Claims for $375,000 or Less. In the event of a claim of $375,000 or less, the Parties shall resolve the claim pursuant to Public Contract Code Sections 20104 et seq., summarized herein. A claim is defined as Contractor’s demand for: (i) a time extension; (ii) payment of money or damages arising from work done by, or on behalf of, Contractor pursuant to the Contract and payment of which is not otherwise expressly provided for or the claimant is not otherwise entitled to; or (iii) an amount the payment of which is disputed by County.
Claims for $375,000 or Less. In the event of a claim of $375,000 or less, the Parties shall resolve the claim pursuant to Public Contract Code Sections 20104 et seq., summarized herein. A claim is defined as D-BE’s demand for: (i) a time extension; (ii) payment of money or damages arising from work done by, or on behalf of, D-BE pursuant to the Contract and payment of which is not otherwise expressly provided for or the claimant is not otherwise entitled to; or (iii) an amount the payment of which is disputed by OWNER.
Claims for $375,000 or Less. In the event of a claim of $375,000 or less, the Parties shall resolve the claim pursuant to Public Contract Code Sections 20104 et seq., summarized herein. A claim is defined as XXXX’x demand for: (i) a time extension; (ii) payment of money or damages arising from work done by, or on behalf of, XXXX pursuant to the Contract and payment of which is not otherwise expressly provided for or the claimant is not otherwise entitled to; or (iii) an amount the payment of which is disputed by Owner.
