Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Representations and Warranties by the Company and the Operating Partnership Each of the Company and the Operating Partnership, jointly and severally, represents and warrants to each Underwriter as of the date hereof, the Applicable Time, the Closing Time (as defined below) and any Date of Delivery (as defined below), and agrees with each Underwriter, as follows:
Contractor’s Representations and Warranties Contractor represents and warrants that neither the execution of this Agreement by Contractor, nor the acts contemplated hereby, nor compliance by Contractor with any provisions hereof will:
a) Violate any provision of the charter documents of Contractor;
b) Violate any laws, rules, regulations, or any judgment, decree, order, regulation or rule of any court or governmental authority applicable to Contractor; or
c) Violate, or be in conflict with, or constitute a default under, or permit the termination of, or require the consent of any person under, any agreement to which Contractor may be bound, the occurrence of which in the aggregate would have a material adverse effect on the properties, business, prospects, earnings, assets, liabilities, or condition (financial or otherwise) of Contractor.
Representations, Warranties and Covenants of the Mortgage Loan Seller and the Purchaser (a) The Mortgage Loan Seller hereby makes, as of the date hereof (and, in connection with any replacement of a Defective Loan (as defined in Section 4(f) hereof) with one or more Qualified Substitute Mortgage Loans (also as defined in Section 4(f) hereof), pursuant to Section 5(a) hereof, as of the related date of substitution), to and for the benefit of the Purchaser, each of the representations and warranties set forth in Exhibit B-1. The Purchaser hereby makes, as of the date hereof, to and for the benefit of the Mortgage Loan Seller, each of the representations and warranties set forth in Exhibit B-2.
(b) The Mortgage Loan Seller hereby makes, as of the date hereof (or as of such other date specifically provided in the particular representation or warranty), to and for the benefit of the Purchaser, each of the representations and warranties set forth in Exhibit C, subject to the exceptions set forth in Schedule C. The Mortgage Loan Seller is also referred to herein as the “Responsible Repurchase Party”.
(c) The Mortgage Loan Seller hereby represents and warrants, as of the date hereof, to and for the benefit of the Purchaser only, that the Mortgage Loan Seller has not dealt with any broker, investment banker, agent or other person (other than the Depositor or an affiliate thereof, the Underwriters and the Initial Purchasers) who may be entitled to any commission or compensation in connection with the sale to the Purchaser of the Mortgage Loans.
(d) The Mortgage Loan Seller hereby represents and warrants that, with respect to the Mortgage Loans and the Mortgage Loan Seller’s role as “originator” (or the role of any third party as “originator” of any Mortgage Loan for which the Mortgage Loan Seller was not the originator) and “sponsor” in connection with the issuance of the Registered Certificates, the information regarding the Mortgage Loans, the related Mortgagors, the related Mortgaged Properties and/or the Mortgage Loan Seller contained in each of the Preliminary Prospectus and the Prospectus complies in all material respects with the applicable disclosure requirements of Regulation AB as in effect on the date hereof and for which compliance is required as of the date hereof. As used herein, “Regulation AB” means Subpart 229.1100 – Asset Backed Securities (Regulation AB), 17 C.F.R. §§229.1100-229.1125, as such rules may be amended from time to time, and subject to such clarification and interpretation as have been or may hereafter be from time to time provided by the Securities and Exchange Commission (the “Commission”) or by the staff of the Commission, in each case as effective from time to time as of the compliance dates specified therein.
Representations and Warranties of the Adviser and the Administrator The Adviser and the Administrator, jointly and severally, represent to each Underwriter as of the date hereof, as of the Applicable Time, as of the Closing Time referred to in Section 2(c) hereof, and as of each Date of Delivery (if any) referred to in Section 2(b) hereof, and agree with each Underwriter as follows:
Representations and Warranties of the Company and the Operating Partnership The Company and the Operating Partnership hereby jointly and severally represent, warrant and covenant to each Underwriter, as of the date of this Agreement, as of the First Closing Date (as hereinafter defined) and as of each Option Closing Date (as hereinafter defined), if any, as follows:
Buyer’s Representations, Warranties and Covenants Buyer represents, warrants and covenants:
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Outage Authority and Coordination Developer and Connecting Transmission Owner may each, in accordance with NYISO procedures and Good Utility Practice and in coordination with the other Party, remove from service any of its respective Attachment Facilities or System Upgrade Facilities and System Deliverability Upgrades that may impact the other Party’s facilities as necessary to perform maintenance or testing or to install or replace equipment. Absent an Emergency State, the Party scheduling a removal of such facility(ies) from service will use Reasonable Efforts to schedule such removal on a date and time mutually acceptable to both the Developer and the Connecting Transmission Owner. In all circumstances either Party planning to remove such facility(ies) from service shall use Reasonable Efforts to minimize the effect on the other Party of such removal.
Representations, Warranties and Covenants of the Master Servicer and the Company (a) The Master Servicer hereby represents and warrants to the Trustee for the benefit of the Certificateholders that:
(i) The Master Servicer is a corporation duly organized, validly existing and in good standing under the laws governing its creation and existence and is or will be in compliance with the laws of each state in which any Mortgaged Property is located to the extent necessary to ensure the enforceability of each Mortgage Loan in accordance with the terms of this Agreement;
(ii) The execution and delivery of this Agreement by the Master Servicer and its performance and compliance with the terms of this Agreement will not violate the Master Servicer's Certificate of Incorporation or Bylaws or constitute a material default (or an event which, with notice or lapse of time, or both, would constitute a material default) under, or result in the material breach of, any material contract, agreement or other instrument to which the Master Servicer is a party or which may be applicable to the Master Servicer or any of its assets;
(iii) This Agreement, assuming due authorization, execution and delivery by the Trustee and the Company, constitutes a valid, legal and binding obligation of the Master Servicer, enforceable against it in accordance with the terms hereof subject to applicable bankruptcy, insolvency, reorganization, moratorium and other laws affecting the enforcement of creditors' rights generally and to general principles of equity, regardless of whether such enforcement is considered in a proceeding in equity or at law;
(iv) The Master Servicer is not in default with respect to any order or decree of any court or any order, regulation or demand of any federal, state, municipal or governmental agency, which default might have consequences that would materially and adversely affect the condition (financial or other) or operations of the Master Servicer or its properties or might have consequences that would materially adversely affect its performance hereunder;
(v) No litigation is pending or, to the best of the Master Servicer's knowledge, threatened against the Master Servicer which would prohibit its entering into this Agreement or performing its obligations under this Agreement;
(vi) The Master Servicer will comply in all material respects in the performance of this Agreement with all reasonable rules and requirements of each insurer under each Required Insurance Policy;
(vii) No information, certificate of an officer, statement furnished in writing or report delivered to the Company, any Affiliate of the Company or the Trustee by the Master Servicer will, to the knowledge of the Master Servicer, contain any untrue statement of a material fact or omit a material fact necessary to make the information, certificate, statement or report not misleading;
(viii) The Master Servicer has examined each existing, and will examine each new, Subservicing Agreement and is or will be familiar with the terms thereof. The terms of each existing Subservicing Agreement and each designated Subservicer are acceptable to the Master Servicer and any new Subservicing Agreements will comply with the provisions of Section 3.02; and
(ix) The Master Servicer is a member of MERS in good standing, and will comply in all material respects with the rules and procedures of MERS in connection with the servicing of the Mortgage Loans that are registered with MERS. It is understood and agreed that the representations and warranties set forth in this Section 2.03(a) shall survive delivery of the respective Mortgage Files to the Trustee or any Custodian. Upon discovery by either the Company, the Master Servicer, the Trustee or any Custodian of a breach of any representation or warranty set forth in this Section 2.03(a) which materially and adversely affects the interests of the Certificateholders in any Mortgage Loan, the party discovering such breach shall give prompt written notice to the other parties (any Custodian being so obligated under a Custodial Agreement). Within 90 days of its discovery or its receipt of notice of such breach, the Master Servicer shall either (i) cure such breach in all material respects or (ii) to the extent that such breach is with respect to a Mortgage Loan or a related document, purchase such Mortgage Loan from the Trust Fund at the Purchase Price and in the manner set forth in Section 2.02; provided that if the omission or defect would cause the Mortgage Loan to be other than a "qualified mortgage" as defined in Section 860G(a)(3) of the Code, any such cure or repurchase must occur within 90 days from the date such breach was discovered. The obligation of the Master Servicer to cure such breach or to so purchase such Mortgage Loan shall constitute the sole remedy in respect of a breach of a representation and warranty set forth in this Section 2.03(a) available to the Certificateholders or the Trustee on behalf of the Certificateholders.
(b) Representations and warranties relating to the Mortgage Loans are set forth in Section 2.03(b) of the Series Supplement.
