ALTERATION OF THE CONSTITUTION Sample Clauses

ALTERATION OF THE CONSTITUTION. The Commonwealth will take the necessary action to submit to the Parliament of the Commonwealth and to the electors proposals for the alteration of the Constitution of the Commonwealth in the following form: — (1) The Commonwealth may make agreements with the States with respect to the public debts of the States, including — (a) the taking over of such debts by the Commonwealth; (b) the management of such debts; (c) the payment of interest and the provision and management of sinking funds in respect of such debts; (d) the consolidation, renewal, conversion, and redemption of such debts; (e) the indemnification of the Commonwealth by the States in respect of debts taken over by the Commonwealth; and (f) the borrowing of money by the States or by the Commonwealth or by the Commonwealth for the States. (2) The Parliament may make laws for validating any such agreement made before the commencement of this section. (3) The Parliament may make laws for the carrying out by the parties thereto of any such agreement. (4) Any such agreement may be varied or rescinded by the parties thereto. (5) Every such agreement and any such variation thereof shall be binding upon the Commonwealth and the States parties thereto, notwithstanding anything contained in this Constitution or the constitution of the several States or in any law of the Parliament of the Commonwealth or of any State. (6) The powers conferred by this section shall not be construed as being limited in any way by the provisions of section 105 of this Constitution.”
AutoNDA by SimpleDocs
ALTERATION OF THE CONSTITUTION. Alterations to the Constitution of the Committee can be made at any meeting convened in accordance with Section 5 above, in accordance with the other provisions of this Constitution.

Related to ALTERATION OF THE CONSTITUTION

  • Governing Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the laws of the State of New York. The section headings in this Agreement have been inserted as a matter of convenience of reference and are not a part of this Agreement.

  • Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Certain Matters of Construction The terms “herein,” “hereof,” “hereunder” and other words of similar import refer to this Agreement as a whole and not to any particular section, paragraph or subdivision. Any pronoun used shall be deemed to cover all genders. In the computation of periods of time from a specified date to a later specified date, “from” means “from and including,” and “to” and “until” each mean “to but excluding.” The terms “including” and “include” shall mean “including, without limitation” and, for purposes of each Loan Document, the parties agree that the rule of ejusdem generis shall not be applicable to limit any provision. Section titles appear as a matter of convenience only and shall not affect the interpretation of any Loan Document. All references to (a) laws or statutes include all related rules, regulations, interpretations, amendments and successor provisions; (b) any document, instrument or agreement include any amendments, waivers and other modifications, extensions or renewals (to the extent permitted by the Loan Documents); (c) any section mean, unless the context otherwise requires, a section of this Agreement; (d) any exhibits or schedules mean, unless the context otherwise requires, exhibits and schedules attached hereto, which are hereby incorporated by reference; (e) any Person include successors and assigns; (f) time of day mean time of day at Lenders’ notice addresses under Section 13.3.1; or (g) discretion of any Lender mean the sole and absolute discretion of such Person. All calculations of fundings of the Loans, and payments of Obligations shall be in Dollars and, unless the context otherwise requires, all determinations made from time to time under the Loan Documents shall be made in light of the circumstances existing at such time. Borrowers shall have the burden of establishing any alleged negligence, misconduct or lack of good faith by any Lender under any Loan Documents. No provision of any Loan Documents shall be construed against any party by reason of such party having, or being deemed to have, drafted the provision.

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

  • ICIF Construction The ICIF shall be designed and constructed in accordance with Good Utility Practice. Within one hundred twenty (120) Calendar Days after the Commercial Operation Date, unless the Parties agree on another mutually acceptable deadline, Interconnection Customer shall deliver to Transmission Provider and Transmission Owner “as-built” drawings, information and documents for the ICIF, such as: a one-line diagram, a site plan showing the Generating Facility and the ICIF, plan and elevation drawings showing the layout of the ICIF, a relay functional diagram, relaying AC and DC schematic wiring diagrams and relay settings for all facilities associated with the Interconnection Customer’s step-up transformers, the facilities connecting the Generating Facility to the step-up transformers and the ICIF, and the impedances (determined by factory tests) for the associated step-up transformers and the Generating Facility. Interconnection Customer shall provide Transmission Provider and Transmission Owner with Interconnection Customer’s specifications for the excitation system, automatic voltage regulator, Generating Facility control and protection settings, transformer tap settings, and communications, if applicable.

  • Construction; Governing Law The headings used in this Agreement are for convenience only and shall not be deemed to constitute a part hereof. Whenever the context requires, words denoting singular shall be read to include the plural. This Agreement and the rights and obligations of the parties hereunder, shall be construed and interpreted in accordance with the laws of the State of Kansas, except to the extent that the laws of the State of Maryland apply with respect to share transactions.

  • FAIR CONSTRUCTION & INTERPRETATION The provisions of this Master Contract shall be construed as a whole according to their common meaning and not strictly for or against any party and consistent with the provisions contained herein in order to achieve the objectives and purposes of this Master Contract. Each party hereto and its counsel has reviewed and revised this Master Contract and agrees that the normal rules of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be construed in the interpretation of this Master Contract. Each term and provision of this Master Contract to be performed by either party shall be construed to be both a covenant and a condition.

  • LAW GOVERNING THIS AGREEMENT This Agreement shall be governed by and construed in accordance with the laws of the State of Nevada without regard to principles of conflicts of laws. Any action brought by either party against the other concerning the transactions contemplated by this Agreement shall be brought only in the state or federal courts located in New York City, New York. The parties to this Agreement hereby irrevocably waive any objection to jurisdiction and venue of any action instituted hereunder and shall not assert any defense based on lack of jurisdiction or venue or based upon forum non conveniens. The parties executing this Agreement and other agreements referred to herein or delivered in connection herewith on behalf of the Company agree to submit to the in personam jurisdiction of such courts and hereby irrevocably waive trial by jury. The prevailing party shall be entitled to recover from the other party its reasonable attorney’s fees and costs. In the event that any provision of this Agreement or any other agreement delivered in connection herewith is invalid or unenforceable under any applicable statute or rule of law, then such provision shall be deemed inoperative to the extent that it may conflict therewith and shall be deemed modified to conform with such statute or rule of law. Any such provision which may prove invalid or unenforceable under any law shall not affect the validity or enforceability of any other provision of any agreement. Each party hereby irrevocably waives personal service of process and consents to process being served in any suit, action or proceeding in connection with this Agreement or any other Registered Offering Transaction Documents by mailing a copy thereof via registered or certified mail or overnight delivery (with evidence of delivery) to such party at the address in effect for notices to it under this Agreement and agrees that such service shall constitute good and sufficient service of process and notice thereof. Nothing contained herein shall be deemed to limit in any way any right to serve process in any other manner permitted by law.

  • DAF Construction The DAF shall be designed and constructed in accordance with Good Utility Practice. Within one hundred twenty (120) Calendar Days after the Commercial Operation Date, unless the Developer and Connecting Transmission Owner agree on another mutually acceptable deadline, the Developer shall deliver to the Connecting Transmission Owner and NYISO “as- built” drawings, information and documents for the DAF, such as: a one-line diagram, a site plan showing the Large Generating Facility and the DAF, plan and elevation drawings showing the layout of the DAF, a relay functional diagram, relaying AC and DC schematic wiring diagrams and relay settings for all facilities associated with the Developer’s step-up transformers, the facilities connecting the Large Generating Facility to the step-up transformers and the DAF, and the impedances (determined by factory tests) for the associated step-up transformers and the Large Generating Facility. The Developer shall provide to, and coordinate with, Connecting Transmission Owner and NYISO with respect to proposed specifications for the excitation system, automatic voltage regulator, Large Generating Facility control and protection settings, transformer tap settings, and communications, if applicable.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!