PRICING for Markup of Non-Prepriced Items in RS Means Unit Price Book What is your proposed Markup Percentage on materials not found in the RS Means Price Book? If any materials being utilized for a project cannot be found in the RS Means Price Book, this question is what is the markup percentage on those materials? When answering this question please insert the number that represents your percentage of proposed markup. Example: if you are proposing a 30 percent markup, please insert the number "30". Remember that this is a ceiling markup. You may markup a lesser percentage to the TIPS Member customer when pricing the project, but not a greater percentage. EXAMPLE: You need special materials that are not in the RS Means Unit Price Book for a project. You would buy the materials and mark them up to the TIPS Member customer by the percentage you propose in this question. If the materials cost you, the contractor, $100 and you proposed a markup on this question for the material of 30 percent, then you would charge the TIPS Member customer $130 for the materials.
Calculation methodology No adjustment in the Conversion Price need be made unless the adjustment would require an increase or decrease of at least 1% in the Conversion Price then in effect, provided that any adjustment that would otherwise be required to be made shall be carried forward and taken into account in any subsequent adjustment. Except as stated in this Article VI, the Conversion Rate will not be adjusted for the issuance of Common Stock or any securities convertible into or exchangeable for Common Stock or carrying the right to purchase any of the foregoing. Any adjustments that are made shall be carried forward and taken into account in any subsequent adjustment. All calculations under Article V and Section 6.06 hereof and this Section 6.07 shall be made to the nearest cent or to the nearest 1/10,000th of a share, as the case may be.
Non pre-priced Adjustment Factor To be applied to Work deemed not to be included in the CTC but within the general scope of the work:
Payment Methodology The Contractor shall be compensated based on the Service Rates in Attachment for units of service authorized by the Institution in a total amount not to exceed the Contract Maximum Liability established in Section C.1. The Contractor’s compensation shall be contingent upon the satisfactory completion of units of service or project milestones identified in Attachment B. The Contractor shall submit invoices, in form and substance acceptable to the Institution with all of the necessary supporting documentation, prior to any payment. Such invoices shall be submitted for completed units of service or project milestones for the amount stipulated.
Calculation of Unit Prices Unit Prices include all sums for payment, repayment, reimbursement, remittance, remuneration, compensation, profit, cost, overhead, expense, loss, expenditure, allowance, charge, demand, hire, wages, salary, tax, cash, assessment, price, money, xxxx, statement, dues, recovery, restitution, benefit, recoupment, exaction, or injury. Unit prices to cover the addition or reinstallation of stormwater management BMPs shall be calculated by type and linear foot. Unit Prices shall not include any Time Dependent Overhead Costs, as such costs will be added as appropriate pursuant to Section 3, Part 3. The Contractor shall certify that the Unit Prices submitted do not exceed current costs in the industry or trade for like services or materials.
Rate Redetermination for Market Change In the event of delay or interruption, exceeding 90 days, under B8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to B3.31, using remaining volumes. Tentative Rates and Flat Rates in effect at the time of delay or interruption or established pursuant to B3.31 will be reduced, if appraised rates declined during the delay or interruption, to become Current Contract Rates. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates shall be considered established under B3.1 for timber Scaled subsequent to the delay or interruption.
GSA Benchmarked Pricing Additionally, where the NYS Net Price is based upon an approved GSA Supply Schedule:
Rental Rates and Wage Rates for Change Orders As soon as is practical, but prior to the completion of the Construction Preparation Period and in any event prior to the commencement of any Work on the Site, the Contractor shall submit in accordance with the style and format of a specimen to be furnished by the Owner for consideration of the Owner the following: (1) a proposal for rental rates on heavy construction equipment that shall apply in the event Change Order Work is performed, and (2) a proposal for wage rates for the types of project labor that shall apply in the event of the execution of any Change Order Work. Under penalty of false swearing, a principal of the contracting firm shall certify that the proposal for rental rates and proposal for wage rates do not exceed current costs for like services. The Owner will in no event consider a rental rate in excess of eighty percent of the rate set forth in the latest edition of the "Compilation of Nationally Averaged Rental Rates for Construction Equipment" of the Associated Equipment Distributors unless the rates proposed in excess of eighty percent are supported by proof satisfactory to the Owner that the excess rates are reasonable. If the equipment is owned by the Contractor the costs shall be charged at a maximum of eighty percent of market monthly rental rates for the amount of time used. If applicable, transportation costs may be included. The decision of the Owner shall be final, binding and conclusive on all parties. Rental rates shall be payable only for the actual time the equipment is required on the Site.
Alternative Tenders 12.1 Unless otherwise specified in the TDS, alternative Tenders shall not be considered.
ECONOMIC PRICE ADJUSTMENT is the adjustment to the Aircraft Basic Price (Base Airframe, Engine and Special Features) as calculated pursuant to Exhibit D.
