Builders Risk/Course of Construction Property Insurance Sample Clauses

Builders Risk/Course of Construction Property Insurance. The Contractor shall, from the date of commencement of the Work until the completion date, and during any part of the access period that Contractor is performing work at the Premises, purchase, provide and maintain, or cause to be purchased, provided and maintained, at its expense, All risks course of construction (builders risks) inclusive of broad form comprehensive boiler and machinery (equipment breakdown) insurance. Such coverage shall be in the name of the Contractor and will show Owner, Consultant, and all Subcontractors of any tier engaged in the project as additional insured in an amount not less than the full replacement cost value of the project. The policy shall be no more restrictive than the IBC 4042 or 4047 policy, including the appropriate CCDC endorsements. The policy shall contain no exclusion for loss or damage caused by the perils of flood or earth movement, including earthquake. The policy shall provide replacement cost coverage on all property including that used in or pertaining to site preparation, demolition of existing structures, erection and/or fabrication and/or reconstruction and/or repair of the insured project while on site, off site or in transit. The policy shall be extended to cover soft costs, delayed rents/delay in start-up (24 months minimum), interest, advertising costs and rental commissions when the loss is caused by an insured risk. Such policy shall include a waiver by the insurer of any rights of subrogation against Owner, its trustees, directors, officers, employees, servants, agents, and the Consultant.
Sample 1Sample 2Sample 3See All (8)
AutoNDA by SimpleDocs

Related to Builders Risk/Course of Construction Property Insurance

  • All Risk Property Insurance (i) During construction, an All Risk Property insurance policy including earthquake and flood (with sublimits as appropriate) shall be maintained during the course of Work being performed and include Start-up and testing for installed equipment and delayed opening coverage. Such policy shall include coverage for materials and equipment while under the care, custody and control of the Seller during the course of Work, at the Site, offsite or while in transit to the Site.

  • Personal Property Insurance Lessee shall obtain, at Lessee's sole cost and expense, a policy of fire and extended coverage insurance including coverage for direct physical loss special form, and a sprinkler leakage endorsement insuring the personal property of Lessee. The proceeds from any personal property damage policy shall be payable to Lessee. All insurance policies required in 6 C) and 6 D) above shall: (i) provide for a certificate of insurance evidencing the insurance required herein, being deposited with Lessor ten (10) days prior to the Commencement Date, and upon each renewal, such certificates shall be provided 15 days prior to the expiration date of such coverage, (ii) be in a form reasonably satisfactory to Lessor and shall provide the coverage required by Lessee in this Lease, (iii) be carried with companies with the a Best Rating of A minimum, (iv) specifically provide that such policies shall not be subject to cancellation or reduction of coverage, except after 30 days prior written notice to Lessor, (v) name Lessor, Lessor's lender, and any other party with an insurable interest in the Premises as additional insureds by endorsement to policy, and (vi) shall be primary. Lessee agrees to pay to Lessor, as additional Rent, on demand, the full cost of the insurance policies referenced in 6 A) and 6 B) above as evidenced as insurance xxxxxxxx to Lessor which shall be included in the CAC. If Lessee does not occupy the entire Premises, the insurance premiums shall be allocated to the portion of the Premises occupied by Lessee on a pro-rata square footage or other equitable basis, as determined by Lessor. It is agreed that Lessee's obligation under this paragraph shall be prorated to the reflect the Commencement Date and the end of the Lease Term. Lessor and Lessee hereby waive any rights each may have against the other related to any loss or damage caused to Lessor or Lessee as the case may be, or to the Premises or its contents, and which may arise from any risk covered by fire and extended coverage insurance and those risks required to be covered under Lessee's personal property insurance. The parties shall provide that their respective insurance policies insuring the property or the personal property include a waiver of any right of subrogation which said insurance company may have against Lessor or Lessee, as the case may be.

  • Property Insurance Borrower shall keep the improvements now existing or hereafter erected on the Property insured against loss by fire, hazards included within the term “extended coverage,” and any other hazards including, but not limited to, earthquakes and floods, for which Lender requires insurance. This insurance shall be maintained in the amounts (including deductible levels) and for the periods that Lender requires. What Lender requires pursuant to the preceding sentences can change during the term of the Loan. The insurance carrier providing the insurance shall be chosen by Borrower subject to Xxxxxx’s right to disapprove Borrower’s choice, which right shall not be exercised unreasonably. Lender may require Borrower to pay, in connection with this Loan, either: (a) a one-time charge for flood zone determination, certification and tracking services; or (b) a one-time charge for flood zone determination and certification services and subsequent charges each time remappings or similar changes occur which reasonably might affect such determination or certification. Borrower shall also be responsible for the payment of any fees imposed by the Federal Emergency Management Agency in connection with the review of any flood zone determination resulting from an objection by Borrower. If Borrower fails to maintain any of the coverages described above, Lender may obtain insurance coverage, at Lender’s option and Xxxxxxxx’s expense. Lender is under no obligation to purchase any particular type or amount of coverage. Therefore, such coverage shall cover Lender, but might or might not protect Borrower, Borrower’s equity in the Property, or the contents of the Property, against any risk, hazard or liability and might provide greater or lesser coverage than was previously in effect. Borrower acknowledges that the cost of the insurance coverage so obtained might significantly exceed the cost of insurance that Borrower could have obtained. Any amounts disbursed by Xxxxxx under this Section 5 shall become additional debt of Borrower secured by this Security Instrument. These amounts shall bear interest at the Note rate from the date of disbursement and shall be payable, with such interest, upon notice from Lender to Borrower requesting payment. All insurance policies required by Xxxxxx and renewals of such policies shall be subject to Xxxxxx’s right to disapprove such policies, shall include a standard mortgage clause, and shall name Xxxxxx as mortgagee and/or as an additional loss payee. Lender shall have the right to hold the policies and renewal certificates. If Lender requires, Borrower shall promptly give to Lender all receipts of paid premiums and renewal notices. If Borrower obtains any form of insurance coverage, not otherwise required by Lender, for damage to, or destruction of, the Property, such policy shall include a standard mortgage clause and shall name Xxxxxx as mortgagee and/or as an additional loss payee. In the event of loss, Borrower shall give prompt notice to the insurance carrier and Lender. Lender may make proof of loss if not made promptly by Xxxxxxxx. Unless Lender and Borrower otherwise agree in writing, any insurance proceeds, whether or not the underlying insurance was required by Lender, shall be applied to restoration or repair of the Property, if the restoration or repair is economically feasible and Lender’s security is not lessened. During such repair and restoration period, Lender shall have the right to hold such insurance proceeds until Xxxxxx has had an opportunity to inspect such Property to ensure the work has been completed to Lender’s satisfaction, provided that such inspection shall be undertaken promptly. Lender may disburse proceeds for the repairs and restoration in a single payment or in a series of progress payments as the work is completed. Unless an agreement is made in writing or Applicable Law requires interest to be paid on such insurance proceeds, Lender shall not be required to pay Borrower any interest or earnings on such proceeds. Fees for public adjusters, or other third parties, retained by Borrower shall not be paid out of the insurance proceeds and shall be the sole obligation of Borrower. If the restoration or repair is not economically feasible or Lender’s security would be lessened, the insurance proceeds shall be applied to the sums secured by this Security Instrument, whether or not then due, with the excess, if any, paid to Borrower. Such insurance proceeds shall be applied in the order provided for in Section 2. If Xxxxxxxx abandons the Property, Lender may file, negotiate and settle any available insurance claim and related matters. If Xxxxxxxx does not respond within 30 days to a notice from Lender that the insurance carrier has offered to settle a claim, then Xxxxxx may negotiate and settle the claim. The 30-day period will begin when the notice is given. In either event, or if Lender acquires the Property under Section 22 or otherwise, Borrower hereby assigns to Lender (a) Borrower’s rights to any insurance proceeds in an amount not to exceed the amounts unpaid under the Note or this Security Instrument, and (b) any other of Borrower’s rights (other than the right to any refund of unearned premiums paid by Borrower) under all insurance policies covering the Property, insofar as such rights are applicable to the coverage of the Property. Lender may use the insurance proceeds either to repair or restore the Property or to pay amounts unpaid under the Note or this Security Instrument, whether or not then due.

  • Insurance, Subcontractor's Public Liability and Property Damage The Contractor shall require each of its subcontractors to secure and maintain during the life of the subcontract, insurance of the type specified in this Contract, or, the Contractor may insure the activities of its subcontractors in the Contractor’s policy, as specified in this Contract.

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • The General Liability and Property Damage coverages required for performance of this Agreement shall include the State of Vermont and its agencies, departments, officers and employees as Additional Insureds. If performance of this Agreement involves construction, or the transport of persons or hazardous materials, then the required Automotive Liability coverage shall include the State of Vermont and its agencies, departments, officers and employees as Additional Insureds. Coverage shall be primary and non-contributory with any other insurance and self-insurance.

  • Maintenance of Property; Insurance (a) Keep all property useful and necessary in its business in good working order and condition, ordinary wear and tear excepted and (b) maintain with financially sound and reputable insurance companies insurance on all its property in at least such amounts and against at least such risks (but including in any event public liability, product liability and business interruption) as are usually insured against in the same general area by companies engaged in the same or a similar business.

  • CONTRACTOR’S INSURANCE REQUIREMENTS The insurance requirements of this Contract are set forth in Appendix J and, if applicable, Appendix J.

  • General Liability and Property Damage With respect to all operations performed under this Agreement, the Party shall carry general liability insurance having all major divisions of coverage including, but not limited to:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!