Builders' Lien Holdback. 21.1 A lien holdback of ten percent (10%) of the cost of the Work will be deducted from the second (2nd) and subsequent progress invoices, and held by the City until fifty-five (55) days after the date of Substantial Performance, in accordance with the Builders Lien Act of British Columbia.

Builders' Lien Holdback. That portion, if any, of the Purchase Price required by law to be held back to the Purchaser in respect of builder’s lien claims (the “Lien Holdback”) will be paid to the Vendor’s Solicitors on the Completion Date. The Lien Holdback will be held in trust by the Vendor’s Solicitors pursuant to the Strata Property Act (British Columbia) and Builders Lien Act (British Columbia) (or successor statutes) solely in respect of lien claims registered in the applicable LTO in connection with work done at the behest of the Vendor. The Vendor’s Solicitors are authorized to pay to the Vendor (or as directed by the Vendor), on the earlier of: (a) the date on which the time for filing a claim of lien under the Builders Lien Act expires; and (b) the date which is 56 days after the Completion Date; the Lien Holdback less the amount of any builders’ lien claim(s) filed against the Strata Lot of which the Purchaser or the Purchaser’s Solicitors notify the Vendor’s Solicitors in writing by 1:00 p.m. on that day. The Purchaser hereby authorizes the Vendor and the Vendor’s Solicitors to do all things necessary to discharge any builders’ liens, including bringing court proceedings in the name of the Purchaser, provided that any such proceedings will be at the sole expense of the Vendor.

Builders' Lien Holdback. The Owner will deduct from each progress payment (and other payment) made to the Design- Builder a holdback pursuant to and in the amount required by the Builders Lien Act (British Columbia).

Builders' Lien Holdback. That portion, if any, or the balance of the Purchase Price required by law to be held back by the Purchaser in respect of the builder's lien claims (the "Lien Holdback") will be paid to the Vendor's Solicitors on the Completion Date. The Lien Holdback will be held in trust for the Purchaser pursuant to the Strata Property Act (British Columbia) and Builders Lien Act (British Columbia) (or successor statutes) solely in respect of the lien claims registered in the applicable Land Title Office in connection with work done ad the behest of the Vendor. The Vendor's Solicitors are authorized to invest the Lien Holdback in an interest bearing trust account and pay to the Vendor (or as directed by the Vendor), on the earlier of (i) the date on which the time for filing a claim of lien under the Builder's Lien Act expires; and (ii) the date which is fifty-six (56) days after the date that the balance of the Purchase Price becomes due as aforesaid (the "Release Date"), the Lien Holdback plus interest, if any, accrued thereon , less the amount of any builder's lien claim filed against the Strata Lot of which the Purchaser or the Purchaser's Solicitor notifies the Vendor's Solicitor in writing by 1pm on that day, The Purchaser hereby consents to and authorizes the Vendor and the Vendor's Solicitor to do all things necessary to discharge any claims of builder's liens registered against title to the Strata Lot, including the commencement of court proceedings in the name of the Purchaser, provided that such proceedings will be solely at the expense of the Vendor. If any claims of builder's liens are registered against title to the Strat lot on or before the Release Date, the Vendor's Solicitors will undertake to continue to hold the Lien Holdback in trust until the builders liens are released from title to the Strata Lot or until a court otherwise orders the release of the Lien Holdback.

Related to Builders' Lien Holdback

Lessor's Lien To the fullest extent permitted by applicable law, Lessor is granted a lien and security interest on all Lessee’s personal property now or hereinafter placed in or upon the Leased Property, and such lien and security interest shall remain attached to such Lessee’s personal property until payment in full of all Rent and satisfaction of all of Lessee’s obligations hereunder; provided, however, Lessor shall subordinate its lien and security interest to that of any non-Affiliate of Lessee which finances such Lessee’s personal property or any non-Affiliate conditional seller of such Lessee’s personal property, the terms and conditions of such subordination to be satisfactory to Lessor in the exercise of reasonable discretion. Lessee shall, upon the request of Lessor, execute such financing statements or other documents or instruments reasonably requested by Lessor to perfect the lien and security interests herein granted. Lessee hereby authorizes Lessor to execute and file financing statements signed only be a representative of Lessor covering the security interest of Lessor in Lessee’s personal property.
Transfer Upon Realization of Pledged, Mortgaged or Charged Escrow Securities (1) You may transfer within escrow to a financial institution the escrow securities you have pledged, mortgaged or charged under section 4.2 to that financial institution as collateral for a loan on realization of the loan. (2) Prior to the transfer the Escrow Agent must receive: (a) a statutory declaration of an officer of the financial institution that the financial institution is legally entitled to the escrow securities; (b) a transfer power of attorney, executed by the transferor in accordance with the requirements of the Issuer’s transfer agent; and (c) an acknowledgement in the form of Schedule “B” signed by the financial institution. (3) Within 10 days after the transfer, the transferee of the escrow securities will file a copy of the acknowledgment with the securities regulators in the jurisdictions in which the Issuer is a reporting issuer.
Discharge of Escrow Agent The Escrow Agent shall resign and be discharged from its duties as escrow agent hereunder if so requested in writing at any time by the other parties hereto, jointly, provided, however, that such resignation shall become effective only upon acceptance of appointment by a successor escrow agent as provided in Section 5.5.
Holdback In connection with a Requested Underwritten Offering or an Underwritten Piggyback Offering, upon the request of the Demand Holders participating therein or the managing underwriters of such offering, each holder of Registrable Securities shall, (a) enter into a customary “lock-up” agreement relating to the sale, offering or distribution of Registrable Securities, in the form reasonably requested by the managing underwriters of such Public Offering and (ii) subject to customary exceptions, not sell, transfer, make any short sale of, grant any option for the purchase of or enter into any hedging or similar transaction with the same economic effect as a sale (including sales pursuant to Rule 144) (a “Sale Transaction”) in each case during, in the case of an initial public offering, the 180-day period beginning on the effective date of such registration statement or, in the case of any other such underwritten offering, the 60-day period beginning on the date of pricing of such offering (each, a “Holdback Period”), except as part of such offering or pursuant to such exceptions as may be agreed by the Demand Holders participating therein and the managing underwriters of such offering; provided, however, that (x) such Holdback Period shall be no longer than that which is applicable to any other Holder and (y) any agreement with the underwriter(s) with respect to a Holdback Period shall provide that the underwriter(s) may not waive the Holdback Period for any other Holder unless it is waived for all Holders. Notwithstanding the foregoing, none of the provisions or restrictions set forth in this Section 8 shall in any way limit Xxxxxxx Xxxxx & Co. LLC or any of its Affiliates from engaging in any brokerage, investment advisory, financial advisory, anti-raid advisory, principaling, merger advisory, financing, asset management, trading, market making, arbitrage, investment activity and other similar activities conducted in the ordinary course of their business. Notwithstanding anything to the contrary set forth in this Agreement, the restrictions contained in this Agreement shall not apply to any Registrable Securities acquired by Xxxxxxx Sachs & Co. LLC or any of its Affiliates following the effective date of the first registration statement of the Company covering Class A Common Stock (or other securities) to be sold on behalf of the Company in an underwritten public offering.
Escrow Fund Prior to any amount being distributed to any Company Holder pursuant to Section 2.6, the Escrow Fund will be withheld from the Merger Consideration and deposited with the Escrow Agent. The Indemnity Portion of the Escrow Fund will be held for the purpose of securing the indemnification obligations of the Company set forth in this Agreement. The Adjustment Portion of the Escrow Fund will be held for the purpose of securing any obligation of the Company to make a payment to Purchaser pursuant to Section 2.13(d). The Escrow Fund will be withheld from the aggregate amount of Merger Consideration otherwise payable to each Company Holder pursuant to Section 2.6, with each Company Holder’s portion of the Escrow Fund equal to its Company Holder Percentage Interest. The Shareholders’ Agent Expense Portion of the Escrow Fund will be held for the purpose of funding any expenses of the Shareholders’ Agent arising in connection with the administration of the Shareholders’ Agent’s duties in this Agreement after the Effective Time. The Escrow Agreement will provide for (i) the release of the Adjustment Portion of the Escrow Fund remaining in the escrow account (in accordance with Company Holder Percentage Interests for any amounts payable to the Company Holders) within five (5) Business Days after the final determination of the Merger Consideration pursuant to Section 2.13(c) (but, for the avoidance of doubt, after any required payment to Purchaser pursuant to Section 2.13(d) has been made), (ii) the release, subject to a reserve in the aggregate amount of all pending claims, of the Indemnity Portion of the Escrow Fund remaining in the escrow account (in accordance with Company Holder Percentage Interests for any amounts payable to the Company Holders) within five (5) Business Days after the earlier of (A) the date Purchaser completes an audit of the Company for 2014 (such date to be confirmed in writing by Purchaser to the Shareholders’ Agent), or (B) April 1, 2015; and (iii) the release of the Shareholders’ Agent Expense Portion of the Escrow Fund upon receipt of written notice from the Shareholders’ Agent. Following payment of the last balance remaining in the Indemnity Portion of the Escrow Fund that was reserved for a claim made by any Indemnified Persons under Section 9 of this Agreement (or the definitive withdrawal or resolution of such claim), and after payment of any Shareholders’ Agent expenses from the Shareholders’ Agent Expense Portion of the Escrow Fund, Purchaser and the Shareholders’ Agent will direct the Escrow Agent to pay to the Company Holders (or with respect to the Company Holders that were holders of Vested Company Options that were cancelled under Section 2.6(c)(i), to the Surviving Corporation for payment to the Company Holders who are entitled to such Company Holders through the Surviving Corporation’s payroll) in accordance with their Company Holder Percentage Interests an aggregate amount that is equal to any remaining balance of the Escrow Fund.
Release of Escrow Funds The Escrow Funds shall be paid by the Escrow Agent in accordance with the following: (a) In the event that the Company advises the Escrow Agent in writing that the Offering has been terminated (the “Termination Notice”), the Escrow Agent shall promptly return the funds paid by each Investor to such Investor without interest or offset. (b) At each Closing, the Company and the Placement Agent shall provide the Escrow Agent with written instructions regarding the disbursement of the Escrow Funds in accordance with Exhibit A attached hereto and made a part hereof and signed by the Company and the Placement Agent (the “Disbursement Instructions”). (c) If by 5:00 P.M. Eastern time on the Final Termination Date, the Escrow Agent has not received written Disbursement Instructions from the Company and Placement Agent regarding the disbursement of the Escrow Funds in the Escrow Account, if any, then the Escrow Agent shall promptly return such Escrow Funds, if any, to the Investors without interest or offset. The Escrow Funds returned to the Investors shall be free and clear of any and all claims of the Escrow Agent. (d) The Escrow Agent shall not be required to pay any uncollected funds or any funds that are not available for withdrawal. (e) The Placement Agent or the Company will provide the Escrow Agent with the payment instructions for each Investor, to whom the funds should be returned in accordance with this section. (f) In the event that Escrow Agent makes any payment to any other party pursuant to this Escrow Agreement and for any reason such payment (or any portion thereof) is required to be returned to the Escrow Account or another party or is subsequently invalidated, declared to be fraudulent or preferential, set aside and/or required to be repaid to a receiver, trustee or other party under any bankruptcy or insolvency law, other federal or state law, common law or equitable doctrine, then the recipient party shall repay to the Escrow Agent upon written request the amount so paid to it. (g) The Escrow Agent shall, in its sole discretion, comply with judgments or orders issued or process entered by any court with respect to the Escrow Amount, including without limitation any attachment, levy or garnishment, without any obligation to determine such court's jurisdiction in the matter and in accordance with its normal business practices. If the Escrow Agent complies with any such judgment, order or process, then it shall not be liable to any of the Parties or any other person by reason of such compliance, regardless of the final disposition of any such judgment, order or process. (h) Each Party understands and agrees that Escrow Agent shall have no obligation or duty to act upon a written direction delivered to Escrow Agent for the disbursement of all or part of the Escrow Amount under this Agreement (a “Written Direction”) if such Written Direction is not (i) in writing, (ii) signed by representatives of both Parties listed in Schedule II to this Agreement, in each case, each such individual an “Authorized Representative” of such Party), and (iii) delivered to, and able to be authenticated by, Escrow Agent in accordance with Section 1.4 below. (i) Upon request by any Party, the Escrow Agent set up each Party with on-line access to the account(s) established pursuant to this Agreement, which each Party can use to view and verify transaction on such account(s). (j) A Party may specify in a Written Direction whether such Escrow Amount shall be disbursed by way of wire transfer or check. If the written notice for the disbursement of funds does not so specify the disbursement means, Escrow Agent may disburse the Escrow Amount by wire transfer.
Mechanics’ Lien Tenant understands and agrees that Tenant and anyone acting on Tenant’s behalf does not have the right to file for mechanic’s liens or any other kind of liens on the Premises. Tenant agrees to give actual advance notice to any contractors, subcontractors or suppliers of goods, labor or services that such liens are invalid. Tenant further agrees to take the additional steps necessary to keep the Premises free of any and all liens that may result from construction completed by or for Tenant.
Claims Upon Escrow Fund (a) Upon receipt by the Escrow Agent at any time on or before the last day of the Escrow Period of a certificate signed by any officer of Buyer (an "Officer's Certificate"): (A) stating that Buyer has paid or properly accrued or, with respect to third-party claims of which Buyer, the Company or the Surviving Corporation has received notice, reasonably anticipates that it will have to pay or accrue Losses, and (B) specifying in reasonable detail the individual items of Losses included in the amount so stated, the date each such item was paid or properly accrued, or the basis for such anticipated liability, and the nature of the misrepresentation, breach of warranty or covenant to which such item is related, the Escrow Agent shall deliver to Buyer out of the Escrow Fund, as promptly as practicable subject to Section 7.2.6, shares of Buyer Common Stock held in the Escrow Fund with a value equal to such Losses; provided, however, that in the event of a third party claim that is the subject of the demand on the Escrow Fund, no shares shall be delivered out of the Escrow Fund until the claim is settled or adjudicated. (b) For the purposes of determining the number of shares of Buyer Common Stock to be delivered to Buyer out of the Escrow Fund as indemnity pursuant to Section 7.2.5(a) hereof, the shares of Buyer Common Stock shall be valued at $33 per share, unless the average closing price of the Buyer Common Stock for any five (5) consecutive trading days during the thirty (30) day period preceding the assertion of a particular indemnity claim exceeds $50 per share, in which case the shares of Buyer shall be valued at $50 per share or, if the average closing price of the Buyer Common Stock for any five (5) consecutive days during the thirty (30) day period preceding the assertion of a particular indemnity claim is less than $16 per share, then the shares of Buyer shall be valued at $16 per share (subject to in each case to the adjustment as a result of the Buyer Stock Split).
Release of Pledged Collateral The Administrative Agent may release any of the Pledged Collateral from this Pledge Agreement or may substitute any of the Pledged Collateral for other Pledged Collateral without altering, varying or diminishing in any way the force, effect, lien, pledge or security interest of this Pledge Agreement as to any Pledged Collateral not expressly released or substituted, and this Pledge Agreement shall continue as a first priority lien on all Pledged Collateral not expressly released or substituted.
Investment of Escrow Fund During the term of this Escrow Agreement, the Escrow Fund shall be invested and reinvested by the Escrow Agent in the investment indicated on Schedule 1 or such other investments as shall be directed in writing by the Issuer and the Depositor and as shall be acceptable to the Escrow Agent. All investment orders involving U.S. Treasury obligations, commercial paper and other direct investments may be executed through broker-dealers selected by the Escrow Agent. Periodic statements will be provided to the Issuer and the Depositor reflecting transactions executed on behalf of the Escrow Fund. The Issuer and the Depositor, upon written request, will receive a statement of transaction details upon completion of any securities transaction in the Escrow Fund without any additional cost. The Escrow Agent shall have the right to liquidate any investments held in order to provide funds necessary to make required payments under this Escrow Agreement. The Escrow Agent shall have no liability for any loss sustained as a result of any investment in an investment indicated on Schedule 1 or any investment made pursuant to the instructions of the parties hereto or as a result of any liquidation of any investment prior to its maturity or for the failure of the parties to give the Escrow Agent instructions to invest or reinvest the Escrow Fund. The Escrow Agent may earn compensation in the form of short-term interest (“float”) on items like uncashed distribution checks (from the date issued until the date cashed), funds that the Escrow Agent is directed not to invest, deposits awaiting investment direction or received too late to be invested overnight in previously directed investments.

Builders' Lien Holdback Sample Clauses

Filter & Search

Related Clauses

Parent Clauses

Related to Builders' Lien Holdback