SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work. 4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work. 4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. 4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents. 4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. 4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof. 4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals. 4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
MSAA Indicator Technical Specification Document This Agreement shall be interpreted with reference to the MSAA Indicator Technical Specifications document.
Signaling Link Transport 9.2.1 Signaling Link Transport is a set of two or four dedicated 56 kbps transmission paths between Global Connection-designated Signaling Points of Interconnection that provide appropriate physical diversity.
Loop Provisioning Involving Integrated Digital Loop Carriers 2.6.1 Where Xxxx has requested an Unbundled Loop and BellSouth uses IDLC systems to provide the local service to the End User and BellSouth has a suitable alternate facility available, BellSouth will make such alternative facilities available to Xxxx. If a suitable alternative facility is not available, then to the extent it is technically feasible, BellSouth will implement one of the following alternative arrangements for Xxxx (e.g. hairpinning): 1. Roll the circuit(s) from the IDLC to any spare copper that exists to the customer premises. 2. Roll the circuit(s) from the IDLC to an existing DLC that is not integrated. 3. If capacity exists, provide "side-door" porting through the switch. 4. If capacity exists, provide "Digital Access Cross Connect System (DACS)- door" porting (if the IDLC routes through a DACS prior to integration into the switch). 2.6.2 Arrangements 3 and 4 above require the use of a designed circuit. Therefore, non- designed Loops such as the SL1 voice grade and UCL-ND may not be ordered in these cases. 2.6.3 If no alternate facility is available, and upon request from Xxxx, and if agreed to by both Parties, BellSouth may utilize its Special Construction (SC) process to determine the additional costs required to provision facilities. Xxxx will then have the option of paying the one-time SC rates to place the Loop.
Product Specifications (a) Supplier shall manufacture all Products according to the Specifications in effect as of the date of this Agreement, with such changes or additions to the Specifications of the Products related thereto as shall be requested by Buyer in accordance with this Section or as otherwise agreed in writing by the Parties. All other Products shall be manufactured with such Specifications as the Parties shall agree in writing. (b) Buyer may request changed or additional Specifications for any Product by delivering written notice thereof to Supplier not less than one hundred twenty (120) days in advance of the first Firm Order for such Product to be supplied with such changed or additional Specifications. Notwithstanding the foregoing, if additional advance time would reasonably be required in order to implement the manufacturing processes for production of a Product with any changed or additional Specifications, and to commence manufacture and delivery thereof, Supplier shall so notify Buyer, and Supplier shall not be required to commence delivery of such Product until the passage of such additional time. (c) Supplier shall be required to accommodate any change of, or additions to, the Specifications for any Product, if and only if (i) in Supplier’s good faith judgment, such changed or additional Specifications would not require Supplier to violate good manufacturing practice, (ii) the representation and warranty of Buyer deemed made pursuant to Subsection (e) below is true and correct, and (iii) Buyer agrees to reimburse Supplier for the incremental costs and expenses incurred by Supplier in accommodating the changed or additional Specifications, including the costs of acquiring any new machinery and tooling. For the avoidance of doubt, such costs and expenses shall be payable by Buyer separately from the cost of Products at such time or times as Supplier shall request. (d) Supplier shall notify Buyer in writing within thirty (30) days of its receipt of any request for changed or additional Specifications (i) whether Supplier will honor such changed or additional Specifications, (ii) if Supplier declines to honor such changed or additional Specifications, the basis therefor and (iii) if applicable, the estimated costs and expenses that Buyer will be required to reimburse Supplier in respect of the requested changes or additions, as provided in Subsection (c) above. Buyer shall notify Supplier in writing within fifteen (15) days after receiving notice of any required reimbursement whether Buyer agrees to assume such reimbursement obligation. (e) By its request for any changed or additional Specifications for any Product, Buyer shall be deemed to represent and warrant to Supplier that the manufacture and sale of the Product incorporating Buyer’s changed or additional Specifications, as a result of such incorporation, will not and could not reasonably be expected to (i) violate or conflict with any contract, agreement, arrangement or understanding to which Buyer and/or any of its Affiliates is a party, including this Agreement and any other contract, agreement, arrangement or understanding with Supplier and/or its Affiliates, (ii) infringe on any trademark, service xxxx, copyright, patent, trade secret or other intellectual property rights of any Person, or (iii) violate any Applicable Law. Buyer shall indemnify and hold Supplier and its Affiliates harmless (including with respect to reasonable attorneys’ fees and disbursements) from any breach of this representation and warranty.
RE-WEIGHING PRODUCT Deliveries are subject to re- weighing at the point of destination by the Authorized User. If shrinkage occurs which exceeds that normally allowable in the trade, the Authorized User shall have the option to require delivery of the difference in quantity or to reduce the payment accordingly. Such option shall be exercised in writing by the Authorized User.
OPEN SOURCE COMPONENTS The DS Offerings may include open source components. Whenever notices (such as acknowledgment, copies of licenses or attribution notice) are required by the original licensor, such notices are included in the Documentation of the DS Offerings. Moreover, some open source components may not be distributed and licensed under the terms of the Agreement but under the terms of their original licenses as set forth in the Documentation of the DS Offerings themselves. Source code for open source software components is available upon request. Except for components mentioned in the section EXCLUSIONS below, the warranty and indemnification provided by DS under the Agreement apply to all open source software components and shall be provided by DS and not by the original licensor, but only for the use of the DS Offerings that is in compliance with the terms of the Agreement, and in conjunction with the DS Offerings. The original licensors of said open source software components provide them on an “as is” basis and without any liability whatsoever to Customer.
Tandem Transit Traffic 12.1 As used in this Section, Tandem Transit Traffic is Telephone Exchange Service traffic that originates on Onvoy's network, and is transported through Frontier’s Tandem to the subtending End Office or its equivalent of another carrier (CLEC, ILEC other than Frontier, Commercial Mobile Radio Service (CMRS) carrier, or other LEC (“Other Carrier”). Neither the originating nor terminating customer is a Customer of Frontier. Subtending End Offices shall be determined in accordance with and as identified in the Local Exchange Routing Guide (LERG). For the avoidance of any doubt, under no circumstances shall Frontier be required to transit traffic through a Frontier Tandem to a Central Office that the LERG does not identify as subtending that particular Frontier Tandem. Switched Exchange Access Service traffic is not Tandem Transit Traffic. 12.2 Tandem Transit Traffic Service provides Onvoy with the transport of Tandem Transit Traffic as provided below. 12.3 Tandem Transit Traffic may be routed over the Interconnection Trunks described in Sections 2 through 6 of this Attachment. Onvoy shall deliver each Tandem Transit Traffic call to Frontier’s Tandem with CCS and the appropriate Transactional Capabilities Application Part (“TCAP”) message to facilitate full interoperability of CLASS Features and billing functions. 12.4 Onvoy may use Tandem Transit Traffic Service only for traffic that originates on Onvoy’s network and only to send traffic to an Other Carrier with whom Onvoy has a reciprocal traffic exchange arrangement (either via written agreement or mutual tariffs) that provides for the Other Carrier, to terminate or complete traffic originated by Onvoy and to bill Onvoy, and not to bill Frontier, for such traffic. Onvoy agrees not to use Frontier’s Tandem Transit Traffic Service to send traffic to an Other Carrier with whom Onvoy does not have such a reciprocal traffic exchange arrangement or to send traffic that does not originate on Onvoy’s network. 12.5 Onvoy shall pay Frontier for Tandem Transit Traffic Service at the rates specified in the Pricing Attachment. Frontier will not be liable for compensation to any Other Carrier for any traffic that is transported through Frontier’s Tandem and Frontier reserves the right to assess to Onvoy any additional charges or costs any Other Carrier imposes or levies on Frontier for the delivery or termination of such traffic, including any Switched Exchange Access Service charges. If Frontier is billed by any Other Carrier for any traffic originated by Onvoy, Frontier may provide notice to Onvoy of such billing. Upon receipt of such notice, Onvoy shall immediately stop using Frontier’s Tandem Transit Traffic Service to send any traffic to such Other Carrier until it has provided to Frontier certification that the Other Carrier has removed such billed charges from its bill to Frontier and that the Other Carrier will not bill Frontier for any traffic originated by Onvoy. Such certification must be signed by an authorized officer or agent of the Other Carrier and must be in a form acceptable to Frontier. 12.6 If Onvoy uses Tandem Transit Traffic Service for traffic volumes that exceed the Centum Call Seconds (Hundred Call Seconds) busy hour equivalent of 200,000 combined minutes of use per month (a DS1 equivalent) to the subtending End Office of a particular Other Carrier for any month (the “Threshold Level”). Onvoy shall use good faith efforts to establish direct interconnection with such Other Carrier and reduce such traffic volumes below the Threshold Level. If Frontier believes that Xxxxx has not exercised good faith efforts promptly to obtain such direct interconnection, either Party may use the Dispute Resolution processes of this Agreement. 12.7 If Onvoy fails to comply with Section 12 of this Attachment, such failure shall be a material breach of a material provision of this Agreement and Frontier may exercise any and all remedies under this Agreement and Applicable Law for such breach. 12.8 If or when a third party carrier plans to subtend an Onvoy switch, then Onvoy shall provide written notice to Frontier at least ninety (90) days before such subtending service arrangement becomes effective so that Frontier may negotiate and establish direct interconnection with such third party carrier. Upon written request from Frontier, Onvoy shall offer to Frontier a service arrangement equivalent to or the same as Tandem Transit Traffic Service provided by Frontier to Onvoy as defined in this Section such that Frontier may terminate calls to a Central Office or its equivalent of a CLEC, ILEC other than Frontier, CMRS carrier, or other LEC, that subtends an Onvoy Central Office or its equivalent (“Reciprocal Tandem Transit Service”). Onvoy shall offer such Reciprocal Transit Service arrangements under terms and conditions of an amendment to this Agreement or a separate agreement no less favorable than those provided in this Section. 12.9 Neither Party shall take any actions to prevent the other Party from entering into a direct and reciprocal traffic exchange arrangement with any carrier to which it originates, or from which it terminates, traffic.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
API If the Software offers integration capabilities via an API, your use of the API may be subject to additional costs or Sage specific policies and terms and conditions (which shall prevail in relation to your use of the API). You may not access or use the API in any way that could cause damage to us or the Software, or in contravention of any applicable laws. We reserve the right in our sole discretion, to: (i) update any API from time to time; (ii) place limitations around your use of any API; and (iii) deny you access to any API in the event of misuse by you or to otherwise protect our legitimate interests.