Additional Time Limitations. The time limits provided in this Article shall be strictly observed but may be extended by written agreement of the parties.
Additional Time Limitations Sample Clauses
Related to Additional Time Limitations
Time Limitations Neither Parent nor Acquisition Corp. shall have any liability (for indemnification or otherwise) with respect to any representation or warranty, or agreement to be performed and complied with prior to the Effective Time, unless on or before the two-year anniversary of the Effective Time (the “Claims Deadline”), Parent is given notice of a claim with respect thereto, in accordance with Section 8.05, specifying the factual basis therefor in reasonable detail to the extent then known by the Company Indemnified Parties.
Time Limitation The time limits established in the grievance procedures shall be followed by the parties and the aggrieved employee. If the time limit procedure is not followed by the Union or the aggrieved employee, the grievance shall be considered settled without precedent. If the time procedure is not followed by the Employer, the grievance shall automatically advance to the next step, but arbitration shall only be instituted upon timely written notice by the Union. The time limits established in the grievance and arbitration procedure may be extended by mutual agreement reduced to writing and signed by the parties.
PERIOD OF LIMITATIONS No legal action shall be brought and no cause of action shall be asserted by or in the right of the Company against Indemnitee, Indemnitee’s spouse, heirs, executors or personal or legal representatives after the expiration of two years from the date of accrual of such cause of action, and any claim or cause of action of the Company shall be extinguished and deemed released unless asserted by the timely filing of a legal action within such two-year period; provided, however, that if any shorter period of limitations is otherwise applicable to any such cause of action such shorter period shall govern.
Extension of Time Limits The time limits referred to in this Article may be extended by mutual agreement of the parties in writing.
Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely: (a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv); (b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13); (c) occurrence of a Force Majeure Event; (d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and (e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement. (ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder. (iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim. (iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension. (v) If the event or circumstance giving rise to the notice has a continuing effect: (a) a fully detailed claim shall be considered as interim; (b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and (c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof
Extension of Time Periods The parties may extend any period of time provided in this Article 7 by mutual agreement.
Limitation Periods To the extent that any limitation period applies to any claim for payment of the Obligations or remedy for enforcement of the Obligations, the Obligor agrees that: (a) any limitation period is expressly excluded and waived entirely if permitted by applicable law; (b) if a complete exclusion and waiver of any limitation period is not permitted by applicable law, any limitation period is extended to the maximum length permitted by applicable law; (c) any applicable limitation period shall not begin before an express demand for payment of the Obligations is made in writing by the Credit Union to the Obligor; and (d) any applicable limitation period shall begin afresh upon any payment or other acknowledgment of the Obligations by the Obligor.
Usage Limitations You shall use best efforts to ensure that only Authorized Customer Support Users are provided access to the Service Desk Infrastructure and Student Support Services, including not causing or permitting third parties to access such infrastructure or services.
DISCLAIMERS; EXCLUSIONS; LIMITATIONS Subject to §4, neither party makes any warranties (express, implied, or otherwise), including implied warranties of merchantability, non-infringement, fitness for a particular purpose, or title, related to its performance or anything else provided under this Agreement. Neither party will be liable for any special, incidental, punitive, or consequential damages of any kind for any reason whatsoever relating to this Agreement, even if such damages were reasonably foreseeable.
Amending of Time Limits The time limits fixed in both the grievance and arbitration procedure may be extended by consent of the parties.
