REQUIRED FOR PART 2 JOC - PRICING OF Regular Hours Coefficient What is your regular hours coefficient for the RS Means Price Book? (FAILURE TO RESPOND PROHIBITS PART 2 JOC EVALUATION) Remember that this is a ceiling price proposed. You can discount lower than your proposed contract coefficient, but not higher. This is one of three pricing questions that are required for consideration for award on this solicitation. Please consider your answer carefully. An explanation of the TIPS scoring of pricing is included in the attachments for your information. The below is an Example of how pricing model works (not intended to influence your proposed coefficient, you should propose a coefficient that you determine is right for your business): To propose the exact pricing as the RS Means Unit Price Book, you would insert a 1.0 and to propose a 5% discount for the RS Means Price Book would be a .95 regular hours coefficient and so on.
OTHER PAYMENT REQUIREMENTS No payment is due for leave days, for days in which treatment is not provided, or for days on which the patient is absent from treatment (whether excused or unexcused).
Treatment of Unallowable Costs Previously Submitted for Payment Defendants further agree that within 90 days of the Effective Date of this Agreement they shall identify to applicable Medicare and TRICARE fiscal intermediaries, carriers, and/or contractors, and Medicaid and FEHBP fiscal agents, any Unallowable Costs (as defined in this Paragraph) included in payments previously sought from the United States, or any State Medicaid program, including, but not limited to, payments sought in any cost reports, cost statements, information reports, or payment requests already submitted by Defendants or any of their subsidiaries or affiliates, and shall request, and agree, that such cost reports, cost statements, information reports, or payment requests, even if already settled, be adjusted to account for the effect of the inclusion of the Unallowable Costs. Defendants agree that the United States, at a minimum, shall be entitled to recoup from Defendants any overpayment plus applicable interest and penalties as a result of the inclusion of such Unallowable Costs on previously-submitted cost reports, information reports, cost statements, or requests for payment. Any payments due after the adjustments have been made shall be paid to the United States pursuant to the direction of the Department of Justice and/or the affected agencies. The United States reserves its rights to disagree with any calculations submitted by Defendants or any of their subsidiaries or affiliates on the effect of inclusion of Unallowable Costs (as defined in this Paragraph) on Defendants or any of their subsidiaries or affiliates’ cost reports, cost statements, or information reports.
Required Forms If subcontractors are used under the contract that has no stated HUB goal, Exhibits H-1, H-2, H-4 and H-6 are required. Exhibits H-1 and H-6 are required if no subcontractors are being used to perform work under this contract. State of Texas HUB Subcontracting Plan Prime Contractor Progress Assessment Report (Exhibit H-6) is required monthly even when no subcontracting activity has occurred. In addition, State of Texas HUB Subcontracting Plan Prime Contractor Progress Assessment Report (Exhibit H-6) should be submitted with the Provider’s invoice. EXHIBIT H-1 Texas Department of Transportation Subprovider Monitoring System Commitment Worksheet Contract #: Assigned Goal: % Federally Funded State Funded Prime Provider: Total Contract Amount: Prime Provider Info: DBE HUB Both Vendor ID #: DBE/HUB Expiration Date: (First 11 Digits Only) If no subproviders are used on this contract, please indicate by placing “N/A” on the 1st line under Subproviders. Subprovider(s) (List All) Type of Work Vendor ID # (First 11 Digits Only) D=DBE H=HUB Expiration Date $ Amount or % of Work * Subprovider(s) Contract or % of Work* Totals *For Work Authorization Contracts, indicate the % of work to be performed by each subprovider. Total DBE or HUB Commitment Dollars $ Total DBE or HUB Commitment Percentages of Contract % (Commitment Dollars and Percentages are for Subproviders only) EXHIBIT H-2 Texas Department of Transportation Subprovider Monitoring System Commitment Agreement This commitment agreement is subject to the award and receipt of a signed contract from the Texas Department of Transportation (TxDOT). NOTE: Exhibit H-2 is required to be attached to each contract that does not include work authorizations. Exhibit H-2 is required to be attached with each work authorization. Exhibit H-2 is also required to be attached to each supplemental work authorization. If DBE/HUB Subproviders are used, the form must be completed and signed. If no DBE/HUB Subproviders are used, indicate with “N/A” on this line: and attach with the work authorization or supplemental work authorization. Contract #: Assigned Goal: % Prime Provider: Work Authorization (WA)#: WA Amount: Date: Supplemental Work Authorization (SWA) #: to WA #: SWA Amount: Revised WA Amount: Description of Work (List by category of work or task description. Attach additional pages, if necessary.) Dollar Amount (For each category of work or task description shown.) Total Commitment Amount (Including all additional pages.) $ IMPORTANT: The signatures of the prime and the DBE/HUB and Second Tier Subprovider, if any (both DBE and Non-DBE) and the total commitment amount must always be on the same page. Provider Name: Name: (Please Print) Title: Signature Date Address: Phone # & Fax #: Email: DBE/HUB Sub Provider Name: (Please Print) Title: Signature Date Subprovider Name: VID Number: Address: Phone # & Fax #: Email: Second Tier Sub Provider: Name: (Please Print) Title: Signature Date Subprovider Name: VID Number: Address: Phone #& Fax #: Email: VID Number is the Vendor Identification Number issued by the Comptroller. If a firm does not have a VID Number, please enter the owner’s Social Security or their Federal Employee Identification Number (if incorporated). Contract No. EXHIBIT H-3 Texas Department of Transportation Subprovider Monitoring System for Federally Funded Contracts Progress Assessment Report for month of (Mo./Yr.) / Contract #: Original Contract Amount: Date of Execution: Approved Supplemental Agreements: Prime Provider: Total Contract Amount: Work Authorization No. Work Authorization Amount: If no subproviders are used on this contract, please indicate by placing “N/A” on the 1st line under Subproviders. DBE All Subproviders Category of Work Total Subprovider Amount % Total Contract Amount Amount Paid This Period Amount Paid To Date Subcontract Balance Remaining Fill out Progress Assessment Report with each estimate/invoice submitted, for all subcontracts, and forward as follows: 1 Copy with Invoice - Contract Manager/Managing Office 1 Copy – TxDOT, BOP Office, 120 X. 00xx, Xxxxxx, XX 00000, 000-000-0000, toll free 000-000-0000, or Fax to 000-000-0000 I hereby certify that the above is a true and correct statement of the amounts paid to the firms listed above. Print Name - Company Official /DBE Liaison Officer Signature Phone Date Email Fax Contract No. EXHIBIT H-4 Texas Department of Transportation Subprovider Monitoring System Final Report The Final Report Form should be filled out by the Prime Provider and submitted to the Contract Manager and the Business Opportunity Programs Office for review upon completion of the contract. The report should reflect all subcontract activity on the project. The report will aid in expediting the final estimate for payment. If the HUB or DBE goal requirements were not met, documentation supporting good faith efforts must be submitted. DBE Goal: % OR HUB Goal: % Total Contract Amount: $ Contract Number: Total Contract Amount: $ Vendor ID # Subprovider Total $ Amt Paid to Date TOTAL This is to certify that % of the work was completed by the HUB or DBE subproviders as stated above. By: Prime Provider Per: Signature Subscribed and sworn to before me, this day of , 20 Notary Public County My Commission expires: 12/06 DBE-H4.A Contract No. EXHIBIT H-5 Federal Subprovider and Supplier Information The Provider shall indicate below the name, address and phone number of all successful and unsuccessful subproviders and/or suppliers that provided proposals/quotes for this contract prior to execution. You may reproduce this form if additional space is needed. Name Address Phone Number The information must be provided and returned with the contract. Signature Date Printed Name Email Phone # Contract No. HUB Subcontracting Plan (HSP) Prime Contractor Progress Assessment Report This form must be completed and submitted to the contracting agency each month to document compliance with your HSP. Contract/Requisition Number: Contracting Agency/University Name: Contractor (Company) Name: Point of Contact: Date of Award: Object Code: (mm/dd/yyyy) State of Texas VID #: Phone #: (Agency Use Only) Reporting (Month) Period: Total Amount Paid this Reporting Period to Contractor: $ - Report HUB and Non-HUB subcontractor information *Texas Certified Total Contract $ Total $ Amount Paid Total Contract $ Subcontractor’s VID or HUB HUB? Amount from HSP This Reporting Period to Amount Paid to Date Object Code Subcontractor’s Name Certificate Number (Yes or No) with Subcontractor Subcontractor to Subcontractor (Agency Use Only) $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ TOTALS: $ - $ - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - Signature: Title: Date: *Note: Prime contractors can verify subcontractor HUB certification status on-line at xxxx://xxx0.xxxx.xxxxx.xx.xx/cmbl/cmblhub.html HSP-PAR Rev. 9/05
Repayment of Amounts Advanced for Network Upgrades Upon the Commercial Operation Date, the Interconnection Customer shall be entitled to a repayment, equal to the total amount paid to the Participating TO for the cost of Network Upgrades. Such amount shall include any tax gross-up or other tax-related payments associated with Network Upgrades not refunded to the Interconnection Customer pursuant to Article 5.17.8 or otherwise, and shall be paid to the Interconnection Customer by the Participating TO on a dollar-for-dollar basis either through (1) direct payments made on a levelized basis over the five-year period commencing on the Commercial Operation Date; or (2) any alternative payment schedule that is mutually agreeable to the Interconnection Customer and Participating TO, provided that such amount is paid within five (5) years from the Commercial Operation Date. Notwithstanding the foregoing, if this LGIA terminates within five (5) years from the Commercial Operation Date, the Participating TO’s obligation to pay refunds to the Interconnection Customer shall cease as of the date of termination. Any repayment shall include interest calculated in accordance with the methodology set forth in FERC’s regulations at 18 C.F.R. §35.19a(a)(2)(iii) from the date of any payment for Network Upgrades through the date on which the Interconnection Customer receives a repayment of such payment. Interest shall continue to accrue on the repayment obligation so long as this LGIA is in effect. The Interconnection Customer may assign such repayment rights to any person. If the Large Generating Facility fails to achieve commercial operation, but it or another Generating Facility is later constructed and makes use of the Network Upgrades, the Participating TO shall at that time reimburse Interconnection Customer for the amounts advanced for the Network Upgrades. Before any such reimbursement can occur, the Interconnection Customer, or the entity that ultimately constructs the Generating Facility, if different, is responsible for identifying the entity to which reimbursement must be made.
SUB-CONTRACTORS TO BE UTILIZED FOR PROJECT PSP shall perform the services under this Assignment with its own forces unless otherwise specified. If the scope of services is less than $100,000.00, a HUB Subcontracting Plan (HSP) is not required. If the scope of services will exceed $100,000.00, PSP shall submit an HSP for approval pursuant to Section 11.2 of the Agreement.
Unusual Job Requirements of Short Duration The nature of health care is such that at times it may be necessary for an employee to perform work not normally required in his/her job for the safety, health or comfort of a client or resident. It is understood that an employee shall not be expected to perform a task for which he/she is not adequately trained.
Minimum Condition and Warranty Requirements for TIPS Sales All goods quoted or sold through a TIPS Sale shall be new unless clearly stated otherwise in writing. All new goods and services shall include the applicable manufacturers minimum standard warranty unless otherwise agreed to in the Supplemental Agreement.
Payment Requirements If funding levels are significantly affected by state or federal budget and funds are not allocated and available for the continuance of the function performed by Subrecipient, the Contract may be terminated by the County at the end of the period for which funds are available. The County shall notify Subrecipient at the earliest possible time of any service, which will or may be affected by a shortage of funds. No penalty shall accrue to the County in the event this provision is exercised and the County shall not be obligated nor liable for any damages as a result of termination under this provision of this Contract, and nothing herein shall be construed as obligating the County to expend or as involving the County in any Contract or other obligation for future payment of money in excess of appropriations authorized by law.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
