BODY PRICE WORKSHEET. A Contractor providing a response to a Mini-Bid that includes a Body shall provide the following information on Form B (Class 3-8): Mini-Bid Response.
BODY PRICE WORKSHEET Sample Clauses
Related to BODY PRICE WORKSHEET
WARRANTY-PRICE A. The Contractor warrants the prices quoted in the Offer are no higher than the Contractor's current prices on orders by others for like deliverables under similar terms of purchase.
Contract Price Adjustment The basis upon which the Contract Price shall be adjusted is as set out in paragraph 9.2 of Schedule IVB.
ESTIMATED / SPECIFIC QUANTITY CONTRACTS Estimated quantity contracts, also referred to as indefinite delivery / indefinite quantity contracts, are expressly agreed and understood to be made for only the quantities, if any, actually ordered during the Contract term. No guarantee of any quantity is implied or given. With respect to any specific quantity stated in the contract, the Commissioner reserves the right after award to order up to 20% more or less (rounded to the next highest whole number) than the specific quantities called for in the Contract. Notwithstanding the foregoing, the Commissioner may purchase greater or lesser percentages of Contract quantities should the Commissioner and Contractor so agree. Such agreement may include an equitable price adjustment.
Price Schedule 35.1. All prices under this agreement are set forth in the attachments designated Table One and Table Two of this Agreement are hereby incorporated into, and made a part of, this Agreement.
Preliminary Cost Estimate Consulting Engineer/Architect shall furnish City an estimate of probable Construction Cost based on the preliminary design. Consulting Engineer/Architect's estimate of probable Construction Cost is to be made on the basis of Consulting Engineer/Architect's experience and qualifications and represent Consulting Engineer/Architect's best judgment as an experienced and qualified design professional, familiar with the construction industry.
Recovery Schedule If the initial schedule or any current updates fail to reflect the Work’s actual plan or method of operation, or a contractual milestone date is more than fifteen (15) days behind, Owner may require that a recovery schedule for completion of the remaining Work be submitted. The Recovery Schedule must be submitted within seven (7) calendar days of Owner’s request. The Recovery Schedule shall describe in detail Construction Contractor’s plan to complete the remaining Work by the required Contract milestone date. The Recovery Schedule submitted shall meet the same requirements as the original Construction Schedule. The narrative submitted with the Recovery Schedule should describe in detail all changes that have been made to meet the Contract milestone dates.
Overall Project Schedule The Construction Progress Schedule that is approved by the Owner.
Preliminary Cost Estimates The Engineer shall develop a preliminary cost estimate using the Average Low Bid Unit Price. The Engineer shall estimate the total project cost including preliminary engineering, final engineering, right-of-way (ROW) acquisition, environmental compliance and mitigation, construction, utility relocation, and construction engineering inspection (CEI).
Construction Progress Schedule; Overall Project Schedule The Contractor shall submit for review by the Design Professional and approval by the Owner a Construction Progress Schedule based upon the Design Professional’s Preliminary Design and Construction Schedule and prepared using a CPM (Critical Path Method) process within sixty days after the Effective Date of the Contract, utilizing a full-featured software package in a form satisfactory to the Design Professional and Owner, showing the dates for commencement and completion of the Work required by the Contract Documents, including coordination of mechanical, plumbing, and electrical disciplines, as well as coordination of the various subdivisions of the Work within the Contract. Milestones must be clearly indicated and sequentially organized to identify the critical path of the Project. The Construction Schedule will be developed to represent the CSI specification divisions. It shall have the minimum number of activities required to adequately represent to the Owner the complete scope of Work and define the Project’s (and each Phase’s if phased) critical path and associated activities. The format of the Construction Progress Schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, inspections for Material Completion and Occupancy Date, and Final Completion Date. The Contractor shall submit, along with the Construction Progress Schedule, the Submittal Schedule for approval by the Design Professional, correlating the associated approval dates for the documents with the Construction Progress Schedule. Upon recommendation by the Design Professional and approval by the Owner, the Construction Progress Schedule shall become the Overall Project Schedule, which shall be utilized by the Design Professional, Owner and Contractor. The Contractor must provide the Design Professional and the Owner with monthly updates of the Overall Project Schedule indicating completed activities and any changes in sequencing or activity durations, including approved change orders. See also Article 3.3.5.
Delivery Schedule The scheduled months of delivery of the Aircraft are listed in the attached Table 1. Exhibit B describes certain responsibilities for both Customer and Boeing in order to accomplish the delivery of the Aircraft.
