Common use of Approval by Landlord Clause in Contracts

Approval by Landlord. Tenant's Plans shall be subject to Landlord's approval, which approval shall not be unreasonably withheld or delayed. Landlord shall be entitled to withhold approval if the proposed plans and specifications (i) interfere with the structural integrity of the Buildings, (ii) overload the utility systems of the Buildings, (iii) violate any applicable laws or regulations, (iv) materially affect the architectural integrity of the Buildings, or (v) affect the future marketability of the Buildings. If Landlord disapproves of any of Tenant's Plans, Landlord shall advise Tenant in reasonable detail of required revisions and the reasons therefor. After being so advised by Landlord, Tenant shall promptly submit a redesign, incorporating the revisions required by Landlord, for Landlord's approval. If Tenant has reason to dispute any Landlord disapproval, then the parties shall meet within 5 days and attempt to resolve the dispute. If the Parties are unable to resolve their differences as to Tenant's Preliminary Plans within 5 days after meeting, then either party may initiate an arbitration procedure by notifying the other Party of the need to submit their disagreements to binding and final arbitration by a mutually acceptable arbitrator with at least ten (10) years commercial office design experience. If the parties are unable to agree on the arbitrator within a period of ten (10) days of notice, then either party may request resolution by a single arbitrator before the American Arbitration Association, as set forth at the end of Lease Section 21.

Approval by Landlord. Tenant's ’s Plans shall be subject to Landlord's ’s approval, which approval shall not be unreasonably withheld or delayed. Landlord shall be entitled to withhold approval if the proposed plans and specifications specifications (i) interfere with the structural integrity of the Buildings, (ii) overload the utility systems of the Buildings, (iii) violate any applicable laws or regulations, (iv) materially affect the architectural integrity of the Buildings, or (v) affect the future marketability of the Buildings. If Landlord disapproves of any of Tenant's ’s Plans, Landlord shall advise Tenant in reasonable detail of required revisions and the reasons therefor. After being so advised by Landlord, Tenant shall promptly submit a redesign, incorporating the revisions required by Landlord, for Landlord's ’s approval. If Tenant has reason to dispute any Landlord disapproval, then the parties shall meet within 5 days and attempt to resolve the dispute. If the Parties are unable to resolve their differences as to Tenant's ’s Preliminary Plans within 5 days after meeting, then either party may initiate an arbitration procedure by notifying the other Party of the need to submit their disagreements to binding and final arbitration by a mutually acceptable arbitrator with at least ten (10) years commercial office design experience. If the parties are unable to agree on the arbitrator within a period of ten (10) days of notice, then either party may request resolution by a single arbitrator before the American Arbitration Association, as set forth at the end of Lease Section 21. If after Landlord has approved Tenant’s Plans, Tenant shall request any change, addition or alteration in the Tenant’s Plans, then Tenant shall promptly give Landlord a written description of the changes requested and submit to Landlord the revised plans. Landlord shall review such revised plans in accordance with the plan approval process described in this Section III.A.4.

Approval by Landlord. Tenant's Plans shall be subject to Landlord's approval, which approval shall not be unreasonably withheld withheld, conditioned or delayed. Landlord shall be entitled to withhold approval if the proposed plans and specifications (i) interfere with the structural integrity of the BuildingsBuilding, (ii) overload the utility systems of the BuildingsBuilding, (iii) violate any applicable laws or regulations, or (iv) materially affect the architectural integrity of the Buildings, or (v) affect the future marketability of the BuildingsBuilding. If Landlord disapproves of any of Tenant's Plans, Landlord shall advise Tenant in reasonable detail of required revisions and the reasons therefor. After being so advised by Landlord, Tenant shall promptly submit a redesign, incorporating the revisions required by Landlord, for Landlord's approval. If Tenant has reason to dispute any Landlord disapproval, then the parties shall meet within 5 days and attempt to resolve the dispute. If the Parties are unable to resolve their differences as to Tenant's Preliminary Plans within 5 days after meeting, then either party may initiate an arbitration procedure by notifying the other Party of the need to submit their disagreements to binding and final arbitration by a mutually acceptable arbitrator with at least ten (10) years commercial office design experience. If the parties are unable to agree on the arbitrator within a period of ten often (10) days of notice, then either party may request resolution by a single arbitrator before the American Arbitration Association, as set forth at the end of Lease Section 213(c).

Approval by Landlord. Tenant's Plans shall be subject to Landlord's approval, which approval shall not be unreasonably withheld withheld, conditioned or delayed. Landlord shall be entitled to withhold approval if the proposed plans and specifications (i) interfere with the structural integrity of the BuildingsBuilding, (ii) overload the utility systems of the BuildingsBuilding, (iii) violate any applicable laws or regulations, or (iv) materially affect the architectural integrity of the Buildings, or (v) affect the future marketability of the BuildingsBuilding. If Landlord disapproves of any of Tenant's Plans, Landlord shall advise Tenant in reasonable detail of required revisions and the reasons therefor. After being so advised by Landlord, Tenant shall promptly submit a redesign, incorporating the revisions required by Landlord, for Landlord's approval. If Tenant Xxxxxx has reason to dispute any Landlord disapproval, then the parties shall meet within 5 days and attempt to resolve the dispute. If the Parties are unable to resolve their differences as to TenantXxxxxx's Preliminary Plans within 5 days after meeting, then either party may initiate an arbitration procedure by notifying the other Party of the need to submit their disagreements to binding and final arbitration by a mutually acceptable arbitrator with at least ten (10) years commercial office design experience. If the parties are unable to agree on the arbitrator within a period of ten often (10) days of notice, then either party may request resolution by a single arbitrator before the American Arbitration Association, as set forth at the end of Lease Section 213(c).