Authorised use of the Assets Sample Clauses

Open Split View

Download

Share

Cite

Authorised use of the Assets. The Assets shall be used by the Lessee in connection with the Project (the “Authorised Activities”).

Sample 1

Save

Copy

Related to Authorised use of the Assets

• Authorised Users individuals who are authorised by the Institution to access the Institution's information services whether on-site or off-site via Secure Authentication and who are affiliated to the Institution as a current student (including but not limited to undergraduates, postgraduates and guest students), member of staff (whether on a permanent or temporary basis including retired members of staff and any teacher who teaches Authorised Users) or contractor or registered user of the Institution. Persons who are not currently a student, member of staff, contractor or registered user of the Institution, but who are permitted to access the Institution's information services from computer terminals or otherwise within the physical premises of the Institution ["Walk-In Users"] are also deemed to be Authorised Users, only for the time they are within the physical premises of the Institution.

• Unauthorised Use of Intellectual Property a) The Supplier/Service Provider agrees to notify Transnet in writing of any conflicting uses of, and applications of registrations of Patents, Designs and Trade Marks or any act of infringement, unfair competition or passing off involving the Intellectual Property of Transnet of which the Supplier/Service Provider acquires knowledge and Transnet shall have the right, as its own option, to proceed against any party infringing its Intellectual Property. b) It shall be within the sole and absolute discretion of Transnet to determine what steps shall be taken against the infringer and the Supplier/Service Provider shall co-operate fully with Transnet, at Transnet’s cost, in whatever measure including legal action to bring any infringement of illegal use to an end. c) The Supplier/Service Provider shall cooperate to provide Transnet promptly with all relevant ascertainable facts. d) If proceedings are commenced by Transnet alone, Transnet shall be responsible for all expenses but shall be entitled to all damages or other awards arising out of such proceedings. If proceedings are commenced by both Parties, both Parties will be responsible for the expenses and both Parties shall be entitled to damages or other awards arising out of proceedings.

• Use of the Equipment 9.1 The Equipment shall be used by Hospital only at the Site and shall not be removed therefrom. Hospital shall use the Equipment only in the regular and ordinary course of Hospital's business operations and only within the capacity of the Equipment as determined by Elekta's specifications. Hospital shall not use nor permit the Equipment to be used in any manner nor for any purpose which, in the opinion of Elekta or GKF, the Equipment is not designed or reasonably suitable. 9.2 This is an agreement of lease only. Nothing herein shall be construed as conveying to Hospital any right, title or interest in or to the Equipment, except for the express leasehold interest granted to Hospital for the Term. All Equipment shall remain personal property (even though said Equipment may hereafter become attached or affixed to real property) and the title thereto shall at all times remain exclusively in GKF. 9.3 During the Term, upon the request of GKF, Hospital shall promptly affix to the Equipment in a prominent place, or as otherwise directed by GKF, labels, plates, insignia, lettering or other markings supplied by GKF indicating GKF's ownership of the Equipment, and shall keep the same affixed for the entire Term. Hospital hereby authorizes GKF to cause this Lease or any statement or other instrument showing the interest of GKF in the Equipment to be filed or recorded, or refiled or re-recorded, with all governmental agencies considered appropriate by GKF, at Hospital's cost and expense. Hospital also shall promptly execute and deliver, or cause to be executed and delivered, to GKF any statement or instrument requested by GKF for the purpose of evidencing GKF's interest in the Equipment, including financing statements and waivers with respect to rights in the Equipment from any owners or mortgagees of any real estate where the Equipment may be located. 9.4 At Hospital's cost and expense, Hospital shall (a) protect and defend GKF's ownership of and title to the Equipment from and against all persons claiming against or through Hospital, (b) at all times keep the Equipment free from any and all liens, encumbrances, attachments, levies, executions, burdens, charges or legal processes imposed against Hospital, (c) give GKF immediate written notice of any matter described in clause (b), and (d) in the manner described in Section 22 below indemnify GKF harmless from and against any loss, cost or expense (including reasonable attorneys' fees) with respect to any of the foregoing.

• Unauthorised use We shall not be liable for any loss, liability or cost whatsoever arising from any unauthorised use of the Electronic Service. You shall on demand indemnify, protect and hold us harmless from and against all losses, liabilities, judgements, suits, actions, proceedings, claims, damages and costs resulting from or arising out of any act or omission by any person using an Electronic Service by using your designated passwords, whether or not you authorised such use.

• Contracts Concerning Use of Project The Recipient agrees that during the Agreement Term it will not contract with any Private Person for use of the Project or any portion thereof or the facility or facilities of which the Project is a part for any Private Business Use unless all of the conditions of subparagraph F.3.a., subparagraph F.3.b. or subparagraph F.3.c. are met: a. If the compensation of the Private Person is based entirely on a periodic, fixed fee that contains no incentive adjustments, all of the following conditions must be met: (A) no amount of compensation is based on a share of the net profits; (B) the compensation is reasonable; (C) the term of the contract does not exceed five (5) years (including any renewal option periods provided for in the contract);

• POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.

• Use of the Property The Tenant agrees with the Landlord as follows:- 3.1 To use the Room or Studio (as applicable) only as a single private residence for occupation by the Tenant personally and not to allow visitors to remain in the Room or in the Flat or Studio (as applicable) overnight unless the Tenant has registered the visitor at reception and obtained the Landlord’s consent to the visitor remaining in the Room or the Flat or Studio (as applicable) overnight such consent not to be unreasonably withheld or delayed provided that no overcrowding occurs and (where applicable) the other occupiers of the Flat do not raise any objection 3.2 The Tenant shall not: 3.2.1 use the Room Studio Flat or Building for the purposes of conducting a business 3.2.2 keep any pets or other animals on or in the Room Studio Flat or Building without the prior written consent of the Landlord 3.2.3 play or use any musical instrument or television radio or other means of reproducing sound so that the sound is audible outside the Room Flat Studio or Building 3.2.4 connect to the telephone line the internet or any other systems 3.2.5 store bicycles in the Room Flat Studio or Building but to store any bicycle in the designated bicycle areas of the Building only and in the event of the Landlord removing any bicycle stored in breach of this clause to pay to the Landlord within 7 days of written demand £25 before the release of the bicycle to the Tenant 3.2.6 store or keep or use any unlawful substance or materials in the Room Flat Studio or Building at any time and to report to the Landlord or any of its employees the presence of any such unlawful substance or materials 3.2.7 keep store or use in the Room Flat Studio or Building any inflammable or dangerous articles, any lighted candles electronic cigarettes incense sticks shisha pipes naked flame appliances portable heater lamp or other portable apparatus fed by paraffin or liquid gas and to comply with all of the Landlord’s requirements relating to fire safety as set out in the Fire Safety Agreement which is available for inspection at the relevant onsite management reception 3.2.8 keep or use in the Room Flat Studio or Building any electrical heating and/or electrical cooking equipment and/or multiway adaptors; 3.2.9 bring into or keep in the Room Flat Studio or Building any other electrical items (“the Items”) unless the Tenant has first produced by prior appointment the Items to the Landlord’s officer in the relevant onsite management reception for Portable Appliance Testing (“XXX”) and thereafter obtained the approval of the Landlord to the keeping and using of the Items in the Room or the Flat or Studio, ( as applicable) which approval will be given if the Items are in good safe working order and meet the XXX requirements 3.2.10 expose or allow to be hung any laundry washing or other items so as to be visible from outside of the Room Flat Studio or Building and not to dry clothes on the storage heaters 3.2.11 not to bring into or keep in the Room Flat Studio or Building any washing machine 3.2.12 glue stick nail tack screw fix or fasten (whether with Blue-Tack or similar materials) anything whatsoever to the interior or the exterior of the Room Flat Studio or Building 3.2.13 smoke (including electronic cigarettes) or use non-prescription drugs within the Room Flat Studio or Building 3.2.14 part with the keys or access fob to the Room Flat Studio or Building and to report immediately any loss of the same to the Landlord and to pay to the Landlord before the Landlord issues any replacements the sum of £20 for each replacement key and £15 for each replacement access fob (and if a key or access fob is found and returned by the student after a replacement has been issued and the cost charged, the refund of the cost is at the Landlord’s discretion and in any event an administrative fee may be charged.) 3.2.15 damage or force or in any way misuse any locks in the Room Flat Studio or Building and in the event of default to pay to the Landlord on demand all reasonable costs (including an additional administration charge) reasonably incurred by the Landlord in replacing the same and/or making good all damage caused 3.2.16 connect to or trail wires from the telephone apparatus and/or any television in the Room Flat Studio or Building to protect the health and safety of the Tenant and (where applicable) the occupiers of the Building 3.2.17 tamper with any fire safety equipment in the Room Flat Studio or Building including without limitation fire extinguishers, smoke alarms, emergency exit signs and break glass alarm points 3.2.18 cause a nuisance annoyance or interference or threaten or abuse any other residents in the Building any employees servants or agents of the Landlord or the owners and occupiers of neighbouring, adjoining or adjacent property or the owners of occupiers of them; 3.2.19 do anything that has the effect of invalidating the insurance that the Landlord has taken out in relation to the Building 3.2.20 use the Room or the Flat or the Studio for immoral or illegal purposes or otherwise commit or be involved in any criminal activity 3.3 The Tenant agrees to: 3.3.1 where applicable, open the windows in the Room or the Studio to the tilt position for at least 30 minutes each day (provided that the Tenant is in occupation) to ventilate the Room or Studio and not to open the windows in the Room beyond the tilt position save in emergencies. 3.3.2 always to use the extractor fan in the bathroom when using the bathroom and not to disable the extractor fan except for safety reasons in an emergency 3.3.3 use best endeavours to ensure that the Tenant’s visitors comply with the Tenant’s obligations under this Agreement while present in the Room Flat Studio or the Building 3.3.4 comply with additional obligations or restrictions set out in any management scheme or other regulations reasonably required by the Landlord which may be notified to the Tenant in writing from time to time. 3.4 Unless otherwise expressly provided, the obligations and liabilities of the Tenant under this agreement are joint and several. This means that where, there is more than one tenant of the Studio Flat or the Building the Tenant will be liable for all sums due under the agreement, not just liable for a proportionate part.

• Use of Equipment mechanical failure of the equipment; negligent design or manufacture of the equipment; the provision of or the failure by the Organization to provide any warnings, directions, instructions or guidance as to the use of the equipment; failure to use or operate the equipment within my own ability.

• Use of Facilities and Equipment The Association shall have the right to use school facilities and equipment not otherwise in use. Such equipment shall not be removed from the building without permission of the building principal. The individual using the equipment shall be responsible for repair or replacement costs beyond normal wear and tear if the equipment is damaged, stolen, or lost. The Association shall pay for the reasonable cost of all materials and supplies incident to such use. The Association may use school buildings for meetings by arranging such use with the building principals.

• POSSESSION OF THE APARTMENT PLOT 8.1 Schedule for possession of the said Apartment: The Promoter agrees and understands that timely delivery of possession of the Apartment to the Allottee and the Common Areas to the Association of the Allottees , is the essence of the Agreement. Provided that the Promoter shall be entitled to reasonable extension of time as agreed by and between the Allottee and the Promoter for giving possession of the Apartment on the aforesaid date and the same shall not include the period of extension given by the Authority for registration. The Promoter, based on the approved plans and specifications, assures to hand over possession of the Apartment on …………,with a grace period of twelve months (Completion date) in case the Promoter fails to complete the Project. unless there is a delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity or order, rule, notification of the Government and/or other public or competent authority/court and/or caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, Provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. Promoter will be entitled to give block-wise and phase-wise possession upon obtaining the Completion Certificate/ Partial Completion Certificate of a building block or a particular phase as the case may be irrespective of the fact that construction of other Blocks and/or other phases and/or provision of facilities may be incomplete. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 45 days from that date.After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement. It is clarified that all amounts collected as taxes, charges, levies, cess, assessments and impositions and deposited with the appropriate authorities concerned shall not be returned by the Promoter and the Allottee shall be free to approach the authorities concerned for refund of such taxes, charges, levies, cess, assessments and impositions. 8.2 The right of the Allottee shall remain restricted to the respective Apartment and the properties appurtenant thereto and the Allottee shall have no right, title or interest nor shall claim any right, title or interest of any kind whatsoever over and in respect of any other Apartment or space and/or any other portions of the Project or Complex. 8.3 The Promoter has provided to the Allottee a time schedule for construction progress based on the milestones on which payment is due. The dates provided are only tentative and for the purpose of dealing with contractors and will also make efforts to complete various stages as per the time schedule upto completion of the Project including the provisions of civic infrastructure like water, electricity, sanitation and all other above mentioned internal/external development works but the Promoter knows there will definitely be delays in the timelines provided but the Promoter assures the Allottee that the Project will be completed within the ‘Completion date’ provided in Clause 8.1 above.