Breach of Security 6.1 Either party shall notify the other immediately upon becoming aware of any Breach of Security including, but not limited to an actual, potential or attempted breach, or threat to, the Security Plan.
Indemnification (Breach of Warranty of Security) The Contractor agrees to defend, indemnify and hold harmless the Department, Customer, the State of Florida, its officers, directors and employees for any claims, suits or proceedings related to a breach of the Warranty of Security. The Contractor will include credit monitoring services at its own cost for those individuals affected or potentially affected by a breach of this warranty for a two year period of time following the breach.
Breach of Covenant The Borrower breaches any material covenant or other term or condition of the Subscription Agreement or this Note in any material respect and such breach, if subject to cure, continues for a period of ten (10) business days after written notice to the Borrower from the Holder.
Breach of Covenants If the Company breaches any of the covenants set forth in this Section 4, and in addition to any other remedies available to the Buyer pursuant to this Agreement, it will be considered an event of default under Section 3.4 of the Note.
Breach of Contract The failure of the Contractor to comply with any of the provisions, covenants or conditions of this Contract shall be a material breach of this Contract. In such event the County may, and in addition to any other remedies available at law, in equity, or otherwise specified in this Contract:
Breach of Obligations The Parties acknowledge that a breach of any of the obligations contained herein would result in injuries. The Parties further acknowledge that the amount of the liquidated damages or the method of calculating the liquidated damages specified in this Agreement is a genuine and reasonable pre-estimate of the damages that may be suffered by the non-defaulting party in each case specified under this Agreement.
Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS.
Damages for breach of maintenance obligations 17.8.1 In the event that the Concessionaire fails to repair or rectify any defect or deficiency set forth in the Maintenance Requirements within the period specified therein, it shall be deemed to be in breach of this Agreement and the Authority shall be entitled to recover Damages, to be calculated and paid for each day of delay until the breach is cured, at the higher of (a) 0.5% (zero point five per cent) of Performance Guarantee, and (b) 0.1% (zero point one per cent) of the cost of such repair or rectification as estimated by the Independent Engineer. Recovery of such Damages shall be without prejudice to the rights of the Authority under this Agreement, including the right of Termination thereof.
Warranty of Security Unless otherwise agreed in writing, the Contractor and its subcontractors will not perform any of the services from outside of the United States, and the Contractor will not allow any State of Florida data to be sent by any medium, transmitted, or accessed outside of the United States. The Contractor agrees that a violation of items listed above will result in immediate and irreparable harm to the Customer and will entitle the Customer to a credit as provided in the Contract documents. This credit is intended only to cover the Customer’s internal staffing and administrative costs as well as the diminished value of services provided under the Contract and will not preclude the Customer from recovering other damages it may suffer as a result of such violation. For purposes of determining the damages due hereunder, a group of violations relating to a common set of operative facts (e.g., same location, same time period, same off-shore entity) will be treated as a single event. A violation of this provision will also entitle the Customer to recover any damages arising from a breach of this section and constitutes an event of default. The Contractor must notify the Department and the Customer as soon as possible, in accordance with the requirements of section 501.171, F.S., if applicable, and in all events within one (1) business day in the event Contractor discovers any data is breached, any unauthorized access of data occurs (even by persons or companies with authorized access for other purposes), any unauthorized transmission of data occurs, or of any credible allegation or suspicion of a material violation of the above. This notification is required regardless of the number of persons or type of data affected. The notification must be clear and conspicuous and include a description of the following:
Breach of Confidentiality Contractor acknowledges that there can be no adequate remedy at law for any breach of Contractor’s obligations hereunder, that any such breach will likely result in irreparable harm, and therefore, that upon any breach or threatened breach of the confidentiality obligations, the Court shall be entitled to appropriate equitable relief, without the requirement of posting a bond, in addition to its other remedies at law. INDEMNIFICATION
