Damages for delay Subject to the provisions of Clause 12.4, if COD does not occur prior to the 91st day after the Scheduled Completion Date, unless the delay is on account of reasons solely attributable to the Authority or due to Force Majeure, the Concessionaire shall pay Damages to the Authority in a sum calculated at the rate of 0.1% (zero point one per cent) of the amount of Performance Security for delay of each day until COD is achieved.
Waiver of Punitive Damages Notwithstanding anything to the contrary contained in this Agreement, the Borrower hereby agrees that it shall not seek from the Lenders or the Administrative Agent punitive, consequential, or indirect damages relating to any such matters under any theory of liability.
No Damages for Delay The Contractor has no claim for monetary damages for delay or hindrances to the Work from any cause, including without limitation any act or omission of the Owner.
Waiver of Consequential Damages, Etc To the fullest extent permitted by applicable law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document or any agreement or instrument contemplated hereby, the transactions contemplated hereby or thereby, any Loan or Letter of Credit or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed to such unintended recipients by such Indemnitee through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.
Waiver of Consequential Damages To the fullest extent permitted by applicable Law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document, the Related Documents or any agreement or instrument contemplated hereby or thereby, the transactions contemplated hereby or thereby, any Term Loan or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed by it through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents, the Related Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.
WAIVER OF SPECIAL DAMAGES THE BORROWER WAIVES, TO THE MAXIMUM EXTENT NOT PROHIBITED BY LAW, ANY RIGHT THE UNDERSIGNED MAY HAVE TO CLAIM OR RECOVER FROM THE BANK IN ANY LEGAL ACTION OR PROCEEDING ANY SPECIAL, EXEMPLARY, PUNITIVE OR CONSEQUENTIAL DAMAGES.
No Waiver by Course of Conduct; Cumulative Remedies No Secured Party shall by any act (except by a written instrument pursuant to Section 8.1), delay, indulgence, omission or otherwise be deemed to have waived any right or remedy hereunder or to have acquiesced in any Default or Event of Default. No failure to exercise, nor any delay in exercising, on the part of any Secured Party, any right, power or privilege hereunder shall operate as a waiver thereof. No single or partial exercise of any right, power or privilege hereunder shall preclude any other or further exercise thereof or the exercise of any other right, power or privilege. A waiver by any Secured Party of any right or remedy hereunder on any one occasion shall not be construed as a bar to any right or remedy which such Secured Party would otherwise have on any future occasion. The rights and remedies herein provided are cumulative, may be exercised singly or concurrently and are not exclusive of any other rights or remedies provided by law.
No Implied Waivers; Cumulative Remedies; Writing Required No course of dealing and no delay or failure of the Agent or any Bank in exercising any right, power, remedy or privilege under this Agreement or any other Loan Document shall affect any other or future exercise thereof or operate as a waiver thereof, nor shall any single or partial exercise thereof or any abandonment or discontinuance of steps to enforce such a right, power, remedy or privilege preclude any further exercise thereof or of any other right, power, remedy or privilege. The rights and remedies of the Agent and the Banks under this Agreement and any other Loan Documents are cumulative and not exclusive of any rights or remedies which they would otherwise have. Any waiver, permit, consent or approval of any kind or character on the part of any Bank of any breach or default under this Agreement or any such waiver of any provision or condition of this Agreement must be in writing and shall be effective only to the extent specifically set forth in such writing.
Limitation of Consequential Damages EXCEPT FOR (A) THIRD PARTY CLAIMS THAT ARE SUBJECT TO INDEMNIFICATION UNDER THIS ARTICLE 10, (B) CLAIMS ARISING OUT OF A PARTY’S WILLFUL MISCONDUCT OR FRAUD UNDER THIS AGREEMENT, (C) A PARTY’S BREACH OF ARTICLE 4, (D) NOVARTIS’ BREACH OF SECTION 6.5, OR (E) CLAIMS ARISING OUT OF A PARTY’S BREACH OF ITS CONFIDENTIALITY OBLIGATIONS UNDER THIS AGREEMENT, NEITHER PARTY NOR ANY OF ITS AFFILIATES WILL BE LIABLE TO THE OTHER PARTY TO THIS AGREEMENT OR ITS AFFILIATES FOR ANY INCIDENTAL, CONSEQUENTIAL, SPECIAL, PUNITIVE OR OTHER INDIRECT DAMAGES OR LOST OR IMPUTED PROFITS OR ROYALTIES, LOST DATA OR COST OF PROCUREMENT OF SUBSTITUTE GOODS OR SERVICES, WHETHER LIABILITY IS ASSERTED IN CONTRACT, TORT (INCLUDING NEGLIGENCE AND STRICT PRODUCT LIABILITY), INDEMNITY OR CONTRIBUTION, AND IRRESPECTIVE OF WHETHER THAT PARTY OR ANY REPRESENTATIVE OF THAT PARTY HAS BEEN ADVISED OF, OR OTHERWISE MIGHT HAVE ANTICIPATED THE POSSIBILITY OF, ANY SUCH LOSS OR DAMAGE.
Lost ADRs, etc In case any ADR shall be mutilated, destroyed, lost, or stolen, the Depositary shall execute and deliver a new ADR of like tenor at the expense of the Holder (a) in the case of a mutilated ADR, in exchange of and substitution for such mutilated ADR upon cancellation thereof, or (b) in the case of a destroyed, lost or stolen ADR, in lieu of and in substitution for such destroyed, lost, or stolen ADR, after the Holder thereof (i) has submitted to the Depositary a written request for such exchange and substitution before the Depositary has notice that the ADR has been acquired by a bona fide purchaser, (ii) has provided such security or indemnity (including an indemnity bond) as may be required by the Depositary to save it and any of its agents harmless, and (iii) has satisfied any other reasonable requirements imposed by the Depositary, including, without limitation, evidence satisfactory to the Depositary of such destruction, loss or theft of such ADR, the authenticity thereof and the Holder’s ownership thereof.
