Accounts Application of Rents Received and Managing Agent
Accounts Application of Rents Received and Managing Agent Sample Clauses
Related to Accounts Application of Rents Received and Managing Agent
Collection of Rents Upon the occurrence of an Event of Default, the license granted to Mortgagor to collect the Rents shall be automatically and immediately revoked, without further notice to or demand upon Mortgagor. Mortgagee may, but shall not be obligated to, exercise any or all of the rights and remedies provided in Section 697.07 of the Florida Statutes and perform any or all obligations of the landlord under any or all of the Leases, and Mortgagee may, but shall not be obligated to, exercise and enforce any or all of Mortgagor’s rights under the Leases. Without limiting the generality of the foregoing, Mortgagee may notify the tenants under the Leases that all Rents are to be paid to Mortgagee, and following such notice all Rents shall be paid directly to Mortgagee and not to Mortgagor or any other Person other than as directed by Mortgagee, xx xxxxg understood that a demand by Mortgagee on any tenant under the Leases for the payment of Rent shall be sufficient to warrant payment by such tenant of Rent to Mortgagee without the necessity of further consent by Mortgagor. Mortgagor hereby irrevocably authorizes and directs the tenants under the Leases to pay all Rents to Mortgagee instead of to Mortgagor, upon receipt of written notice from Mortgagee, without the necessity of any inquiry of Mortgagor xxx xxxxout the necessity of determining the existence or non-existence of an Event of Default. Mortgagor hereby appoints Mortgagee as Mortgagor’x xxxxxxey-in-fact with full power of substitution, which appointment shall take effect upon the occurrence of an Event of Default and is coupled with an interest and is irrevocable prior to the full and final payment and performance of the Obligations, in Mortgagor’x xxxx xr in Mortgagee’s name: (a) to endorse all checks and other instruments received in payment of Rents and to deposit the same in any account selected by Mortgagee; (b) to give receipts and releases in relation thereto; (c) to institute, prosecute and/or settle actions for the recovery of Rents; (d) to modify the terms of any Leases including terms relating to the Rents payable thereunder; (e) to cancel any Leases; (f) to enter into new Leases; and (g) to do all other acts and things with respect to the Leases and Rents which Mortgagee may deem necessary or desirable to protect the security for the Obligations. Any Rents received shall be applied first to pay all Expenses and next in reduction of the other Obligations. Mortgagor shall pay, on demand, to Mortgagee, the amount of any deficiency between (i) the Rents received by Mortgagee, and (ii) all Expenses incurred together with interest thereon as provided in the Loan Agreement and the other Loan Documents.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Collection of Rent In any case where State has a cause of action for damages, State shall have the privilege of splitting the cause to permit the institution of a separate suit for rent due hereunder, and neither institution of any suit, nor the subsequent entry of judgment shall bar State from bringing another suit for rent; it being the purpose of this provision to provide that the forbearance on the part of State in any suit or entry of judgment for any part of the rent reserved under this Contract, to sue for, or to include in, any suit and judgment the rent then due, shall not serve as defense against, nor prejudice a subsequent action for, rent or other obligations due under the Contract. The claims for rent may be regarded by State, if it so elects, as separate claims capable of being assigned separately.
Construction Administration Phase Delete the following paragraph if Submittal Exchange isn’t going to be used: 2.
Construction Administration Redeveloper shall be responsible for all components of the Redeveloper Improvements constructed by Redeveloper including construction management, coordination of contractors and regulatory permitting and other requirements. Redeveloper and its contractor(s) shall reasonably cooperate with City contractors performing work in the vicinity of the Redevelopment Project Area including, but not limited to, Redeveloper's scheduling of its work to provide for a smooth sequence of operations. The Redeveloper will be solely responsible for payment of all construction costs for the Redeveloper Improvements as set forth in this Redevelopment Agreement.
Collateral Protection Expenses Preservation of Collateral (a) If an Event of Default shall have occurred and be continuing, the Agent may discharge taxes and other encumbrances at any time levied or placed on any of the Collateral, make repairs thereto and pay any necessary filing fees. Each Grantor agrees to reimburse the Agent on demand for any and all expenditures so made. The Agent shall have no obligation to any Grantor to make any such expenditures, nor shall the making thereof relieve any Grantor of any default. (b) Anything herein to the contrary notwithstanding, each Grantor shall remain liable under each contract or agreement comprised in the Collateral to be observed or performed by such Grantor thereunder. The Agent shall not have any obligation or liability under any such contract or agreement by reason of or arising out of this Agreement or the receipt by the Agent of any payment relating to any of the Collateral, nor shall the Agent be obligated in any manner to perform any of the obligations of any Grantor under or pursuant to any such contract or agreement, to make inquiry as to the nature or sufficiency of any payment received by the Agent in respect of the Collateral or as to the sufficiency of any performance by any party under any such contract or agreement, to present or file any claim, to take any action to enforce any performance or to collect the payment of any amounts which may have been assigned to the Agent or to which the Agent may be entitled at any time or times. The Agent’s sole duty with respect to the custody, safe keeping and physical preservation of the Collateral in its possession, under Sections 9-207 and 9-208 of the UCC or otherwise, shall be to deal with such Collateral in the same manner as the Agent deals with similar property for its own account. (c) Each Grantor shall, to the extent reasonably necessary to preserve and maintain the Intellectual Property Collateral and the interest of the Agent therein, diligently pursue legal or other action to enforce the Intellectual Property Collateral and any licenses thereof.
Audit Rights Period for Construction-Related Accounts and Records Accounts and records related to the design, engineering, procurement, and construction of Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades shall be subject to audit for a period of twenty-four months following Connecting Transmission Owner’s issuance of a final invoice in accordance with Article 12.2 of this Agreement.
Administrative Procedures Administrative procedures with respect to the sale of Notes shall be agreed upon from time to time by the Agents and the Company (the "Procedures"). The Agents and the Company agree to perform the respective duties and obligations specifically provided to be performed by them in the Procedures.
Loan Administration Advances made under the Loans shall be as follows: (a) A request for an advance shall be made by Borrower giving Lender notice of its intention to borrow, in which notice Borrower shall specify the amount of the proposed borrowing, whether such proposed borrowing will be a borrowing under this First Revolving Loan or the Second Revolving Loan, and the proposed borrowing date, not later than 2:00 p.m. Eastern time one (1) business day prior to the proposed borrowing date; provided, however, that no such request may be made at a time when there exists an Event of Default. (b) In the case of each request for an advance under the First Revolving Loan, Borrower shall deliver to Lender, concurrently with delivery of the notice of borrowing required by clause (a) of this Section 18.4, a Borrowing Base Certificate executed by Borrower and prepared as of a date not more than thirty (30) business days prior to the date of such requested advance. (c) Borrower hereby authorizes Lender to disburse the proceeds of each revolving credit advance requested by wire transfer to such bank account as may be agreed upon by Borrower and Lender from time to time or elsewhere if pursuant to written direction from Borrower. (d) All revolving credit advances and other extensions of credit to or for the benefit of Borrower shall constitute one general Obligation of Borrower and shall be secured by Lender's lien upon all of the Collateral. (e) Lender shall enter all revolving credit advances as debits to a loan account in the name of Borrower and shall also record in said loan account all payments made by Borrower on any Obligations and all proceeds of Collateral which are indefeasibly paid to Lender, and may record therein, in accordance with customary accounting practice, other debits and credits, including interest and all charges and expenses properly chargeable to Borrower. All payments and collections shall be applied first to fees, costs and expenses due and owing under the Documents, then to interest due and owing under the Documents, and then to principal outstanding under the Loan. (f) Lender will account to Borrower monthly with a statement of the Loans, charges and payments made pursuant to this Agreement, and such accounting rendered by Lender shall be deemed final, binding and conclusive upon Borrower unless Lender is notified by Borrower in writing to the contrary within thirty (30) days of the date each accounting is mailed to Borrower. Such notices shall be deemed an objection to those items specifically objected to therein. (g) Borrower shall establish one or more bank accounts for deposits of advances made under the Loans and for deposits of repayments of Third Party Loans, and shall assign such accounts to Lender. Borrower shall not deposit advances from Lender or repayments from borrowers under Third Party Loans into any other accounts.
COLLECTION OF CHARGES 16.1 A Sector Association may request the consent of the Administrator to collect charges due from Operators to the Administrator in respect of facilities under the charging scheme. 16.2 If a Sector Association wishes to collect charges due from an Operator to the Administrator under the charging scheme, the Sector Association may serve a notice in writing on the Administrator by the last working day in February in the calendar year in which the charges fall due. 16.3 A notice served under Rule 16.2 must specify the facilities in respect of which the Sector Association intends to collect charges, being not fewer than 50% of the facilities covered by an umbrella agreement. 16.4 Following receipt of the notice, the Administrator must: 16.4.1 consent to the Sector Association collecting charges; or 16.4.2 refuse consent to the Sector Association collecting charges, giving reasons for the decision. 16.5 If the Administrator consents to the Sector Association collecting charges the Sector Association must: 16.5.1 itemise charges separately in any invoices that it issues in respect of charges; 16.5.2 collect and remit all charges collected to the Administrator without deduction or set off by the last working day in September in each year; 16.5.3 prepare an annual report to the Administrator by the last working day in October in the year in which it has collected charges setting out which Operators it has collected charges from and which Operators have failed to pay charges due to the Sector Association. 16.6 A Sector Association must not actively pursue any outstanding charges after the last working day in September in any year in which they fall due. If a Sector Association receives charges after this date the Sector Association must accept the payment and remit this to the Environment Agency along with information identifying the Operator making the payment. 16.7 If a Sector Association fails to comply with any of its obligations under this Rule the Administrator may serve a notice on the Sector Association that consent to the Sector Association continuing to collect charges is withdrawn at the expiry of 20 working days from the date of the notice.
