Delivery Point Once Manufacture of the Products has been completed, Contractor shall be responsible for delivering the Finished Goods FCA, (as defined in Incoterms (2000) published by the International Chamber of Commerce) and to a freight forwarder specified by Company in its Order, or otherwise approved by Company. “Delivery Point” as used in this Agreement shall mean the specific time and location that the Product is delivered to the shipper specified on the Order.
Delivery Schedule The scheduled months of delivery of the Aircraft are listed in the attached Table 1. Exhibit B describes certain responsibilities for both Customer and Boeing in order to accomplish the delivery of the Aircraft.
Execution, Delivery; Valid and Binding Agreement The authorization, execution and delivery of this Agreement, the consummation of the transactions herein contemplated and compliance with the terms, conditions and provisions of this Agreement do not and will not conflict with or result in a breach of any of the terms, conditions or provisions of any agreement or instrument to which either the Depositor or the Depositor Eligible Lender Trustee is a party or by which either is bound or constitute a default thereunder; neither the Depositor nor the Depositor Eligible Lender Trustee is a party to or bound by any agreement or instrument or subject to any charter or other corporate restriction or judgment, order, writ, injunction, decree, law, rule or regulation which may materially and adversely affect the ability of either the Depositor or the Depositor Eligible Lender Trustee to perform its respective obligations under this Agreement. This Agreement constitutes a valid and binding obligation of each of the Depositor and the Depositor Eligible Lender Trustee enforceable against such party in accordance with its terms, subject to the effects of bankruptcy, insolvency, reorganization, moratorium, fraudulent conveyance and other similar laws relating to or affecting creditors' rights generally and court decisions with respect thereto, and no consent, approval or authorization is required in connection with the consummation of the transactions herein contemplated, except for those that have been obtained.
Shipments All Products delivered pursuant to the terms of this Agreement shall be suitably packed for shipment in accordance with the Specifications and marked for shipment to Customer’s destination specified in the applicable purchase order. Shipments will be made EXW (Ex-Works, Incoterms 2000) Flextronics’s facility, at which time risk of loss and title will pass to Customer. All freight, insurance and other shipping expenses, as well as any special packing expenses not included in the original quotation for the Products, will be paid by Customer. In the event Customer designates a freight carrier to be utilized by Flextronics, Customer agrees to designate only freight carriers that are currently in compliance with all applicable laws relating to anti-terrorism security measures and to adhere to the C-TPAT (Customs-Trade Partnership Against Terrorism) security recommendations and guidelines as outlined by the United States Bureau of Customs and Border Protection and to prohibit the freight carriage to be sub-contracted to any carrier that is not in compliance with the C-TPAT guidelines.
Place and Date of Closing; Risk of Loss The closing of the transaction contemplated hereby (the “Closing”) will be held on the Closing Date at such place and time as the parties may mutually agree. Upon Seller’s delivery of the items set forth in Section 6.2 and Purchaser’s delivery of the items set forth in Section 6.3, the Closing will be consummated and Purchaser shall be deemed to have accepted delivery of the Ownership Interests in the Asset. Title to and all risks of loss with respect to the Ownership Interests will pass from Seller to Purchaser upon the completion of the Closing in accordance with this Section 6.
Delivery at Closing At the Closing, the Company will deliver to the Purchaser a stock certificate registered in the Purchaser’s name, representing the number of Shares to be purchased by Purchaser hereunder, against payment of the purchase price therefore as indicated above.
Failure to Deliver Warrant Shares (a) In the event that the Company fails for any reason to deliver to the Holder the number of Warrant Shares specified in the applicable Exercise Notice on or before the Delivery Date therefor (an “Exercise Default”), the Company shall pay to the Holder payments (“Exercise Default Payments”) in the amount of (i) (N/365) multiplied by (ii) the aggregate Exercise Price of the Warrant Shares which are the subject of such Exercise Default multiplied by (iii) the lower of fifteen percent (15%) per annum and the maximum rate permitted by applicable law (the “Default Interest Rate”), where “N” equals the number of days elapsed between the original Delivery Date of such Warrant Shares and the date on which all of such Warrant Shares are issued and delivered to the Holder. Cash amounts payable hereunder shall be paid on or before the fifth (5th) Business Day of each calendar month following the calendar month in which such amount has accrued.
Delivery Points The measurement of and tests for quality of Shipper's Gas redelivered at the Delivery Points shall be governed by and determined in accordance with the requirements of the receiving pipeline at each Delivery Point.
Shipment If any of the Major Components associated with any Unit is not Shipped on or before (with the prior approval of the Buyer) the Scheduled Major Component Shipment Date set forth in Attachment 1 for reasons attributable to the Seller and not excused elsewhere in this Contract, the Seller shall pay as liquidated damages, and not as a penalty, a sum calculated in accordance with the table below for each Unit for each day of delay after the Scheduled Major Component Shipment Date as set forth in Attachment 1 until actual Shipment of the last Major Component for such Unit: Days after Scheduled Major Component Shipment Date Liquidated Damages (per day or partial day) *** *** *** *** *** *** Such liquidated damages, if any, shall be computed based on the date of Shipment of the last Major Component for a given Unit and such computations shall disregard any part of or accessory to the Major Component which may be shipped separately and arrive later unless such part of or accessory to the Major Component is necessary for the installation of the Major Component.
Share Delivery Delivery of any shares in connection with settlement of the Award will be by book-entry credit to an account in the Grantee’s name established by the Company with the Company’s transfer agent, or upon written request from the Grantee (or his personal representative, beneficiary or estate, as the case may be), in certificates in the name of the Grantee (or his personal representative, beneficiary or estate).
