Delivery Schedule The Goods specified in the List of Goods are required to be delivered within the acceptable time range (after the earliest and before the final date, both dates inclusive) specified in Section V, Schedule of Requirements. No credit will be given to deliveries before the earliest date, and Tenders offering delivery after the final date shall be treated as non-responsive. Within this acceptable period, an adjustment of [insert the adjustment factor], will be added, for evaluation purposes only, to the Tender price of Tenders offering deliveries later than the “Earliest Delivery Date” specified in Section V, Schedule of Requirements.
DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
Equipment Specifications All equipment must meet the contract specifications and all federal and State safety codes and regulations in effect at the date of manufacture. All equipment must be Original Equipment Manufacturer (OEM) equipment unless otherwise stated in the contract. All products, materials, supplies, replacement parts, and equipment offered and furnished must be new, of current manufacturer production, and must have been formally announced by the manufacturer as being commercially available, unless otherwise stated in this Contract.
ESTIMATED / SPECIFIC QUANTITY CONTRACTS Estimated quantity contracts, also referred to as indefinite delivery / indefinite quantity contracts, are expressly agreed and understood to be made for only the quantities, if any, actually ordered during the Contract term. No guarantee of any quantity is implied or given. With respect to any specific quantity stated in the contract, the Commissioner reserves the right after award to order up to 20% more or less (rounded to the next highest whole number) than the specific quantities called for in the Contract. Notwithstanding the foregoing, the Commissioner may purchase greater or lesser percentages of Contract quantities should the Commissioner and Contractor so agree. Such agreement may include an equitable price adjustment.
ODUF Packing Specifications 6.3.1 A pack will contain a minimum of one message record or a maximum of 99,999 message records plus a pack header record and a pack trailer record. One transmission can contain a maximum of 99 packs and a minimum of one pack.
DELIVERY SCHEDULES In accordance with the "Non-State Agencies Participation in Centralized Contracts” and “Extension of Use” clauses herein, this Contract is extended to local governments, political subdivisions and others authorized by law as well as State agencies. The Delivery Schedules (based on Requirement Letter RL182) are available as a guide to indicate proposed delivery points and estimated annual requirements. Delivery Schedules may be revised or clarified as necessary. Any specific questions regarding the site conditions should be directed to the end-user at the telephone number shown on the Delivery Schedule. The Delivery Schedules are available upon request. Contractors shall be obligated to deliver under the Contract to any State agency which places a purchase order under the Contract, whether or not such delivery location is identified in the Delivery Schedules. Any political subdivision or other non-State entity which has not filed a requirement with OGS as of the date of the bid opening shall be eligible to receive deliveries at Contractor's option only, upon placement of a valid purchase order to the Contractor's address as indicated in the award. Contracts created by OGS in response to receipt of Filed Requirements are considered to be binding. At Contractor's request, Contractor will be advised in writing regarding political subdivisions or other Non-State entities which have filed on a timely basis but do not appear on the Delivery Schedule. Where “Standby” is indicated in the Delivery Schedule, this reflects those facilities which normally use a fuel supply (i.e. natural gas) other than fuel oil and will only use fuel oil when alternate fuel is unavailable.
All new supplies equipment and services shall include manufacturer's minimum standard warranty unless otherwise agreed to in writing. Vendor shall be legally permitted to sell all products offered for sale to TIPS Members. All goods proposed and sold shall be new unless clearly stated in writing. The Vendor shall provide timely and accurate customer support for orders to TIPS Members as agreed by the Parties. Vendors shall respond to such requests within a commercially reasonable time after receipt of the request. If support andƒor training is a line item sold or packaged with a sale, support shall be as agreed with the TIPS Member. Most TIPS Members are tax exempt and the related laws andƒor regulations of the controlling jurisdiction(s) of the TIPS Member shall apply. No assignment of Agreement may be made without the prior notification of TIPS. Written approval of TIPS shall not be unreasonably withheld. Payment for delivered goods and services can only be made to the awarded Vendor, Vendor designated reseller or vendor assigned company.
Aircraft This peril includes self-propelled missiles and spacecraft.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Packing Specifications 7.3.1 A pack will contain a minimum of one message record or a maximum of 99,999 message records plus a pack header record and a pack trailer record. One transmission can contain a maximum of 99 packs and a minimum of one pack.
