Block Delay Liquidated Damages Sample Clauses

Block Delay Liquidated Damages. (a) If Contractor has not achieved Block Substantial Completion of a Block by the Guaranteed Block Substantial Completion Date for such Block (a “Late Block”) for reasons not excused under the terms of this Agreement, then Contractor shall pay to Owner delay liquidated damages (“Block Delay Liquidated Damages”) equal to, for each Day after the Guaranteed Block Substantial Completion Date for such Late Block, Dollars ($***) per MW by which the Block Measured Capacity of the Late Block is less than the Minimum Capacity Level of the Late Block; provided that any amounts that Contractor is obligated to pay to Owner under this Section 17.1 are subject to the limitations set forth in Section 17.1(b) and Article 29. In the event that the Capacity Test has not been performed by the Guaranteed Block Substantial Completion Date, the Block Measured Capacity of such Block shall be *** until the Block Substantial Completion Date of such Block. Block Delay Liquidated Damages shall cease to accrue upon the earlier to occur of (i) the Block Substantial Completion Date for such Block and (ii) the Guaranteed Facility Substantial Completion Date. After taking into account the set-off against the bonus payable under Section 17.1(b) in accordance with Section 17.4, any amount Contractor is obligated to pay to Owner under this Section 17.1(a) shall be due and payable within thirty (30) Days after Contractor's receipt of Owner's invoice submitted not more frequently than monthly following the Guaranteed Block Substantial Completion Date of the Late Block.
Sample 1Sample 2
AutoNDA by SimpleDocs
Block Delay Liquidated Damages. (a) If Contractor has not achieved Block Substantial Completion of a Block by the Guaranteed Block Substantial Completion Date for such Block (a “Late Block”) for reasons not excused under the terms of this Agreement, then Contractor shall pay to Owner delay liquidated damages (“Block Delay Liquidated Damages”) equal to, for each Day after the Guaranteed Block Substantial Completion Date for such Late Block, ***; provided that any amounts that Contractor is obligated to pay to Owner under this Section 17.1 are subject to the limitations set forth in Section 17.1(b) and Article 29. *** CONFIDENTIAL MATERIAL REDACTED AND SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION. 58 *** Block Delay Liquidated Damages shall cease to accrue upon the earlier to occur of (i) the Block Substantial Completion Date for such Block and (ii) the Guaranteed Facility Substantial Completion Date. After taking into account the set-off against the bonus payable under Section 17.1(b) in accordance with Section 17.4, any amount Contractor is obligated to pay to Owner under this Section 17.1(a) shall be due and payable within *** after Contractor's receipt of Owner's invoice submitted not more frequently than monthly following the Guaranteed Block Substantial Completion Date of the Late Block.
Sample 1

Related to Block Delay Liquidated Damages

  • Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.

  • Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.

  • Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.

  • Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.

  • Six-Month Delay Notwithstanding anything to the contrary in this Agreement, no compensation or benefits, including without limitation any severance payments or benefits payable under this Section 4, shall be paid to the Executive during the six-month period following the Executive’s Separation from Service if the Company determines that paying such amounts at the time or times indicated in this Agreement would be a prohibited distribution under Section 409A(a)(2)(B)(i) of the Code. If the payment of any such amounts is delayed as a result of the previous sentence, then on the first day of the seventh month following the date of Separation from Service (or such earlier date upon which such amount can be paid under Section 409A without resulting in a prohibited distribution, including as a result of the Executive’s death), the Company shall pay the Executive a lump-sum amount equal to the cumulative amount that would have otherwise been payable to the Executive during such period.

  • Six-Month Delay Rule The “six-month delay rule” will apply to 000X XXXx if these four conditions are met:

  • Default Payment Following the occurrence and during the continuance of an Event of Default, the Holder, at its option, may demand repayment in full of all obligations and liabilities owing by Company to the Holder under this Note, the Purchase Agreement and/or any other Related Agreement and/or may elect, in addition to all rights and remedies of the Holder under the Purchase Agreement and the other Related Agreements and all obligations and liabilities of the Company under the Purchase Agreement and the other Related Agreements, to require the Company to make a Default Payment (“Default Payment”). The Default Payment shall be 130% of the outstanding principal amount of the Note, plus accrued but unpaid interest, all other fees then remaining unpaid, and all other amounts payable hereunder. The Default Payment shall be applied first to any fees due and payable to the Holder pursuant to this Note, the Purchase Agreement, and/or the other Related Agreements, then to accrued and unpaid interest due on this Note and then to the outstanding principal balance of this Note. The Default Payment shall be due and payable immediately on the date that the Holder has exercised its rights pursuant to this Section 2.3.

  • Transfer Premium If Landlord consents to a Transfer, as a condition thereto which the parties hereby agree is reasonable, Tenant shall pay to Landlord fifty percent (50%) of any “Transfer Premium,” as that term is defined in this Section 14.3, received by Tenant from such Transferee in any particular calendar month, which amount shall be paid to Landlord immediately following Tenant’s receipt of the same. “Transfer Premium” shall mean all rent, additional rent or other consideration (including, without limitation, key money, bonus money or other cash consideration but excluding any payment for assets, inventory, equipment or furniture transferred by Tenant to Transferee in connection with such Transfer) payable by such Transferee in connection with the Transfer in excess of the Rent and Additional Rent payable by Tenant under this Lease during the term of the Transfer on a per rentable square foot basis if less than all of the Premises is transferred, after deducting the reasonable expenses incurred by Tenant for (i) any changes, alterations and improvements to the Premises in connection with the Transfer, and (ii) any market rate, third party brokerage commissions incurred in connection with the Transfer (collectively, the “Subleasing Costs”); provided, however, that if, at the time of any such sublease or assignment, Landlord determines that the foregoing “Transfer Premium” formula may result in the receipt by Landlord of amounts that the Landlord may not be permitted to receive pursuant to any requirements, obligation or understanding applicable to Landlord, the parties agree to enter into an amendment to this Lease which revises the “Transfer Premium” formula in a manner that (x) is mutually agreed to by the parties and (y) does not result in any material increase in the expected costs or benefits to either party under this Section 14.3. 14.4

  • Default Interest; Late Charge Following the occurrence and during the continuance of any Event of Default, and regardless of whether or not the Agent or the Lenders shall have accelerated the maturity of the Loans, all Loans shall bear interest payable on demand at a rate per annum equal to the sum of the Base Rate plus the Applicable Margin plus five percent (5.0%) (the “Default Rate”), until such amount shall be paid in full (after as well as before judgment), and the fee payable with respect to Letters of Credit shall be increased to a rate equal to five percent (5.0%) above the Letter of Credit fee that would otherwise be applicable to such time, or if any of such amounts shall exceed the maximum rate permitted by law, then at the maximum rate permitted by law. In addition, the Borrower shall pay a late charge equal to four percent (4.0%) of any amount of interest and/or principal payable on the Loans or any other amounts payable hereunder or under the other Loan Documents, which is not paid by the Borrower within ten (10) days of the date when due (or, in the case of amounts due at the Revolving Credit Maturity Date or Term Loan Maturity Date, as applicable, within fifteen (15) Business Days of such date).

  • Payment of default interest on overdue amounts The Borrower shall pay interest in accordance with the following provisions of this Clause 7 on any amount payable by the Borrower under any Finance Document which the Agent, the Security Trustee or the other designated payee does not receive on or before the relevant date, that is:

Time is Money Join Law Insider Premium to draft better contracts faster.