Binding Dispute Resolution For any Claim subject to, but not resolved by, mediation pursuant to Article 15 of AIA Document A232–2019, the method of binding dispute resolution shall be as follows: [ ] Arbitration pursuant to Article 15 of AIA Document A232–2019. [ X ] Litigation in a court of competent jurisdiction. [ ] Other: (Specify) If the Owner and Contractor do not select a method of binding dispute resolution, or do not subsequently agree in writing to a binding dispute resolution method other than litigation, Claims will be resolved by litigation in a court of competent jurisdiction.
Commencing Dispute Resolution 13.3.1 Dispute Resolution shall commence upon one Party’s receipt of written Notice of a controversy or claim arising out of or relating to this Agreement or its breach. No Party may pursue any claim unless such written Notice has first been given to the other Party. There are three (3) separate Dispute Resolution methods:
13.3.1.1 Service Center Dispute Resolution;
13.3.1.2 Informal Dispute Resolution; and
13.3.1.3 Formal Dispute Resolution, each of which is described below.
Governing Law and Dispute Resolution Procedure 25.1 This Agreement and any dispute or claim (including any non-contractual dispute or claim) arising out of or in connection with it or its subject matter, shall be governed by, and construed in accordance with, the laws of England and Wales.
25.2 Subject to the remainder of this clause 25, the parties irrevocably agree that the courts of England and Wales shall have exclusive jurisdiction to settle any dispute or claim (including any non-contractual dispute or claim) that arises out of or in connection with this Agreement or its subject matter.
25.3 In the event that any claim or dispute arises out of or in connection with this Agreement, the parties shall, following service of written notice by one party on the other, attempt to resolve amicably by way of good faith negotiations and discussions any such dispute or claim as soon as reasonably practicable (and in any event within 14 calendar days after such notice or by such later date as the parties may otherwise agree in writing). If the parties are unable to resolve the dispute or claim in accordance with this clause 25.3, either party may commence proceedings in accordance with clause 25.2.
25.4 Nothing in this clause 25 shall prevent either party from applying at any time to the court for injunctive relief on the grounds of infringement, or threatened infringement, of the other party's obligations of confidentiality contained in this Agreement or infringement, or threatened infringement, of the applicant's Intellectual Property Rights.
Dispute resolution; Attorney’s fees In the event VMLS claims that Firm, Salesperson Party, or Consultant has violated the VMLS Policies, VMLS may, at its option, resolve such a claim according to the disciplinary procedures set out in the VMLS Policies, provided VMLS does not also base a claim that Firm, Salesperson Party, or Consultant has breached this Agreement on the same facts. Except as set forth in the preceding sentence, any controversy or claim to which Consultant is not a party arising out of or relating to this Agreement, or the breach thereof, shall be settled by arbitration administered by the American Arbitration Association under its Commercial Arbitration Rules, including its Optional Rules for Emergency Measures of Protection (collectively, the “Arbitration Rules”), and judgment on the award rendered by the arbitrator(s) may be entered in any court having jurisdiction thereof. The parties irrevocably agree, consent, and submit themselves to personal jurisdiction in the courts of the State of Colorado located in Eagle County or the federal court of the United States situated therein, as applicable, which shall have sole and exclusive jurisdiction over any action under this Agreement not subject to VMLS’s disciplinary procedures or to arbitration. If any party prevails in an action or proceeding to enforce or interpret this Agreement or any provision hereof, it shall be entitled to reasonable attorney’s fees and costs for the legal action.
Governing Law; Dispute Resolution (a) This Limited Guarantee shall be interpreted, construed and governed by and in accordance with the Laws of the State of New York without regard to the conflicts of law principles thereof that would subject such matter to the Laws of another jurisdiction other than the State of New York.
(b) Any disputes, actions and proceedings against any party or arising out of or in any way relating to this Limited Guarantee shall be submitted to the Hong Kong International Arbitration Centre (the “HKIAC”) and resolved in accordance with the Arbitration Rules of HKIAC in force at the relevant time (the “Rules”) and as may be amended by this Section 10(b). The place of arbitration shall be Hong Kong. The official language of the arbitration shall be English and the arbitration tribunal shall consist of three arbitrators (each, an “Arbitrator”). The claimant(s), irrespective of number, shall nominate jointly one Arbitrator; the respondent(s), irrespective of number, shall nominate jointly one Arbitrator; and a third Arbitrator will be nominated jointly by the first two Arbitrators and shall serve as chairman of the arbitration tribunal. In the event the claimant(s) or respondent(s) or the first two Arbitrators shall fail to nominate or agree on the joint nomination of an Arbitrator or the third Arbitrator within the time limits specified by the Rules, such Arbitrator shall be appointed promptly by the HKIAC. The arbitration tribunal shall have no authority to award punitive or other punitive-type damages. The award of the arbitration tribunal shall be final and binding upon the disputing parties. Any party to an award may apply to any court of competent jurisdiction for enforcement of such award and, for purposes of the enforcement of such award, the parties irrevocably and unconditionally submit to the jurisdiction of any court of competent jurisdiction and waive any defenses to such enforcement based on lack of personal jurisdiction or inconvenient forum.
(c) Notwithstanding the foregoing, the parties hereto consent to and agree that in addition to any recourse to arbitration as set out in Section 10(b), any party may, to the extent permitted under the Laws of the jurisdiction where application is made, seek an interim injunction from a court or other authority with competent jurisdiction and, notwithstanding that this Agreement is governed by the Laws of the State of New York, a court or authority hearing an application for injunctive relief may apply the procedural Law of the jurisdiction where the court or other authority is located in determining whether to grant the interim injunction. For the avoidance of doubt, this Section 10(c) is only applicable to the seeking of interim injunctions and does not restrict the application of Section 10(b) in any way.
Dispute Resolution Mandatory Arbitration Class Action Waiver SAMPLE
(a) Claims Subject to Arbitration. Except as expressly provided below, the parties agree that to the fullest extent permitted by applicable law, any dispute arising out of or relating in any way to this Agreement or a similar prior agreement, the Property or the relationship between Resident and Owner or Manager (including matters occurring prior to the date of this Agreement and disputes also involving third parties) (collectively, “Claims”) will, at the election of either party, be resolved by arbitration, including any dispute about arbitrability, such as scope and enforceability.
Resolving Disputes The Company and the customer will use all reasonable endeavours to resolve any dispute between them. If they cannot resolve their dispute between them, they will:-
a. Refer the dispute to mediation which will be conducted in accordance with the Resolution Institute New Zealand Standard Mediation Agreement; and
b. If mediation is unsuccessful, the matter of dispute shall be referred to a single arbitrator in accordance with the provisions contained in the Arbitration Xxx 0000 and any amendments. Nothing in this clause will preclude either party from taking immediate steps to seek urgent equitable relief before an appropriate Court.
Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. 5 5 Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. 6
Informal Dispute Resolution Process 1. In the event there is a dispute under this Centralized Contract, the Contractor, OGS and Authorized User agree to exercise their best efforts to resolve the dispute as soon as possible. The Contractor, OGS and Authorized User shall, without delay, continue to perform their respective obligations under this Centralized Contract which are not affected by the dispute. Primary responsibility for resolving any dispute arising under this Centralized Contract shall rest with the Authorized User’s Contractor Coordinators and the Contractor’s Account Executive and the State & Local Government Regional General Manager.
2. In the event the Authorized User is dissatisfied with the Contractor’s Products provided under this Centralized Contract, the Authorized User shall notify the Contractor in writing pursuant to the terms of the Contract. In the event the Contractor has any disputes with the Authorized User, the Contractor shall so notify the Authorized User in writing. If either party notifies the other of such dispute, the other party shall then make good faith efforts to solve the problem or settle the dispute amicably, including meeting with the party’s representatives to attempt diligently to reach a satisfactory result through negotiation.
3. If negotiation between the Contractor and Authorized User fails to resolve any such dispute to the satisfaction of the parties within fourteen (14) business days or as otherwise agreed to by the Contractor and Authorized User, of such notice, then the matter shall be submitted to the State's Contract Administrator and the Contractor’s senior executive officer representative. Such representatives shall meet in person and shall attempt in good faith to resolve the dispute within the next fourteen (14) business days or as otherwise agreed to by the parties. This meeting must be held before either party may seek any other method of dispute resolution, including judicial or governmental resolutions. Notwithstanding the foregoing, this section shall not be construed to prevent either party from seeking and obtaining temporary equitable remedies, including injunctive relief.
4. The Contractor shall extend the informal dispute resolution period for so long as the Authorized User continues to make reasonable efforts to cure the breach, except with respect to disputes about the breach of payment of fees or infringement of its or its licensors’ intellectual property rights.
Termination Procedures and Compensation During Dispute 7.1. After a Change in Control and during the term of this Agreement, any purported termination of the Executive's employment (other than by reason of death) shall be communicated by written Notice of Termination from one party hereto to the other party hereto in accordance with Section 10 hereof. For purposes of this Agreement, a "Notice of Termination" shall mean a notice which shall indicate the specific termination provision in this Agreement relied upon and shall set forth in reasonable detail the facts and circumstances claimed to provide a basis for termination of the Executive's employment under the provision so indicated. Further, a Notice of Termination for Cause issued by the Company is required to include a copy of a resolution duly adopted by the affirmative vote of not less than three-quarters (3/4) of the entire membership of the Board at a meeting of the Board which was called and held for the purpose of considering such termination (after reasonable notice to the Executive and an opportunity for the Executive, together with the Executive's Counsel, to be heard before the Board) finding that, in the good faith opinion of the Board, the Executive engaged in conduct set forth in clause (i) or (ii) of the definition of Cause herein, and specifying the particulars thereof in detail.
