Aircraft Basic Price The Aircraft Basic Price is listed in Table 1 and is subject to escalation in accordance with the terms of this Purchase Agreement.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Base Price Initial price quoted, proposed and/or contracted per unit of measure.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Economic Price Adjustment is the adjustment to the Aircraft Basic Price (Base Airframe, Engine and Special Features) as calculated pursuant to Exhibit D.
JOC Pricing of Itemized List of Means Non-Prepriced Items” based on the information herein. This Addendum is only to correct a misstatement on the original optional attachment entitled “PART 2 JOC Pricing of Itemized List of Means Non-Prepriced Items.” The attachment mistakenly provided for and discussed “Attribute 39.” Specifically, any erroneous reference to “Attribute 39” on the specified attachment should be considered immediately replaced with “the Attribute Question asking for Pricing for Markup of Non- Prepriced Items in RS Means Unit Price Book.” Please disregard any reference to Attribute 39 on this optional form and consider it to be referencing the Attribute Question asking for “Pricing for Markup of Non-Prepriced Items in RS Means Unit Price Book” instead.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Table 4 Ending this Addendum when the Approved Addendum Changes
Delivery Schedule The Goods specified in the List of Goods are required to be delivered within the acceptable time range (after the earliest and before the final date, both dates inclusive) specified in Section V, Schedule of Requirements. No credit will be given to deliveries before the earliest date, and Tenders offering delivery after the final date shall be treated as non-responsive. Within this acceptable period, an adjustment of [insert the adjustment factor], will be added, for evaluation purposes only, to the Tender price of Tenders offering deliveries later than the “Earliest Delivery Date” specified in Section V, Schedule of Requirements.
Price Schedule, Payment Terms and Billing, and Price Adjustments (a) Price Schedule: Price Schedule under this Contract is set forth in Exhibit B.
