Approval of Contractors, Subcontractors, and Materialmen Sample Clauses

Approval of Contractors, Subcontractors, and Materialmen. Lender shall have approved a list of all contractors employed in connection with the construction of the Tenant Improvements for the Project, showing the name, address, and telephone number of each contractor, a general description of the nature of the work to be done, the labor and materials to be supplied, the names of materialmen, if known, and the approximate dollar value of the labor, work, or materials with respect to each contractor or materialman. Lender shall have the right to communicate with any person to verify the facts disclosed by the list or by any application for any Advance, or for any other purpose.
Sample 1
AutoNDA by SimpleDocs
Approval of Contractors, Subcontractors, and Materialmen. Majority Owner shall have approved the General Contractor and a list of all contractors employed in connection with the construction of the Improvements, showing the name, address, and telephone number of each contractor, a general description of the nature of the work to be done, and labor and materials to be supplied, the names of materialmen, if known, and the approximate dollar value of the labor, work, or materials with respect to each contractor or materialmen. Majority Owner shall have the right to communicate with any person to verify the facts disclosed by the list or by any application for any Advance, or for any other purpose.
Sample 1
Approval of Contractors, Subcontractors, and Materialmen. Lender shall have approved a list of all contractors employed in connection with the construction of the Tenant Improvements or Capital Expenditures, as applicable, for the Project, showing the name, address, and telephone number of each contractor, a general description of the nature of the work to be done, the labor and materials to be supplied, the names of materialmen, if known, and the approximate dollar value of the labor, work, or materials with respect to each contractor or materialman. Lender shall have the right to communicate with any person to verify the facts disclosed by the list or by any application for any Advance, or for any other purpose.
Sample 1

Related to Approval of Contractors, Subcontractors, and Materialmen

  • Subcontractors The Contractor will not subcontract any work under the Contract without prior written consent of the Department. The Contractor is fully responsible for satisfactory completion of all its subcontracted work. The Department supports diversity in its procurements and contracts, and requests that the Contractor offer subcontracting opportunities to certified woman-, veteran-, and minority-owned small businesses. The Contractor may contact the OSD at xxxxxxx@xxx.xxxxxxxxx.xxx for information on certified small business enterprises available for subcontracting opportunities.

  • Third Party Contractors Tenant shall obtain and deliver to Landlord, Third Party Contractor’s certificates of insurance and applicable endorsements at least seven (7) business days prior to the commencement of work in or about the Premises by any vendor or any other third-party contractor (collectively, a “Third Party Contractor”). All such insurance shall (a) name Landlord as an additional insured under such party’s liability policies as required by Section 10.3.1 above and this Section 10.6, (b) provide a waiver of subrogation in favor of Landlord under such Third Party Contractor’s commercial general liability insurance, (c) be primary and any insurance carried by Landlord shall be excess and non-contributing, and (d) comply with Landlord’s minimum insurance requirements.

  • Contractors All LAUSD Contractors and their Representatives are expected to conduct any and all business affiliated with LAUSD in an ethical and responsible manner that fosters integrity and public confidence. A “Contractor” is any individual, organization, corporation, sole proprietorship, partnership, nonprofit, joint venture, association, or any combination thereof that is pursuing or conducting business with and/or on behalf of LAUSD, including, without limitation, consultants, suppliers, manufacturers, and any other vendors, bidders or proposers. A Contractor’s “Representative” is also broadly defined to include any subcontractors, employees, agents, or anyone else who acts on a Contractor’s behalf.

  • Subcontractor Any vendor, subcontractor or other Person that is not responsible for the overall servicing (as “servicing” is commonly understood by participants in the mortgage-backed securities market) of Mortgage Loans but performs one or more discrete functions identified in Item 1122(d) of Regulation AB with respect to Mortgage Loans under the direction or authority of the Servicer or a Subservicer.

  • Sub-contractors Transfer Agent may, without further consent on the part of Customer, subcontract with other subcontractors for telephone and mailing services as may be required from time to time; provided, however, that the Transfer Agent shall be as fully responsible to the Customer for the acts and omissions of any subcontractor as it is for its own acts and omissions.

  • Contractor If COUNTY elects to renegotiate this Agreement due to reduced or terminated 20 funding, CONTRACTOR shall not be obligated to accept the renegotiated terms.

  • Subcontractors and Unaffiliated Third Parties (a) The Escrow Agent may, without further consent of any party hereto, subcontract with (i) any of its affiliates, or (ii) unaffiliated subcontractors for such services as may be required from time to time (e.g., lost stockholder searches, escheatment, telephone and mailing services); provided, however, that the Escrow Agent (i) shall be fully responsible for the acts and omissions of its affiliate as it is for its own acts and omissions and (ii) shall not be liable for the acts and omissions of any subcontractor absent willful misconduct, bad faith or gross negligence of the Escrow Agent in the selection of such subcontractor (each as determined by a final, non-appealable judgment of a court of competent jurisdiction).

  • Architects, Consultants and Contractors Landlord and Tenant hereby acknowledge and agree that: (i) the general contractor and any subcontractors for the Tenant Improvements shall be selected by Landlord, subject to Tenant’s approval, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) DGA shall be the architect (the “TI Architect”) for the Tenant Improvements.

  • Independent Contractor; Authority Notwithstanding the Services provided by the Administrator pursuant to this Agreement, the Administrator shall be deemed to be an independent contractor with respect to the Services. The management, policies and operations of the Parties (including the ultimate approval of the making or disposition of the Painting by the Issuer or Masterworks Cayman, and the terms and conditions thereof) shall be the responsibility of the Parties other than the Administrator.

Time is Money Join Law Insider Premium to draft better contracts faster.