City's Remedies for Concessionaire's Default Sample Clauses

City's Remedies for Concessionaire's Default. If any of the events of default, as set forth in this Section, shall occur, the City may, after expiration of the cure periods, as provided above, at its sole option and discretion, institute such proceedings as in its opinion are necessary to cure such defaults and to compensate City for damages resulting from such defaults, including but not limited to the right to give to Concessionaire a notice of termination of this Agreement. If such notice is given, the term of this Agreement shall terminate upon the date specified in such notice from City to Concessionaire. On the date so specified, Concessionaire shall then quit and surrender the Concession Area(s) to City pursuant to the provisions of Subsection 13.7. Upon the termination of this Agreement, all rights and interest of Concessionaire in and to the Concession Area(s) and to this Agreement, and every part thereof, shall cease and terminate and City may, in addition to any other rights and remedies it may have, retain all sums paid to it by Concessionaire under this Agreement, including but not limited to, the Performance Bond in Section 15 herein. In addition to the rights set forth above, the City shall have the rights to pursue any and all of the following:
Sample 1
AutoNDA by SimpleDocs
City's Remedies for Concessionaire's Default. If any of the events of default by Concessionaire as set forth in this Section shall occur, the City may, after notice (if required) and the expiration of cure periods, as provided above, at its sole option and discretion, institute such proceedings as in its opinion are necessary to cure such defaults and to compensate City for damages resulting from such defaults, including but not limited to the right to give to Concessionaire a notice of termination of this Agreement. If such notice is given, the Term of this Agreement shall terminate upon the date specified in such notice from City to Concessionaire. On the date so specified, Concessionaire shall then quit and surrender the Concession Area(s) to City pursuant to the provisions of Subsection 13.7. Upon the termination of this Agreement, all rights and interest of Concessionaire in and to the Concession Area(s) and to this Agreement, and every part thereof, shall cease and terminate and City may, in addition to any other rights and remedies it may have, retain all sums paid to it by Concessionaire under this Agreement, including but not limited to, beginning procedures to collect the Security Deposit, as provided in Section 14 herein. In addition to the rights set forth above, City shall have the rights to pursue any and all of the following: a. the right to injunction or other similar relief available to it under Florida law against Concessionaire; and or b. the right to maintain any and all actions at law or suits in equity or other proper proceedings to obtain damages resulting from Concessionaire's default. 13.5 If an event of default, as set forth in this Section, by the City shall occur, the Concessionaire may, after notice (if required) and the expiration of the cure periods, as provided above, at its sole option and discretion, terminate this Agreement upon written notice to the City and /or xxx for damages. Said termination shall become effective upon receipt of a written notice of termination by the City, but in no event shall Concessionaire specify a termination date that is less than sixty (60) days from the date of the written termination notice. On the date specified in the notice, Concessionaire shall quit and surrender the Concession Areas to City pursuant to the provisions of Subsection 13.7. 13.7
Sample 1

Related to City's Remedies for Concessionaire's Default

  • Remedies for Default (a) Enterprise Services’ rights to suspend and terminate Contractor’s rights under this Master Contract are in addition to all other available remedies.

  • Remedies for Contractor Breach Pertaining to contract-related issues, it is the responsibility of both the Agency and the Contractor to communicate with each in as clear and complete a manner as possible. If at any time during the term of this contract the Agency or the Contractor is not satisfied with any issue, it is the responsibility of that party to deliver to the other party communication, in writing, fully detailing the issue and corrective action (please note that the Agency has the right to issue unilateral addendums to this contract, but the Contractor does not have the same right). The other party shall, within 10 days, respond in writing to the other party (however, the Agency shall retain the right to, if conditions warrant, require the Contractor to respond in a shorter period of time). Further, the Agency shall, at a minimum, employ the following steps in dealing with the Contractor as to any performance issues:

  • City’s Remedies In addition to any other remedies the City may have upon Developer and/or Developer’s contractor for the failure to provide and maintain insurance or policy endorsements to the extent and within the time required, the City shall have the right, to order Developer to stop work, and/or withhold any payment(s), which become due until Developer and/or Developer’s contractor demonstrates compliance with the requirements.

  • REMEDIES OF THE PARTIES A. If BUYERS fail to timely perform this Agreement, SELLERS may forfeit it as provided in the Iowa Code (Chapter 656), and all payments made shall be forfeited; or, at SELLERS' option, upon thirty days written notice of intention to accelerate the payment of the entire balance because of BUYERS' default (during which thirty days the default is not corrected), SELLERS may declare the entire balance immediately due and payable. Thereafter this agreement may be foreclosed in equity and the Court may appoint a receiver.

  • Breach and Remedies for Breach 14 10.1 Liquidated Damages Schedule and Schedule Amendments.

  • Authority’s Remedies In the event of any of the foregoing events of default enumerated in this Article, and following 30 days’ notice by Authority and Company’s failure to cure, Authority, at its election, may exercise any one or more of the following options or remedies, the exercise of any of which will not be deemed to preclude the exercise of any other remedy herein listed or otherwise provided by statute or general law:

  • Exclusive Remedies Subject to Section 9.12, the parties acknowledge and agree that their sole and exclusive remedy with respect to any and all claims (other than claims arising from intentional fraud on the part of a party hereto in connection with the transactions contemplated by this Agreement) for any breach of any representation, warranty, covenant, agreement or obligation set forth herein or otherwise relating to the subject matter of this Agreement, shall be pursuant to the indemnification provisions set forth in this ARTICLE VII. In furtherance of the foregoing, each party hereby waives, to the fullest extent permitted under the law, any and all rights, claims and causes of action for any breach of any representation, warranty, covenant, agreement or obligation set forth herein or otherwise relating to the subject matter of this Agreement it may have against the other parties hereto and their affiliates and each of their respective representatives arising under or based upon any law, rule or regulation, except pursuant to the indemnification provisions set forth in this ARTICLE VII. Nothing in this Section 7.05 shall limit any person’s right to seek and obtain any equitable relief to which any person shall be entitled pursuant to Section 9.12 or to seek any remedy on account of any intentional fraud by any party hereto.

  • BREACH; REMEDIES Notwithstanding anything to the contrary in this Agreement, the Participant agrees and acknowledges that the breach of this Section would cause substantial loss to the goodwill of the Company and/or its Affiliates, and cause irreparable harm for which there is no adequate remedy at law. Further, because the Participant’s employment with the Employer is personal and unique, because damages alone would not be an adequate remedy and because of the Participant’s access to the Confidential Information, the Company and/or its Affiliates shall have the right to enforce this Section, including any of its provisions, by injunction, specific performance, or other equitable relief, without having to post bond or prove actual damages, and without prejudice to any other rights and remedies that the Company and/or its Affiliates may have for a breach of this Section, including, without limitation, money damages. The Participant agrees and acknowledges that notwithstanding the arbitration provisions in this Agreement, the Company may elect to file and pursue claims which arise from or relate to the Participant’s actual or threatened breaches of this Section in state or federal court of competent jurisdiction. The Participant shall be liable to pay all costs, including reasonable attorneys’ and experts’ fees and expenses, that the Company and/or its Affiliates may incur in enforcing or defending this Section, whether or not litigation is actually commenced and including litigation of any appeal taken or defended by the Company and/or its Affiliates where the Company and/or its Affiliates succeed in enforcing any provision of this Section.

  • Event of Breach Remedies 14.1. Event of Breach by Contractor. Any one or more of the following Contractor acts or omissions constitute an event of material breach under this Contract:

  • Breach; STATE’s Remedies If PURCHASER fails to remedy a violation within the time allowed and as instructed by STATE, or if PURCHASER fails to complete work as required within any interim contract completion date or by the contract expiration date, PURCHASER is in breach, and STATE may pursue any and all remedies available to STATE. Such remedies include, but are not limited to: (1) making a claim on each bond provided by PURCHASER; (2) suing PURCHASER for all damages STATE incurs as a result of PURCHASER's breach; (3) suing PURCHASER for specific performance of the contract; (4) terminating the contract and reselling the breached contract; and (5) declaring PURCHASER in default, in accordance with the provisions of OAR 629- 032-0000 through 0070 (as adopted at the time of contracting and as may be amended later by the agency having jurisdiction or authority over such activities). The provisions of OAR 629-032-0000 through 0070, and any future amendments, are incorporated into this contract and made a permanent part hereof by reference as though fully set forth herein. THE PROVISIONS OF OAR 629-032-0000 THROUGH 0070 ARE IN ADDITION TO, AND NOT IN LIEU OF, ANY OTHER REMEDIES STATE MAY HAVE FOR THE PURCHASER'S BREACH OF CONTRACT. NOTICES, PLANS, AND INSPECTIONS Section 35. Work Responsibility and Acceptance. Prior to the completion and final acceptance of operations, PURCHASER shall be held responsible for, and shall correct any injury or damage to, the operations or any part of the operations, from any cause whatsoever, unless adjustment is made pursuant to Section 28. STATE shall make final inspection of operations done by PURCHASER within 10 calendar days after written notification is received by STATE from PURCHASER stating that the operation is complete. Following inspection, STATE shall notify PURCHASER of acceptance in writing. If the operation is not acceptable to STATE, STATE shall advise PURCHASER in writing of the particular defects to be remedied before final acceptance by STATE can be made.

Time is Money Join Law Insider Premium to draft better contracts faster.