B Remediation Sample Clauses

B Remediation. Seller shall cause completion of the Remediation in accordance with the terms of the Remediation Plan prior to the Outside Closing Date, as may be extended as provided herein. 7.01. C Termination on Determination of Seller's Inability to Complete Remediation. If Buyer determines no earlier than 60 days prior to the Outside Closing Date that Seller will be unable to complete the Remediation prior to the Outside Closing Date as extended by any permitted extensions, Buyer shall give Seller notice of such determination (the "COMPLETION NOTICE"). Unless Seller provides Buyer, within 30 days after receiving the Completion Notice, with adequate assurances of Seller's ability to timely complete the Remediation, Buyer may obtain a signed statement from Northgate Environmental Management, Inc., Buyer's environmental consultant, and from Treadwell & Rollo, Seller's environmental consultant, stating that txx Xxxxxxatixx xxnnot be timely completed (including any permitted extensions) and such delays are not a result of force majeure events. If such statement cannot be obtained because such consultants do not agree, then a statement to the same effect from an independent professional environmental consultant selected by Buyer and Seller may be substituted by Buyer. If Buyer desires to terminate its obligations under this Agreement in reliance on such third party statement(s), provided Buyer is not in material default of this Agreement, such statement(s) shall be attached to a Buyer's Termination Notice and delivered to Seller, in which event the Full Deposit shall be returned to Buyer within 150 days of delivery of such Buyer's Termination Notice, as provided in the Deposit Note. In addition to the foregoing, Buyer and Seller may agree, in their discretion, to invoke the provisions of this Section 7.01.C prior to the 60th day prior to the Outside Closing Date.
AutoNDA by SimpleDocs

Related to B Remediation

  • Environmental Remediation Failure to remediate (or pursue the remediation process with due diligence and good faith) within the time period required by law or governmental order, (or within a reasonable time in light of the nature of the problem if no specific time period is so established), environmental problems in violation of Applicable Law related to Properties of the Borrower and/or its Subsidiaries where the estimated cost of remediation is in the aggregate in excess of Seventy-Five Million Dollars ($75,000,000), in each case after all administrative hearings and appeals have been concluded.

  • Lessee Remediation Lessee shall not cause or permit any Hazardous Substance to be spilled or released in, on, under, or about the Premises (including through the plumbing or sanitary sewer system) and shall promptly, at Lessee's expense, take all investigatory and/or remedial action reasonably recommended, whether or not formally ordered or required, for the cleanup of any contamination of, and for the maintenance, security and/or monitoring of the Premises or neighboring properties, that was caused or materially contributed to by Lessee, or pertaining to or involving any Hazardous Substance brought onto the Premises during the term of this Lease, by or for Lessee, or any third party.

  • Hazardous Materials; Remediation (a) If any release or disposal of Hazardous Materials shall occur or shall have occurred on any real property or any other assets of any Borrower or any other Credit Party, such Borrower will cause, or direct the applicable Credit Party to cause, the prompt containment and removal of such Hazardous Materials and the remediation of such real property or other assets as is necessary to comply with all Laws and to preserve the value of such real property or other assets. Without limiting the generality of the foregoing, each Borrower shall, and shall cause each other Credit Party to, comply with each Law requiring the performance at any real property by any Borrower or any other Credit Party of activities in response to the release or threatened release of a Hazardous Material. (b) Borrower will provide Agent within thirty (30) days after written demand therefor with a bond, letter of credit or similar financial assurance evidencing to the reasonable satisfaction of Agent that sufficient funds are available to pay the cost of removing, treating and disposing of any Hazardous Materials or Hazardous Materials Contamination and discharging any assessment which may be established on any property as a result thereof, such demand to be made, if at all, upon Agent’s determination that the failure to remove, treat or dispose of any Hazardous Materials or Hazardous Materials Contamination, or the failure to discharge any such assessment could reasonably be expected to have a Material Adverse Change. (c) If there is any conflict between this Section 6.10 and any environmental indemnity agreement which is a Financing Document, the environmental indemnity agreement shall govern and control.

  • Investigations and Remediations Lessor shall retain the responsibility and pay for any investigations or remediation measures required by governmental entities having jurisdiction with respect to the existence of Hazardous Substances on the Premises prior to the Start Date, unless such remediation measure is required as a result of Lessee's use (including "Alterations", as defined in Paragraph 7.3(a) below) of the Premises, in which event Lessee shall be responsible for such payment. Lessee shall cooperate fully in any such activities at the request of Lessor, including allowing Lessor and Lessor's agents to have reasonable access to the Premises at reasonable times in order to carry out Lessor's investigative and remedial responsibilities.

  • Remediation The Charter School shall provide remediation in required cases pursuant to State Board of Education Rule 160-4-5-.01 and No Child Left Behind.

  • Incident Notice and Remediation If Contractor becomes aware of any Incident, it shall notify the State immediately and cooperate with the State regarding recovery, remediation, and the necessity to involve law enforcement, as determined by the State. Unless Contractor can establish that none of Contractor or any of its agents, employees, assigns or Subcontractors are the cause or source of the Incident, Contractor shall be responsible for the cost of notifying each person who may have been impacted by the Incident. After an Incident, Contractor shall take steps to reduce the risk of incurring a similar type of Incident in the future as directed by the State, which may include, but is not limited to, developing and implementing a remediation plan that is approved by the State at no additional cost to the State.

  • Remedial Action A. If a represented individual has worked more than one thousand fifty (1,050) hours in the twelve (12) month period from the individual’s original date of hire, the represented individual may request remedial action from the State Human Resources Director in accordance with WAC 357-49. Following the Director’s review of the remedial action request, an individual may file exceptions to the Director’s decision in accordance with WAC 357. B. Remedial action is not subject to the provisions of the grievance procedure specified in Section 5.12, below.

  • Joint Remediation Committee If the Sellers (acting reasonably) determine that the Purchasers have committed a Major Default, then, at the election of the Sellers, within three (3) Business Days of the Sellers providing the Purchasers written notice of such determination, the Sellers and the Purchasers shall establish a joint remediation committee of designated executives from the Sellers and the Purchasers (“Joint Remediation Committee”) consisting of three (3) members of each of the Sellers and the Purchasers. The Joint Remediation Committee shall be responsible for overseeing the development of a mutually agreeable plan in accordance with subsection 3 below to either (i) remediate any breaches giving rise to the Major Default to the extent such breaches can be remediated and/or (ii) prevent similar breaches from recurring in the future (clauses (i) and (ii), a “Corrective Action Plan”). Each member of the Joint Remediation Committee shall have sufficient authority on the part of his or her respective party to make decisions relating to matters reviewed by the Joint Remediation Committee, and shall be approved by the other party (such approval not to be unreasonably delayed, conditioned or withheld). The Joint Remediation Committee shall have access to Purchaser Personnel that are primarily responsible for the area of the business relationship (such as information technology, data security or regulatory) where the breaches giving rise to the Major Default arise (such Purchaser Personnel, collectively, the “Subject Matter Experts”). The Sellers and the Purchasers shall cause their respective members on the Joint Remediation Committee to, and the Purchasers shall cause the Subject Matter Experts to, act in good faith in connection with the development of the Corrective Action Plan.

  • Tenant’s Remedies Notwithstanding any other provision of this Lease, if any default hereunder by Landlord is not cured within the applicable cure period provided in Paragraph 20(c) or any other applicable cure period provided in this Lease (including any Mortgagee’s additional cure period), Tenant’s exclusive remedies shall be (i) an action for specific performance, or (ii) an action for actual damages. Notwithstanding any other provision of this Lease, the liability of Landlord to Tenant for any breach or default by Landlord under the terms of this Lease, or for any other matter related to this Lease or to the Premises or Project, shall be limited to Tenant’s actual direct, but not consequential, damages therefor, and any judgment against Landlord in connection therewith shall be recoverable only from the interest of Landlord in the Buildings. Tenant hereby waives any claim for damages for any disturbance, loss of business, nuisance, injury or inconvenience to or interference with Tenant’s business, any loss of occupancy or quiet enjoyment of the Premises, and any other loss arising from Landlord’s entry and acts pursuant to Paragraph 18 or otherwise with respect to any act, omission or breach of Landlord. Without limiting the preceding sentence, in no event shall Landlord be liable to Tenant for any consequential damages, including, without limitation, any losses arising from any interruption of Tenant’s business, or for lost profits, or for charges or expenses which continue but would have been earned if the business had gone on without interruption, or for any other loss, claim, cost, expense or damage which would be covered by a standard policy of business interruption insurance. Landlord, or if Landlord is a partnership its partners whether general or limited, or if Landlord is a corporation its directors, officers or shareholders, or if Landlord is a limited liability company its members or managers, shall never be personally liable for any such judgment. Any lien obtained to enforce such judgment and any levy of execution thereon shall be subject and subordinate to any Mortgage (excluding any Mortgage which was created as part of an effort to defraud creditors, i.e., a fraudulent conveyance); provided, however that any such judgment and any such levy of execution thereon shall not be subject or subordinated to any Mortgage that is created or recorded in the official records of the county in which the Project is located after the date of the judgment giving rise to such lien. Landlord’s interest in the Buildings shall include any insurance proceeds received by Landlord which are not controlled by any Mortgagee or other lender. Tenant hereby waives the benefit of any Laws granting it (A) the right to perform Landlord’s obligations, or (B) the right to terminate this Lease or withhold Rent on account of any Landlord default, including, without limitation, Sections 1932(1), 1941 and 1942 of the California Civil Code.

  • Disputes and Remedies 6.01 Agreement of the Parties The Parties agree that the interests of fairness, efficiency, and good business practices are best served when the Parties employ all reasonable and informal means to resolve any dispute under the Contract before resorting to formal dispute resolution processes otherwise provided in the Contract. The Parties will use all reasonable and informal means of resolving disputes prior to invoking a remedy provided elsewhere in the Contract, unless HHSC immediately terminates the Contract in accordance with the terms and conditions of the Contract. Any dispute, that in the judgment of any Party to the Agreement, may materially affect the performance of any Party will be reduced to writing and delivered to the other Party within 10 business days after the dispute arises. The Parties must then negotiate in good faith and use every reasonable effort to resolve the dispute at the managerial or executive levels prior to initiating formal proceedings pursuant to the UTC and Texas Government Code §2260, unless a Party has reasonably determined that a negotiated resolution is not possible and has so notified the other Party. The resolution of any dispute disposed of by agreement between the Parties will be reduced to writing and delivered to all Parties within 10 business days of such resolution.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!