Continuing Performance during Dispute Resolution Sample Clauses

Continuing Performance during Dispute Resolution. In the event of a claim or dispute between Contractor and COUNTY as to performance of the work, a demand for an extension of time, the interpretation of the Contract Documents, or payment or nonpayment for work performed, Contractor and COUNTY shall attempt to resolve the claim or dispute. Pending resolution of the claim or dispute, Contractor shall continue the work diligently to completion as directed by COUNTY. If the claim or dispute is not resolved, Contractor agrees that it will neither rescind this Contract nor stop the progress of the work. Claims for $375,000 or Less: In the event of a claim of $375,000 or less, the Parties shall resolve the claim pursuant to Public Contract Code Section 20104, et seq., summarized herein. A claim is defined as Contractor’s demand for: (i) a time extension; (ii) payment of money or damages arising from work done by, or on behalf of, Contractor pursuant to the Contract and payment of which is not otherwise expressly provided for or the claimant is not otherwise entitled to; or (iii) an amount the payment of which is disputed by COUNTY.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Continuing Performance during Dispute Resolution. In the event of a claim or dispute between Contractor and County as to performance of the work, a demand for an extension of time, the interpretation of the Contract Documents, or payment or nonpayment for work performed, Contractor and County shall attempt to resolve the claim or dispute. Pending resolution of the claim or dispute, Contractor shall continue the work diligently to completion as directed by County. If the claim or dispute is not resolved, Contractor agrees that it will neither rescind this Contract nor stop the progress of the work.
Sample 1Sample 2
Continuing Performance during Dispute Resolution. In the event of a claim or dispute between D-BE and OWNER as to performance of the work, a demand for an extension of time, the interpretation/implementation of the Contract Documents, or payment or nonpayment for work performed, D-BE and OWNER shall attempt to resolve the claim or dispute. Pending resolution of the claim or dispute, D-BE shall continue the work diligently to completion as directed by OWNER. If the claim or dispute is not resolved, D-BE agrees that it will neither rescind this Contract nor stop the progress of the work.
Sample 1
Continuing Performance during Dispute Resolution. In the event of a claim or dispute between XXXX and Owner as to performance of the work, a demand for an extension of time, the interpretation/implementation of the Contract Documents, or payment or nonpayment for work performed, XXXX and Owner shall attempt to resolve the claim or dispute. Pending resolution of the claim or dispute, XXXX shall continue the work diligently to completion as directed by Owner. If the claim or dispute is not resolved, XXXX agrees that it will neither rescind this Contract nor stop the progress of the work.
Sample 1

Related to Continuing Performance during Dispute Resolution

  • Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 6

  • Customer Service, Dispute Resolution If you have a question about your XOOM charges or service you may contact XOOM directly by calling 0-000-000-0000 Monday – Friday 8 (eight) a.m. to 11 (eleven)p.m.

Time is Money Join Law Insider Premium to draft better contracts faster.