Applications for Payment 9.3.1 At least ten days before the date for each progress payment established in the State- Contractor Agreement, the Contractor shall submit to the Architect an itemized Application for Payment, notarized if required, supported by such data substantiating the Contractor's right to payment as the State or the Architect may require. The application for payment must, at a minimum, reflect retainage and the required waivers of lien and any other support documentation enumerated elsewhere in the Contract Documents.
Application for Payment The form acceptable to Owner that is to be used by the Contractor during the course of the Work in requesting payment from the Owner and that is to be accompanied by such supporting documentation as is required by the Contract Documents.
Subcontractor Payments Subject to Agency’s prior approval, Agency will reimburse Outside Counsel for the actual, reasonable and necessary expenses relating to Outside Counsel’s use of subcontractors. Outside Counsel shall be responsible for any payments and other claims due to subcontractors for work performed under this OCC. Outside Counsel, in subcontracting for any performances or in support of any of the performances specified herein (e.g., expert services, local counsel, and other services), expressly understands and agrees that Agency shall not be directly liable in any manner to Outside Counsel’s subcontractor(s).
Contractor’s Submittals The Contract shall submit with reasonable promptness consistent with the Work Project Schedule and in orderly sequence all Shop Drawings, Samples, or other information required by the Contract Documents, or subsequently required by Change Order. Prior to submitting, the Contractor shall review each submittal for compliance with the Contract Documents and certify its approval by an approval stamp affixed to each copy. Submittal data presented without the Contractor’s certification will be returned without review or comment, and any delay resulting from such certification is the Contractor's responsibility.
000 APPLICATION FOR PROJECT AGREEMENT 1.100 Any Company desiring to enter into a Project Agreement for Maintenance by Contract, must appear before the General Presidents' Committee (hereinafter the "Committee") for purposes of review and orientation and present to the Committee written evidence of the Owner's intent to engage that Company in the performance of maintenance service for a minimum period of one full year, subject to the usual termination clauses in such contracts.
CONTRACTOR’S SUBMISSION OF CONTRACT MODIFICATIONS In connection with any Contract modification, OGS reserves the right to: request additional information reject Contract modifications remove Products from Contract modification requests request additional discounts for new or existing Products
SCOPE OF ARCHITECT’S BASIC SERVICES 3.1 The Architect’s Basic Services consist of those described in this Article 3 and include usual and customary structural, mechanical, and electrical engineering services. Services not set forth in this Article 3 are Supplemental or Additional Services.
Contractor’s Fee When all the Work is performed on the basis of cost-plus, Contractor’s fee shall be determined as set forth in the Agreement. When the value of any Work covered by a Change Order for an adjustment in Contract Price is determined on the basis of Cost of the Work, Contractor’s fee shall be determined as set forth in Paragraph 12.01.C.
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Treatment of Unallowable Costs Previously Submitted for Payment Defendants further agree that within 90 days of the Effective Date of this Agreement they shall identify to applicable Medicare and TRICARE fiscal intermediaries, carriers, and/or contractors, and Medicaid and FEHBP fiscal agents, any Unallowable Costs (as defined in this Paragraph) included in payments previously sought from the United States, or any State Medicaid program, including, but not limited to, payments sought in any cost reports, cost statements, information reports, or payment requests already submitted by Defendants or any of their subsidiaries or affiliates, and shall request, and agree, that such cost reports, cost statements, information reports, or payment requests, even if already settled, be adjusted to account for the effect of the inclusion of the Unallowable Costs. Defendants agree that the United States, at a minimum, shall be entitled to recoup from Defendants any overpayment plus applicable interest and penalties as a result of the inclusion of such Unallowable Costs on previously-submitted cost reports, information reports, cost statements, or requests for payment. Any payments due after the adjustments have been made shall be paid to the United States pursuant to the direction of the Department of Justice and/or the affected agencies. The United States reserves its rights to disagree with any calculations submitted by Defendants or any of their subsidiaries or affiliates on the effect of inclusion of Unallowable Costs (as defined in this Paragraph) on Defendants or any of their subsidiaries or affiliates’ cost reports, cost statements, or information reports.
