Common use of ACCEPTANCE OF SCHEDULE Clause in Contracts

ACCEPTANCE OF SCHEDULE. When the Government has accepted any time schedule, it shall be binding on the Contractor. The completion date is fixed and may be extended only by a written modification to the task order signed by the Contracting Officer. Acceptance or approval of any schedule or revision thereof by the Government shall not:

ACCEPTANCE OF SCHEDULE. When the Government has accepted any time schedule, it shall be binding on upon the Contractor. The completion date is fixed and may be extended only by a written modification to the task delivery order signed by the Contracting Officer. Acceptance or approval of any schedule or revision thereof by the Government shall not:not (1) extend the completion date or obligate the Government to do so, (2) constitute acceptance or approval of any delay, nor (3) excuse the Contractor from or relieve the Contractor of its obligation to maintain the progress of the work and achieve final completion by the established completion date.

ACCEPTANCE OF SCHEDULE. When the Government has accepted any time schedule, it shall be binding on the Contractorcontractor. The completion date is fixed and may be extended only by a written modification to the task order signed by the Contracting Officer. Acceptance or approval of any schedule or revision thereof by the Government shall not: (a) extend the completion date or obligate the Government to do so, (b) constitute acceptance or approval of any delay, nor (c) excuse the contractor from or relieve the contractor of its obligation to maintain the progress of the work and achieve final completion by the established completion date.

ACCEPTANCE OF SCHEDULE. When the Government has accepted any time schedule, it shall be binding on upon the Contractor. The completion date is fixed and may be extended only by a written contract modification to the task order signed by the Contracting Officer. Acceptance or approval of any schedule or revision thereof by the Government shall not:not (1) extend the completion date or obligate the Government to do so, (2) constitute acceptance or approval of any delay, or (3) excuse the Contractor from or relieve the Contractor of its obligation to maintain the progress of the work and achieve final completion by the established completion date.

ACCEPTANCE OF SCHEDULE. When the Government has accepted any time schedule, it shall be binding on the Contractor. The completion date is fixed and may be extended only by a written modification to the task order signed by the Contracting Officer. Acceptance or approval of any schedule or revision thereof by the Government shall not: (a) extend the completion date or obligate the Government to do so, (b) constitute acceptance or approval of any delay, nor (c) excuse the Contractor from or relieve the Contractor of its obligation to maintain the progress of the work and achieve final completion by the established completion date.

ACCEPTANCE OF SCHEDULE. When the Government has accepted any time schedule, it this acceptance shall be binding on the Contractor. The completion date is fixed and may be extended only by a written contract modification to the task order signed by the Contracting Officer. Acceptance or approval of any schedule or revision thereof by the Government shall not: (1) extend the completion date or obligate the Government to do so; (2) constitute acceptance or approval of any delay, or; (3) excuse or relieve the Contractor of its obligation to maintain the progress of the work and achieve final completion by the established completion date.