Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the Delivery Date which the Arbitration Board may deem appropriate. (End of Article)
Appears in 6 contracts
Samples: Construction Contract (Danaos Corp), Construction Contract (Danaos Corp), Construction Contract (Danaos Corp)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the Delivery Date DELIVERY DATE which the Arbitration Board ARBITRATION BOARD may deem appropriate. (End appropriate and/or a determination by the ARBITRATION BOARD as to whether a delay is classified as permissible or non-permissible for the purpose of Article)Article VIII hereof and/or Article V hereof.
Appears in 4 contracts
Samples: Shipbuilding Contract (Quintana Maritime LTD), Shipbuilding Contract (Quintana Maritime LTD), Shipbuilding Contract (Quintana Maritime LTD)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the Delivery Date which the Arbitration Board Arbitrators may deem appropriate. (End of Article).
Appears in 3 contracts
Samples: Ship Sale Contract (Globus Maritime LTD), Ship Sale Contract (Globus Maritime LTD), Ship Sale Contract (Globus Maritime LTD)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSELDRILLSHIP, the award may include any postponement adjustment of the Delivery Date which that the Arbitration Board may deem appropriate. (End of Article).
Appears in 3 contracts
Samples: Construction Contract (DryShips Inc.), Contract for Construction and Sale of a Drillsip (DryShips Inc.), Construction Contract (DryShips Inc.)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement adjustment of the Delivery Date which the Arbitration Board may deem appropriate. (End of Article)
Appears in 2 contracts
Samples: Construction Contract (R&b Falcon Corp), Contract for Construction and Sale of Vessel (R&b Falcon Corp)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSELDRILLS HIP, the award may include any postponement adjustment of the Delivery Date which that the Arbitration Board may deem appropriate. (End of Article).
Appears in 2 contracts
Samples: Construction Contract (DryShips Inc.), Construction Contract (DryShips Inc.)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the Delivery Date Date, which the Arbitration Board may deem appropriate. (End of Article).
Appears in 2 contracts
Samples: Shipbuilding and Construction Agreement (Stolt Nielsen S A), Shipbuilding and Construction Agreement (Stolt Nielsen S A)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the Delivery Date which the Arbitration Board may deem appropriate. (End of Article)) 44
Appears in 1 contract
Samples: Construction Contract
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSELDRILLSHIP, the award may include any postponement adjustment of the Delivery Date which the Arbitration Board may deem appropriate. (End of Article)) ------------------------------------------
Appears in 1 contract
Samples: Contract for Construction and Sale of a Drilling Ship (R&b Falcon Corp)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of the matters occurring prior to delivery of the VESSEL, the award may include any postponement of the Delivery Date DELIVERY DATE which the Arbitration Board ARBITRATION BOARD may deem appropriate. (End of Article).
Appears in 1 contract
