Direct Claims Any Action by an Indemnified Party on account of a Loss which does not result from a Third Party Claim (a “Direct Claim”) shall be asserted by the Indemnified Party giving the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than 30 days after the Indemnified Party becomes aware of such Direct Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Direct Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have 30 days after its receipt of such notice to respond in writing to such Direct Claim. The Indemnified Party shall allow the Indemnifying Party and its professional advisors to investigate the matter or circumstance alleged to give rise to the Direct Claim, and whether and to what extent any amount is payable in respect of the Direct Claim and the Indemnified Party shall assist the Indemnifying Party’s investigation by giving such information and assistance (including access to the Company’s premises and personnel and the right to examine and copy any accounts, documents or records) as the Indemnifying Party or any of its professional advisors may reasonably request. If the Indemnifying Party does not so respond within such 30 day period, the Indemnifying Party shall be deemed to have rejected such claim, in which case the Indemnified Party shall be free to pursue such remedies as may be available to the Indemnified Party on the terms and subject to the provisions of this Agreement.
NOTICE OF THIRD PARTY CLAIMS Pursuant to Public Contract Code Section 9201, District shall provide Contractor timely notification of the receipt of any third-party claim relating to this Contract. District shall be entitled to recover its reasonable costs incurred in providing such notification.
Claims Excluded from Arbitration The following matters will not be subject to arbitration but will instead be adjudicated in the courts of Xxxxxx County, Texas or such other court in which jurisdiction and venue are proper: (a) an action for possession or for injunctive remedies provided under applicable landlord-tenant laws or to enforce intellectual property rights; (b) a suit by Owner or its assignee for collection of amounts owed by Resident under this Agreement; and (c) any claim or dispute for which applicable law (as determined by a binding court decision) or the applicable arbitration rules do not permit arbitration and require adjudication in a specific civil court. Matters within the jurisdiction of an applicable small claims court may also be brought in that court in lieu of arbitration.
Third Party Liability 23.1 For the purposes of the Contracts (Rights of Third Parties) Xxx 0000 this Agreement is not intended to, and does not, give any person who is not a party to it any right to enforce any of its provisions.
Excluded Claims Notwithstanding the foregoing, the following are not included in the Released Claims (the “Excluded Claims”): (i) any rights or claims for indemnification you may have pursuant to any written indemnification agreement with the Company to which you are a party, the charter, bylaws, or operating agreements of the Company, or under applicable law; (ii) any rights which are not waivable as a matter of law; and (iii) any claims for breach of this Agreement. In addition, nothing in this Agreement prevents you from filing, cooperating with, or participating in any proceeding before the Equal Employment Opportunity Commission, the Department of Labor, or any other government agency, except that you acknowledge and agree that you are hereby waiving your right to any monetary benefits in connection with any such claim, charge or proceeding. You hereby represent and warrant that, other than the Excluded Claims, you are not aware of any claims you have or might have against any of the Released Parties that are not included in the Released Claims.
Indemnification Claims (a) In the event that any of the Parties are entitled, or seek to assert rights, to indemnification under this Article VI, the Party or Parties seeking indemnification (the “Indemnified Parties”) shall give written notification to the other Party or Parties (the “Indemnifying Parties”) of the commencement of any suit or proceeding relating to a third party claim for which indemnification pursuant to this Article VI may be sought. Such notification shall be given within 20 Business Days after receipt by the Indemnified Parties of notice of such suit or proceeding, and shall describe in reasonable detail (to the extent known by the Indemnified Parties) the facts constituting the basis for such suit or proceeding and the amount of the claimed damages; provided, however, that no delay on the part of the Indemnified Parties in notifying the Indemnifying Parties shall relieve the Indemnifying Parties of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Parties may, upon written notice thereof to the Indemnified Parties seeking indemnification, assume control of the defense of such suit or proceeding with counsel reasonably satisfactory to the Indemnified Party seeking indemnification; provided that the Indemnifying Parties may not assume control of the defense of a suit or proceeding involving criminal liability or in which equitable relief is sought against the Indemnified Party seeking indemnification. If the Indemnifying Parties do not so assume control of such defense, the Indemnified Parties seeking indemnification shall control such defense. The Party not controlling such defense (the “Non-Controlling Party”) may participate therein at its own expense; provided that if the Indemnifying Parties assumes control of such defense and the Indemnified Parties seeking indemnification reasonably concludes that the Indemnifying Parties and the Indemnified Parties seeking indemnification have conflicting interests or different defenses available with respect to such suit or proceeding, the reasonable fees and expenses of counsel to the Indemnified Parties shall be considered “Damages” for purposes of this Agreement. The Party or Parties controlling such defense (the “Controlling Party”) shall keep the Non-Controlling Party advised of the status of such suit or proceeding and the defense thereof and shall consider in good faith recommendations made by the Non-Controlling Party with respect thereto. The Non-Controlling Party shall furnish the Controlling Party with such information as it may have with respect to such suit or proceeding (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party as reasonably needed in the defense of such suit or proceeding at the sole cost and expense of the Indemnifying Parties under Section 6.1 or 6.2, which cost and expense shall be considered “Damages” for purposes of this Agreement. The Indemnifying Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnified Parties, which shall not be unreasonably withheld or delayed; provided that the consent of the Indemnified Parties shall not be required if the Indemnifying Parties agrees in writing to pay any amounts payable pursuant to such settlement or judgment and such settlement or judgment includes a complete release of the Indemnified Parties from further liability and has no other materially adverse effect on the Indemnified Parties. The Indemnified Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnifying Parties, which shall not be unreasonably withheld or delayed.
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Third Party Infringement In the event there is infringement by a third party of any Biochrom patent for the Product (“Third Party Infringement”) and GE Healthcare becomes aware of such infringement, GE Healthcare may give Biochrom written notice to that effect, including with such written notice evidence establishing a prima facie case of infringement by such third party. Biochrom shall bear all expenses of any suit brought by it based upon such infringement and shall retain all damages or other monies awarded or received in settlement of such suit. If, after the expiration of ninety (90) days from the date of such notice, Biochrom has not obtained a discontinuance of such infringement or brought suit against the third party infringer, then the parties shall appoint by mutual agreement an attorney with at least 15 years experience in litigating patent infringement lawsuits in the United States, who is a partner at a law firm with a nationally recognized intellectual property practice and who has no prior relationship with either party (“Independent Patent Counsel”). Such Independent Patent Counsel shall evaluate the identified Third Party Infringement and advise the parties in writing by not later than 60 days after his or her appointment whether he or she believes there is a reasonable likelihood of success in pursuing a claim for the Third Party Infringement. The cost of Independent Patent Counsel shall be shared equally by the parties. If Independent Patent Counsel determines that there is a reasonable likelihood of success and by the 30th day after such advice Biochrom has still not obtained a discontinuance of such infringement or brought suit against the third party infringer, then GE Healthcare shall have the right, but not the obligation, to bring suit against such infringer. Biochrom will cooperate with GE Healthcare in any such suit for infringement brought by GE Healthcare against such third party, and shall have the right to consult with GE Healthcare and to participate in and be represented by independent counsel in such litigation at its own expense. GE Healthcare shall bear all expenses of such suit, and shall retain any damages or other monies awarded or received in consequence of such litigation.
Defense of Third Party Claims Upon receipt by the Indemnifying Party of a notice from the Indemnified Party with respect to any claim of a third party against the Indemnified Party, for which the Indemnified Party seeks indemnification hereunder, the Indemnifying Party shall have the right to assume the defense of such claim, and the Indemnified Party shall cooperate to the extent reasonably requested by the Indemnifying Party in defense or prosecution thereof and shall furnish such records, information and testimony and attend all such conferences, discovery proceedings, hearings, trials and appeals as may be reasonably requested by the Indemnifying Party in connection therewith. If the Indemnifying Party shall elect to assume the defense of such claim, the Indemnified Party shall have the right to employ its own counsel in any such case, but the fees and expenses of such counsel shall be at the expense of the Indemnified Party. If the Indemnifying Party has assumed the defense of any claim against the Indemnified Party, the Indemnifying Party shall have the right to settle any claim for which indemnification has been sought and is available hereunder; provided that, to the extent that such settlement requires the Indemnified Party to take, or prohibits the Indemnified Party from taking, any action or purports to obligate the Indemnified Party, then the Indemnifying Party shall not settle such claim without the prior written consent of the Indemnified Party, such consent not to be unreasonably withheld, conditioned or delayed. If the Indemnifying Party does not assume the defense of a third party claim and disputes the Indemnified Party’s right to indemnification, the Indemnified Party shall have the right to assume control of the defense of such claim through counsel of its choice, the reasonable costs of which shall be at the Indemnifying Party’s expense in the event that the Indemnified Party’s right of indemnification is ultimately established through settlement, compromise or other legal proceeding. In no circumstance may the Indemnified Party compromise or settle a claim with a third party for which it seeks indemnification from the Indemnifying Party without first obtaining the prior written consent of the Indemnifying Party, such consent not to be unreasonably withheld, conditioned or delayed.
Product Claims You acknowledge that Company, not an App Distributor, is responsible for addressing any claims of yours or any third party relating to the Company application or your possession and/or use of the Company application, including, but not limited to: (i) product liability claims; (ii) any claim that the Company application fails to conform to any applicable legal or regulatory requirement; and (iii) claims arising under consumer protection or similar legislation. (5)
