Lease Commencement Date The earlier to occur of (i) the date upon which Tenant first commences to conduct business in the Premises, and (ii) the later to occur of (A) November 1, 2018 and (B) the date upon which the Premises are Ready for Occupancy (as that term is defined in Section 5.1 of the Tenant Work Letter attached hereto as Exhibit B (the “Tenant Work Letter”)).
Lease Commencement Notwithstanding anything contained herein to the contrary, if Lessor, for any reason whatsoever, including Lessor's negligence except as provided for in Article 27(b), cannot deliver possession of the Premises, as provided for in Article 27(a), to Lessee at the commencement of the agreed Term as set forth in Article 2, this Lease shall not be void or voidable, nor shall Lessor be liable to Lessee for any loss or damage resulting therefrom, but in that event, the Term shall be for the full term as specified above to commence from and after the date Lessor shall have delivered possession of the Premises to Lessee or from the date Lessor would have delivered possession of the Premises to Lessee but for Lessee's failure to timely supply to Lessor such drawings and/or information required by Exhibit C or for any other reason attributable to Lessee (herein the "Commencement Date") and to expire midnight of the day immediately preceding Term anniversary of the Commencement Date, and if requested by Lessor, Lessor and Lessee shall, ratify and confirm said Commencement and Expiration Dates by completing and signing Exhibit G attached hereto and made a part hereof.
Termination of Lease (a) Landlord and Tenant hereby agree that, effective as of the Termination Date, the Lease and the term thereof shall terminate and expire, and Tenant’s estate in and right of possession to the Premises shall terminate and be wholly extinguished, as if said Termination Date was originally set forth in the Lease as the expiration date thereunder. Effective as of the Termination Date, neither Landlord nor Tenant shall have any further rights or obligations under the Lease, except as provided in this Agreement. Effective as of the Termination Date, Landlord and Tenant for themselves and their predecessors-in-interest, successors and assigns, do hereby release and forever discharge each other, their successors and assigns, from all actions, causes of action, sums of money, covenants, agreements, promises, damages, judgments, claims and demands whatsoever in law or in equity which each against the other ever had, now has, or which they or their respective predecessors, successors or assigns hereafter may have, upon or by reason of any matter, cause or thing whatsoever from the beginning of the world through the Termination Date arising out of or in connection with the Lease or the Premises, or the Building; provided that (A) neither party shall be released from any of its obligations under this Agreement (and this Agreement shall survive the termination of the Lease), (B) neither Landlord or Tenant shall be released from any indemnification obligations that accrued under the Lease prior to the Termination Date and (C) the provisions of Section 8.13 and Section 8.21 of the Lease shall survive the termination of the Lease. Effective as of the Termination Date, Landlord shall be entitled to lease the Premises to any person or entity, or take any other action with respect thereto, free from any claim of Tenant or any person or entity claiming through Tenant. (b) On or prior to the Termination Date, Tenant agrees to surrender unto Landlord and its successors and assigns, and Landlord agrees to accept, the Premises in its “as is” condition. (c) In consideration of this Agreement and the termination of the Lease, Tenant agrees to permit the letter of credit in the amount of $8,698,662.00 issued by Citibank, N.A. (the “Letter of Credit”) which Letter of Credit Landlord is presently holding as security under the Lease, to be drawn down for the payment of the following sums: (i) $7,800,000.00 (the “Termination Fee”) to be drawn down and paid to Landlord in consideration of the termination of the Lease and the other transactions contemplated by this Agreement; and (ii) $898,662.00, representing the balance of the proceeds of the Letter of Credit shall be paid to Tenant. Tenant hereby authorizes Landlord to draw on the Letter of Credit and the entire proceeds of the Letter of Credit (the “Proceeds”) and Landlord agrees to deliver Tenant’s share of the Proceeds described in clause (ii) above to Tenant’s bank account within three (3) Business Days of Landlord’s receipt of the entire Proceeds in accordance with Tenant’s wire instructions attached hereto as Exhibit A. Except as otherwise set forth in this Agreement, it is agreed that in no event shall Tenant at any time be entitled to receive any other sums from Landlord in connection with the Lease, including, without limitation, all or any portion of the Work Allowance or any reimbursement of any amounts previously paid by Tenant to Landlord in connection with the construction of the Terrace Space. Contemporaneously herewith, Landlord shall deliver a sight draft to the issuer of the Letter of Credit in order to obtain payment of the Proceeds, which sight draft shall provide for the Proceeds to be paid to Landlord’s bank account, as designated by Landlord. Tenant hereby agrees to cooperate with Landlord and execute any and all documents required by the issuing bank in order to facilitate Landlord’s efforts to draw down on the Proceeds of the Letter of Credit. The effectiveness of the surrender and termination provided for in this Agreement is subject to, and conditioned upon, Landlord’s receipt of the Termination Fee in accordance with the terms hereof. If Landlord does not receive the Termination Fee in accordance with the terms hereof, then the termination of the Lease shall automatically be null and void and of no further force or effect and the Lease shall continue in full force and effect as if this Agreement had never been entered into. (d) Tenant shall be responsible for, and shall indemnify Landlord for, any and all transfer taxes, sales taxes or other taxes or similar charges imposed by any federal, state or local governmental authority or under any Law arising from or relating to this Agreement, the Termination Fee or any of the other transactions hereunder. Tenant will execute and deliver to Landlord a New York State Form TP 584 and a New York City Form RPT. (e) Landlord and Tenant agree that the disgorgement of any portion of the Termination Fee or the avoidance in whole or in part of this Agreement, under any applicable law, including, but not limited to, chapter 5 of title 11 of the United States Code (the "Bankruptcy Code"), shall be considered a breach of this Agreement by Tenant and shall entitle Landlord to seek the full amount of the Obligations and any other damages to which Landlord is entitled under the Lease from Tenant resulting from the breach of this Agreement.
Extension of Lease Term The Original Lease Term is hereby extended for a period of eighteen (18) months continuing through and including November 30, 2022 (the “Extension Term” and the Original Lease Term as so extended by the Extension Term, the “Lease Term”).
Rent Commencement Date The "Rent Commencement Date" shall be the date that Tenant first uses the Premises or any portion thereof for any purpose permitted under this lease. In the event this lease pertains to a building or building interior finish to be constructed, the "Rent Commencement Date" shall be the date upon which the buildings and other improvements erected and to be erected upon the premises shall have been substantially completed in accordance with the plans and specifications described on Exhibit "C" attached hereto and incorporated herein by reference, provided however, that if Landlord shall be delayed in such substantial completion as a result of: (i) Tenant's failure to agree to plans, specifications, and cost estimates, within a reasonable period of time; (ii) Tenant's request for materials, finishes or installations other than Landlord's standard; (iii) Tenant's changes in plans; the commencement date and the payment of rent hereunder shall be accelerated by the number of days of such delay, and provided further that if Landlord cannot substantially complete the premises as a result of any events (i) through (iii) above, Landlord may as its election complete so much of Landlord's work as may be practical under the circumstances and, by written notice to Tenant, establish the commencement date as the date of such partial completion, subject to any applicable accelerations due to delays resulting from events (i) through (iii) above. Taking possession by Tenant shall be deemed conclusively to establish that said buildings and other improvements have been completed in accordance with the plans and specifications and that the premises are in good and satisfactory condition, as of when possession was so taken. Tenant acknowledges that no representations as to the repair of the premises have been made by Landlord, unless such are expressly set forth in the lease. After such "Rent Commencement Date" Tenant shall, upon demand, execute and deliver to Landlord a letter of acceptance of delivery of the premises. In the event of any dispute as to substantial completion of work performed, execute or required to be performed by Landlord, the certificate of Landlord's architect or general contractor shall be conclusive.
Commencement of Leave Parental leave must commence no later than the first anniversary date of the birth or adoption of the child or of the date on which the child comes into the actual care and custody of the employee. The employee will decide when his or her parental leave is to commence.
Service Commencement Date The date the Transmission Provider begins to provide service pursuant to the terms of an executed Service Agreement, or the date the Transmission Provider begins to provide service in accordance with Section 15.3 or Section 29.1 under the Tariff.
Commencement Date The Subcontractor shall be permitted to begin the Services on ______________________, 20____ (“Commencement Date”).
TERM OF LEASE This Lease shall commence on the date of ________ and shall continue until its natural termination under this part on the date of ________ at 11:59 PM. After the date of termination, this Lease shall automatically renew and shall continue for the same term amount until Landlord or Tenant undertake cancellation of this Lease in writing. At the expiration of this Lease, Tenant shall be responsible for providing a forwarding address to Landlord to receive any funds owed or other notices.
Tenant’s Lease Default Notwithstanding any provision to the contrary contained in the Lease, if an event of default by Tenant of this Tenant Work Letter or the Lease has occurred at any time on or before the Substantial Completion of the Premises and remains after the expiration of applicable notice and cure periods, then (i) in addition to all other rights and remedies granted to Landlord pursuant to the Lease, at law and/or in equity, Landlord shall have the right to cause the Contractor to suspend the construction of the Premises (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such work stoppage as a Tenant Delay as set forth in Section 4.2 above), and (ii) all other obligations of Landlord under the terms of this Tenant Work Letter shall be forgiven until such time as such default is cured pursuant to the terms of the Lease (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such inaction by Landlord as a Tenant Delay). In addition, if the Lease is terminated prior to the Lease Commencement Date, for any reason due to a default by Tenant as described in Section 19.1 of the Lease or under this Tenant Work Letter, in addition to any other remedies available to Landlord under the Lease, at law and/or in equity, Tenant shall pay to Landlord, as Additional Rent under the Lease, within five (5) business days after Tenant’s receipt of a statement therefor, any and all costs incurred by Landlord and not reimbursed or otherwise paid by Tenant through the date of such termination in connection with the Tenant Improvements to the extent planned, installed and/or constructed as of such date of termination, including, but not limited to, any costs related to the removal of all or any portion of the Tenant Improvements and restoration costs related thereto.
