Breach of Contract Claims To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.
Breach of Contract The failure of the Contractor to comply with any of the provisions, covenants or conditions of this Contract shall be a material breach of this Contract. In such event the County may, and in addition to any other remedies available at law, in equity, or otherwise specified in this Contract:
Breach of Contract and Cure If either party breaches any of the covenants, promises, agreements, representations, and warranties provided by this Agreement, then the non-breaching party shall provide written notice of the breach to the address provided below for written notices under this Agreement by hand-delivery, U.S. Mail, commercial delivery service, such as Fed Ex or UPS, or fax, identifying the nature of the breach and providing the breaching party with ten (10) days from the delivery of the written notice to cure the breach. If the breaching party fails to cure the breach within ten (10) days of the delivery of the written notice of the breach, then the non-breaching party may terminate this contract for cause as set forth below and pursue any and all remedies for the breach available at law. If the District notifies Contractor that it is in breach of this Agreement, then the District may withhold all future payments to Contractor until any dispute regarding the breach of contract is resolved by the mutual, written agreement of the parties or by the entry of a final judgment by a court of law of competent subject matter jurisdiction and the resolution of any possible appeals from any such judgment. If the District withholds any payments to Contractor pursuant to this paragraph, then the District shall not be required to pay Contractor any amounts ultimately determined to be owed by the District to Contractor under this Agreement until any breach of contract dispute is resolved by the mutual, written agreement of the parties or by the entry of a final judgment by a court of law of competent subject matter jurisdiction and the resolution of any possible appeals from such judgment. Contractor further agrees that it may not charge interest on any payments withheld by the District pursuant to this paragraph until the breach of contract is resolved by the mutual, written agreement of the parties or by the entry of a final judgment by a court of law of competent subject matter jurisdiction and the resolution of any possible appeals from such judgment
Material Breach of Contract In the event Contractor fails to deliver the product and services as contracted for herein, to the satisfaction of the City of Sparks or otherwise fails to perform any provisions of this Contract, the City, after providing five (5) days written notice and Contractor’s failure to cure such breach within the time specified in the notice, may without waiving any other remedy, make good the deficiencies and deduct the actual cost of providing alternative products and/or services from payment due the Contractor. Non-performance after the first notice of non-performance shall be considered a material breach of contract.
BREACH OF CONTRACT TERMS The State reserves its right to all administrative, contractual, or legal remedies, including but not limited to suspension or termination of this contract, in instances where the Contractor or any of its subcontractors violate or breach any contract term. If the Contractor or any of its subcontractors violate or breach any contract term, they shall be subject to such sanctions and penalties as may be appropriate. The duties and obligations imposed by the contract documents and the rights and remedies available thereunder shall be in addition to and not a limitation of any duties, obligations, rights and remedies otherwise imposed or available by law.
No Breach of Contract The Executive hereby represents to the Company that: (i) the execution and delivery of this Agreement by the Executive and the performance by the Executive of the Executive’s duties hereunder shall not constitute a breach of, or otherwise contravene, the terms of any other agreement or policy to which the Executive is a party or otherwise bound, except for agreements entered into by and between the Executive and any member of the Group pursuant to applicable law, if any; (ii) that the Executive has no information (including, without limitation, confidential information and trade secrets) relating to any other person or entity which would prevent, or be violated by, the Executive entering into this Agreement or carrying out his duties hereunder; (iii) that the Executive is not bound by any confidentiality, trade secret or similar agreement (other than this) with any other person or entity except for other member(s) of the Group, as the case may be.
Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS.
Termination for Breach of Contract 1. Except as provided in PSC-6, if CONTRACTOR fails to perform any of the provisions of this Contract or so fails to make progress as to endanger timely performance of this Contract, CITY may give CONTRACTOR written notice of the default. CITY’S default notice will indicate whether the default may be cured and the time period to cure the default to the sole satisfaction of CITY. Additionally, CITY’S default notice may offer CONTRACTOR an opportunity to provide CITY with a plan to cure the default, which shall be submitted to CITY within the time period allowed by CITY. At CITY’S sole discretion, CITY may accept or reject CONTRACTOR’S plan. If the default cannot be cured or if CONTRACTOR fails to cure within the period allowed by CITY, then CITY may terminate this Contract due to CONTRACTOR’S breach of this Contract.
Liability for Breach of Contract 1. Any Party who violates the provisions of this Agreement and makes all or part of this Agreement unenforceable, shall be liable for breach of contract and shall compensate the other Party for the losses caused thereby (including the litigation fees and attorney fees caused thereby). If both Parties breach this Agreement, each shall bear the corresponding responsibility according to the actual situations.
Breach of Conditions Where a loss occurs and there has been a breach of condition relating to a matter before the happening of the loss, which bre ach would otherwise disentitle the Insured from recovery under this Form, the breach shall not disentitle the Insured from recovery if the Insured establishes that the loss was not caused or contributed to by the breach of condition or if the breach of condition occurred in any portion of the project over which the Insured has no control.
