Disputed Claims 4.1 Notwithstanding paragraph 4.5 of this Schedule, payment by the Authority of all or any part of any invoice rendered or other claim for payment by the Contractor shall not signify approval of such invoice/claim. The Authority reserves the right to verify invoices/claims after the date of payment and subsequently to recover any sums which have been overpaid.
Indemnity Limitation for TIPS Sales Texas and other jurisdictions restrict the ability of governmental entities to indemnify others. Vendor agrees that if any "Indemnity" provision which requires the TIPS Member to indemnify Vendor is included in any TIPS sales agreement/contract between Vendor and a TIPS Member, that clause must either be stricken or qualified by including that such indemnity is only permitted, "to the extent permitted by the laws and constitution of [TIPS Member's State]” unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing an "Indemnity" clause that conflicts with these terms is rendered void and unenforceable.
Delay Claim Must Be In Writing Any claim to extend the Contract Time and Material Completion and Occupancy Date must be in writing, must set forth in detail the basis for the claim and the number of days of delay claimed, must be correlated with the approved Overall Project Schedule, must be executed by the Contractor and delivered to the Design Professional and the Owner, and must be reviewed and an appropriate time assessed by the Design Professional.
Indemnification Claims (a) In the event that any of the Parties are entitled, or seek to assert rights, to indemnification under this Article VI, the Party or Parties seeking indemnification (the “Indemnified Parties”) shall give written notification to the other Party or Parties (the “Indemnifying Parties”) of the commencement of any suit or proceeding relating to a third party claim for which indemnification pursuant to this Article VI may be sought. Such notification shall be given within 20 Business Days after receipt by the Indemnified Parties of notice of such suit or proceeding, and shall describe in reasonable detail (to the extent known by the Indemnified Parties) the facts constituting the basis for such suit or proceeding and the amount of the claimed damages; provided, however, that no delay on the part of the Indemnified Parties in notifying the Indemnifying Parties shall relieve the Indemnifying Parties of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Parties may, upon written notice thereof to the Indemnified Parties seeking indemnification, assume control of the defense of such suit or proceeding with counsel reasonably satisfactory to the Indemnified Party seeking indemnification; provided that the Indemnifying Parties may not assume control of the defense of a suit or proceeding involving criminal liability or in which equitable relief is sought against the Indemnified Party seeking indemnification. If the Indemnifying Parties do not so assume control of such defense, the Indemnified Parties seeking indemnification shall control such defense. The Party not controlling such defense (the “Non-Controlling Party”) may participate therein at its own expense; provided that if the Indemnifying Parties assumes control of such defense and the Indemnified Parties seeking indemnification reasonably concludes that the Indemnifying Parties and the Indemnified Parties seeking indemnification have conflicting interests or different defenses available with respect to such suit or proceeding, the reasonable fees and expenses of counsel to the Indemnified Parties shall be considered “Damages” for purposes of this Agreement. The Party or Parties controlling such defense (the “Controlling Party”) shall keep the Non-Controlling Party advised of the status of such suit or proceeding and the defense thereof and shall consider in good faith recommendations made by the Non-Controlling Party with respect thereto. The Non-Controlling Party shall furnish the Controlling Party with such information as it may have with respect to such suit or proceeding (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party as reasonably needed in the defense of such suit or proceeding at the sole cost and expense of the Indemnifying Parties under Section 6.1 or 6.2, which cost and expense shall be considered “Damages” for purposes of this Agreement. The Indemnifying Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnified Parties, which shall not be unreasonably withheld or delayed; provided that the consent of the Indemnified Parties shall not be required if the Indemnifying Parties agrees in writing to pay any amounts payable pursuant to such settlement or judgment and such settlement or judgment includes a complete release of the Indemnified Parties from further liability and has no other materially adverse effect on the Indemnified Parties. The Indemnified Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnifying Parties, which shall not be unreasonably withheld or delayed.
Compensation Claims (a) The Employer agrees to cooperate toward the prompt disposition of employee on-the-job injury claims. The Employer shall provide worker’s compensation protection for all employees even though not required by state law, or the equivalent thereof, if the injury arose out of or in the course of employment. No employee will be disciplined or threatened with discipline as a result of filing an on-the-job injury report. The Employer or its designee shall not visit an injured worker at his/her home, at a hospital or any location outside the employee’s home terminal without his/her consent.
Our Liability for Failure to Complete Transactions If we do not properly complete a transaction from your Card on time or in the correct amount according to our Agreement with you, we will be liable for your losses or damages. However, there are some exceptions. We will not be liable, for instance:
Compensation for Damages or Losses When investments by investors of either Contracting Party suffer damages or losses owing to war, armed conflict, a state of national emergency, revolt, insurrection, riot or other similar events in the territory of the other Contracting Party, they shall be accorded by the latter Contracting Party a treatment, as regards compensation or other settlement, not less favourable than that accorded to its own investors or to investors of any Third State.
OUR LIABILITY FOR FAILURE TO STOP PAYMENT If You order Us to place a stop payment on one of Your pre-authorized payments 3 business days or more before the transfer is scheduled, and We do not do so, We will be liable for losses or damages, to the extent provided by law. TRANSACTION SLIPS. Except for mail-in transactions and certain small-value transactions, You can get a receipt at the time You make any transaction to or from Your Account through the use of Your Card. When an electronic fund transfer has been made during any given month, You will receive a monthly statement to reflect all electronic fund transfers to or from Your Account during that statement period. In any case, You will receive a statement at least quarterly. FEES. We may assess reasonable charges against Your Account for transactions performed at electronic terminals. If so, We will specify any charges for these or other types of electronic transactions, including automatic transfers, on an accompanying pricing document. We will explain the charges to You when You open Your Account. You will be provided with a fee schedule, and other specified information after Your Account is established. Additional fee schedules are available at any of Our office locations. When You use an ATM not owned by Us, You may be charged a fee by the ATM operator, or any network used, and You may be charged a fee for a balance inquiry even if You do not complete a fund transfer.
Claims for Additional Costs 11.3.1 If the Contractor wishes to make a claim for an increase in the Contract Sum not related to a requested change, it shall give the Owner and the A/E written notice thereof within twenty-one (21) days after the occurrence of the event giving rise to such claim, but, in any case before proceeding to execute the work considered to give rise to the additional cost or time, except in an emergency endangering life or property in which case the Contractor shall act in accordance with Article 7.2.1. No such claim shall be valid unless so made. If the Owner and the Contractor cannot agree on the amount of the adjustment in the Contract Sum, it shall be determined as set forth under Article 15. Any change in the Contract Sum resulting from such claim shall be authorized by Change Order.
Released Claims In consideration of these additional benefits, you, on behalf of your heirs, spouse and assigns, hereby completely release and forever discharge Ikanos, its past and present affiliates, agents, officers, directors, shareholders, employees, attorneys, insurers, successors and assigns (collectively referred to as the “Company”) from any and all claims, of any and every kind, nature and character, known or unknown, foreseen or unforeseen, based on any act or omission occurring prior to the date of you signing this Release Agreement, including but not limited to any claims arising out of your offer of employment, your employment or termination of your employment with the Company or your right to purchase, or actual purchase of shares of stock of the Company (including, but not limited to, all rights related to or associated with stock options and restricted stock units), including, without limitation, any claims for fraud, misrepresentation, breach of fiduciary duty, breach of duty under applicable state corporate law, and securities fraud under any state or federal law. The matters released include, but are not limited to, any claims under federal, state or local laws, including claims arising under the Age Discrimination in Employment Act of 1967 (“ADEA”) as amended by, including but not limited to, the Older Workers’ Benefit Protection Act (“OWBPA”) and any common law tort contract or statutory claims, and any claims for attorneys’ fees and costs. You understand and agree that this Release Agreement extinguishes all claims, whether known or unknown, foreseen or unforeseen, except for those claims expressly described below. You expressly waive any rights or benefits under Section 1542 of the California Civil Code, or any equivalent statute. California Civil Code Section 1542 provides as follows: “A GENERAL RELEASE DOES NOT EXTEND TO CLAIMS WHICH THE CREDITOR DOES NOT KNOW OR SUSPECT TO EXIST IN HIS FAVOR AT THE TIME OF EXECUTING THE RELEASE, WHICH IF KNOWN BY HIM MUST HAVE MATERIALLY AFFECTED HIS SETTLEMENT WITH THE DEBTOR.” You fully understand that, if any fact with respect to any matter covered by this Release Agreement is found hereafter to be other than or different from the facts now believed by you to be true, you expressly accept and assume that this Release Agreement shall be and remain effective, notwithstanding such difference in the facts.
