Acquisition of Project Issuance of Bonds Project Fund Sample Clauses

Open Split View

Download

Share

Cite

Acquisition of Project Issuance of Bonds Project Fund 

Sample 1Sample 2Sample 3

Save

Copy

Related to Acquisition of Project Issuance of Bonds Project Fund

• Construction of Project 11.1.1 Developer agrees to cause the Project to be developed, constructed, and installed in accordance with the terms hereof and the Construction Provisions set forth in Exhibit D, including those things reasonably inferred from the Contract Documents as being within the scope of the Project and necessary to produce the stated result even though no mention is made in the Contract Documents.

• Completion of Project This Grant Agreement shall terminate upon completion of the project and payment of the last invoice.

• PROJECT FUNDING 8.1 The Project Funding for completion of this PFA is as follows:[X]

• EVALUATION OF PROJECT BENEFITS The goal of this task is to report the benefits resulting from this project.

• Project Fund (a) All proceeds of the Governmental Lender Notes provided by the Funding Lender shall be deposited to the Note Proceeds Account or Capitalized Interest Account of the Project Fund and disbursed as herein provided. The Fiscal Agent shall disburse moneys in the Note Proceeds Account of Project Fund for the acquisition, construction and equipping of the Project, to pay other Qualified Project Costs and to pay other costs related to the Project as provided herein as requested by the Borrower pursuant to a Written Requisition in the form attached hereto as Exhibit C. All funds deposited by or on behalf of the Borrower for credit to the Borrower Equity Account Project Fund shall be disbursed as requested by the Borrower pursuant to a Written Requisition in the form attached hereto as Exhibit C. Before any payment shall be made from the Project Fund, the Regulatory Agreement shall have been executed and submitted to a title company for recordation in the official records of Travis County, Texas, and there shall be filed with the Fiscal Agent a Written Requisition of the Borrower substantially in the form attached hereto as Exhibit C and approved by the Funding Lender pursuant to the terms, conditions and provisions of the Construction Funding Agreement. In addition to the above, in connection with a Written Requisition: (1) Only the signature of an Authorized Representative of the Funding Lender shall be required on a Written Requisition during any period in which Borrower Loan Agreement Default has occurred and is then continuing under the Borrower Loan Documents (Written Notice of which default has been given by an Authorized Representative of the Funding Lender to the Fiscal Agent and the Governmental Lender, and the Fiscal Agent shall be entitled to conclusively rely on any such Written Notice as to the occurrence and continuation of such a default). (2) The Fiscal Agent shall disburse amounts in the Project Fund for the payment of interest due on the Governmental Lender Note upon receipt from the Funding Lender of a statement detailing the amount due (and without the need for a Written Requisition signed by the Funding Lender or any approval by an Authorized Representative of the Borrower). (3) The Fiscal Agent may conclusively rely on all Written Requisitions, the execution of the Written Requisitions by the Authorized Representative of the Borrower and the approval of all Written Requisitions by the Authorized Representative of the Funding Lender, as required by this Section, as conditions of payment from the Project Fund, which Written Requisitions constitute, as to the Fiscal Agent, irrevocable determinations that all conditions to payment of the specified amounts from the Project Fund have been satisfied. These documents shall be retained by the Fiscal Agent, subject at all reasonable times to examination by the Borrower, the Governmental Lender, the Funding Lender and the agents and representatives thereof upon reasonable notice to the Fiscal Agent. The Fiscal Agent is not required to inspect the Project or the construction work or to make any independent investigation with respect to the matters set forth in any Written Requisition or other statements, orders, certifications and approvals received by the Fiscal Agent. The Fiscal Agent is not required to obtain completion bonds, lien releases or otherwise supervise the acquisition, construction, renovation, equipping, improvement and installation of the Project. (b) Upon receipt of each Written Requisition submitted by the Borrower and Approved in Writing by the Funding Lender, the Fiscal Agent shall promptly, but in any case within three Business Days, make payment from the appropriate account within the Project Fund in accordance with such Written Requisition. The Fiscal Agent shall have no duty to determine whether any requested disbursement from the Note Proceeds Account of the Project Fund complies with the terms, conditions and provisions of the Funding Loan Documents, constitutes payment of Qualified Project Costs or complies with the other representations in the Written Requisition. The Approval in Writing of a Written Requisition by the Funding Lender shall be deemed a certification and, insofar as the Fiscal Agent is concerned, shall constitute conclusive evidence that all of the terms, conditions and requirements of the Funding Loan Documents applicable to such disbursement have been fully satisfied or waived and the Written Requisition from the Borrower shall, insofar as the Fiscal Agent is concerned, constitute conclusive evidence that the costs described in the Written Requisition constitute Qualified Project Costs or other permitted Project costs. (c) Moneys on deposit in the Capitalized Interest Account of the Project Fund, together with investment earnings thereon, which shall be retained therein, shall be transferred to the Governmental Lender Note Payment Fund and applied pursuant to Section 7.4 on each Borrower Loan Payment Date to the extent necessary to enable the Fiscal Agent to pay interest due on the Funding Loan on such date; provided that, upon receipt of a Written Direction of the Borrower, moneys on deposit in the Capitalized Interest Account of the Project Fund shall be transferred to the Servicer on the date when due under the Borrower Note in an amount as set forth in such Written Direction, which amount shall represent the Borrower Loan Payment due at such time. Upon the request of the Fiscal Agent, the Servicer shall provide the Fiscal Agent with a schedule of the Borrower Loan Payment Dates and corresponding Borrower Loan Payment amounts. The transfer of moneys from the Capitalized Interest Account of the Project Fund to the Governmental Lender Note Payment Fund or the Servicer as set forth above shall occur automatically without the need for a Written Requisition of the Borrower, or consent of the Funding Lender. After the Closing Date, the Borrower, with the written consent of the Funding Lender, may deposit additional funds into the Capitalized Interest Account. (d) Immediately prior to any mandatory prepayment of the Governmental Lender Notes pursuant to the terms hereof, any amounts then remaining in the Project Fund shall, at the Written Direction of the Funding Lender, be transferred to the Governmental Lender Note Payment Fund to be applied to the prepayment of the Governmental Lender Notes pursuant hereto. (e) Amounts on deposit in the Project Fund shall be invested in Permitted Investments at the Written Direction of the Borrower. Investment income earned on amounts on deposit in each account of the Project Fund shall be retained in and credited to and become a part of the amounts on deposit in that account of the Project Fund. (f) Amounts on deposit in the Governmental Lender Note Payment Fund, Expense Fund and Closing Costs Fund shall be invested in Permitted Investments at the Written Direction of the Borrower. The Fiscal Agent shall have no discretion for investing funds or advising any party on investing funds. Investment income earned on amounts on deposit in each account of the Governmental Lender Note Payment Fund, Expense Fund and Closing Costs Fund shall be retained in and credited to and become a part of the amounts on deposit in that account of the Governmental Lender Note Payment Fund, Expense Fund and Closing Costs Fund. In the absence of Written Direction from the Borrower, such amounts shall be invested by the Fiscal Agent only in investments described in (e) of the definition of Permitted Investments. The Fiscal Agent is authorized to implement its automated cash investment system to assure that cash on hand is invested and to charge its normal cash management fees, which may be deducted from income earned on investments. The Fiscal Agent shall not be liable for any losses (including, specifically depreciation of value) resulting from investments made in Permitted Investments. The Fiscal Agent shall not be responsible for the Governmental Lender Notes becoming "arbitrage bonds" as defined in the Code when it makes investments pursuant to the terms hereof. The Fiscal Agent may make any and all investments permitted under this Funding Loan Agreement through its own trust or banking department or any Affiliate and may pay said department reasonable, customary fees for placing such investments. The Fiscal Agent and its Affiliates may act as principal, agent, sponsor, advisor or depository with respect to Permitted Investments under this Funding Loan Agreement. The Fiscal Agent shall have no responsibility or liability for any loss which may result from any investment or sale of investment made pursuant to this Funding Loan Agreement. The Fiscal Agent is hereby authorized in making or disposing of any investment permitted by this Funding Loan Agreement, to deal with itself (in its individual capacity) or with any one or more of its affiliates, whether it or any such affiliate is acting as agent of the Fiscal Agent or for any third person or dealing as principal for its own account. The Governmental Lender, the Funding Lender and the Borrower acknowledge that the Fiscal Agent is not providing investment supervision, recommendations, or advice. The Governmental Lender, the Funding Lender and the Borrower (by its execution of the Borrower Loan Agreement) acknowledge that to the extent regulations of the Comptroller of the Currency or other applicable regulatory entity grant the Governmental Lender or the Funding Lender the right to receive brokerage confirmations of security transactions as they occur, the Governmental Lender and the Funding Lender will not receive such confirmations to the extent permitted by law. The Fiscal Agent shall furnish the Borrower, the Funding Lender and the Governmental Lender (to the extent requested by such parties) periodic cash transaction statements which shall detail for all investment transactions, if any, made by the Fiscal Agent hereunder. (g) Unless otherwise approved by the Governmental Lender and the Funding Lender, any amounts representing proceeds of the Funding Loan remaining on deposit in any fund or account held under this Funding Loan Agreement on the Outside Conversion Date, shall be immediately transferred to the Funding Loan Payment Account and used to prepay the Governmental Lender Notes.

• Application of Proceeds of Sale The proceeds of any sale of Collateral pursuant to Section 6, as well as any Collateral consisting of cash, shall be applied by the Collateral Agent as follows: FIRST, to the payment of all costs and expenses incurred by the Collateral Agent in connection with such sale or otherwise in connection with this Agreement, any other Loan Document or any of the Obligations, including all court costs and the reasonable fees and expenses of its agents and legal counsel, the repayment of all advances made by the Collateral Agent hereunder or under any other Loan Document on behalf of any Pledgor and any other costs or expenses incurred in connection with the exercise of any right or remedy hereunder or under any other Loan Document; SECOND, to the payment in full of the Obligations (the amounts so applied to be distributed among the Secured Parties pro rata in accordance with the amounts of the Obligations owed to them on the date of any such distribution); and THIRD, to the Pledgors, their successors or assigns, or as a court of competent jurisdiction may otherwise direct. The Collateral Agent shall have absolute discretion as to the time of application of any such proceeds, moneys or balances in accordance with this Agreement. Upon any sale of the Collateral by the Collateral Agent (including pursuant to a power of sale granted by statute or under a judicial proceeding), the receipt of the purchase money by the Collateral Agent or of the officer making the sale shall be a sufficient discharge to the purchaser or purchasers of the Collateral so sold and such purchaser or purchasers shall not be obligated to see to the application of any part of the purchase money paid over to the Collateral Agent or such officer or be answerable in any way for the misapplication thereof.

• Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.

• Initial Contribution of Trust Property; Organizational Expenses The Property Trustee acknowledges receipt in trust from the Depositor in connection with the Original Trust Agreement of the sum of $10, which constituted the initial Trust Property. The Depositor shall pay organizational expenses of the Trust as they arise or shall, upon request of any Trustee, promptly reimburse such Trustee for any such expenses paid by such Trustee. The Depositor shall make no claim upon the Trust Property for the payment of such expenses.

• Trustee Not Responsible for Recitals, Disposition of Securities or Application of Proceeds Thereof The recitals contained herein and in the Securities, except the Trustee’s certificates of authentication, shall be taken as the statements of the Issuer, and the Trustee assumes no responsibility for the correctness of the same. The Trustee makes no representation as to the validity or sufficiency of this Indenture or of the Securities. The Trustee shall not be accountable for the use or application by the Issuer of any of the Securities or of the proceeds thereof.

• Application of Proceeds Subject to the terms of the First Lien Intercreditor Agreement and the Second Lien Intercreditor Agreement, in each case, if executed, any amount received by the Administrative Agent or the Collateral Agent from any Credit Party (or from proceeds of any Collateral) following any acceleration of the Obligations under this Agreement or any Event of Default with respect to the Borrower under Section 11.4 shall be applied: (i) first, to the payment of all reasonable and documented costs and expenses incurred by the Administrative Agent or the Collateral Agent in connection with any collection or sale of the Collateral or otherwise in connection with any Credit Document, including all court costs and the reasonable fees and expenses of its agents and legal counsel, the repayment of all advances made by the Administrative Agent or the Collateral Agent hereunder or under any other Credit Document on behalf of any Credit Party and any other reasonable and documented costs or expenses incurred in connection with the exercise of any right or remedy hereunder or under any other Credit Document to the extent reimbursable hereunder or thereunder; (ii) second, to the Secured Parties, an amount (x) equal to all Obligations owing to them on the date of any distribution and (y) sufficient to Cash Collateralize all Letters of Credit Outstanding on the date of any distribution, and, if such moneys shall be insufficient to pay such amounts in full and Cash Collateralize all Letters of Credit Outstanding, then ratably (without priority of any one over any other) to such Secured Parties in proportion to the unpaid amounts thereof and to Cash Collateralize the Letters of Credit Outstanding; and (iii) third, any surplus then remaining shall be paid to the applicable Credit Parties or their successors or assigns or to whomsoever may be lawfully entitled to receive the same or as a court of competent jurisdiction may direct; provided that any amount applied to Cash Collateralize any Letters of Credit Outstanding that has not been applied to reimburse the Borrower for Unpaid Drawings under the applicable Letters of Credit at the time of expiration of all such Letters of Credit shall be applied by the Administrative Agent in the order specified in clauses (i) through (iii) above. Notwithstanding the foregoing, amounts received from any Guarantor that is not an “Eligible Contract Participant” (as defined in the Commodity Exchange Act) shall not be applied to its Obligations that are Excluded Swap Obligations.