Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the DELIVERY DATE which the ARBITRATION BOARD may deem appropriate and/or a determination by the ARBITRATION BOARD as to whether a delay is classified as permissible or non-permissible for the purpose of Article VIII hereof and/or Article V hereof.
Appears in 4 contracts
Samples: Shipbuilding Contract (Quintana Maritime LTD), Shipbuilding Contract (Quintana Maritime LTD), Shipbuilding Contract (Quintana Maritime LTD)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the DELIVERY DATE Delivery Date which the ARBITRATION BOARD Arbitrators may deem appropriate and/or a determination by the ARBITRATION BOARD as to whether a delay is classified as permissible or non-permissible for the purpose appropriate. (End of Article VIII hereof and/or Article V hereof.Article)
Appears in 3 contracts
Samples: Shipsale Contract (Globus Maritime LTD), Shipsale Contract (Globus Maritime LTD), Shipsale Contract (Globus Maritime LTD)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSELDRILLSHIP, the award may include any postponement adjustment of the DELIVERY DATE which Delivery Date that the ARBITRATION BOARD Arbitration Board may deem appropriate and/or a determination by the ARBITRATION BOARD as to whether a delay is classified as permissible or non-permissible for the purpose appropriate. (End of Article VIII hereof and/or Article V hereof.Article)
Appears in 3 contracts
Samples: Construction and Sale (DryShips Inc.), Contract (DryShips Inc.), Construction and Sale (DryShips Inc.)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement adjustment of the DELIVERY DATE Delivery Date which the ARBITRATION BOARD Arbitration Board may deem appropriate and/or a determination by the ARBITRATION BOARD as to whether a delay is classified as permissible or non-permissible for the purpose appropriate. (End of Article VIII hereof and/or Article V hereof.Article)
Appears in 2 contracts
Samples: R&b Falcon Corp, R&b Falcon Corp
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the DELIVERY DATE Delivery Date, which the ARBITRATION BOARD Arbitration Board may deem appropriate and/or a determination by the ARBITRATION BOARD as to whether a delay is classified as permissible or non-permissible for the purpose appropriate. (End of Article VIII hereof and/or Article V hereof.Article)
Appears in 2 contracts
Samples: Stolt Nielsen S A, Stolt Nielsen S A
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the DELIVERY DATE Delivery Date which the ARBITRATION BOARD Arbitration Board may deem appropriate and/or a determination by the ARBITRATION BOARD as to whether a delay is classified as permissible or non-permissible for the purpose appropriate. (End of Article VIII hereof and/or Article V hereof.Article) 44
Appears in 1 contract
Samples: www.dieselduck.info
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of the matters occurring prior to delivery of the VESSEL, the award may include any postponement of the DELIVERY DATE which the ARBITRATION BOARD may deem appropriate and/or a determination by the ARBITRATION BOARD as to whether a delay is classified as permissible or non-permissible for the purpose appropriate. (End of Article VIII hereof and/or Article V hereof.Article)
Appears in 1 contract