary prospectuses), expenses incurred in the preparation and printing of brochures and other advertising materials and any other selling expenses.”