Compensation for Additional Preparation Lane Changes
Compensation for Additional Preparation Lane Changes Sample Clauses
Related to Compensation for Additional Preparation Lane Changes
Compensation for Additional Services Additional Services shall be compensated as set forth on Exhibit A for the stipulated payment amounts set forth therein. Other Additional Services not set forth on Exhibit A that are required or requested by the Owner shall be compensated as agreed, using the methodology set forth on Exhibit A, prior to the Design Professional undertaking such Additional Services; provided, however, that if such compensation cannot be agreed, the Additional Services shall be performed at the hourly rates set forth and listed in Exhibit B, plus reimbursable expenses pursuant to Article 4.1.3 below, with a limitation as to maximum amount specified.
Compensation for Overtime Assigned overtime is designated as those hours over the regular hours of work which are requested of the employee by management. Assigned overtime worked shall be paid at the rate of time and one-half (1 1/2).
Developer Compensation for Emergency Services If, during an Emergency State, the Developer provides services at the request or direction of the NYISO or Connecting Transmission Owner, the Developer will be compensated for such services in accordance with the NYISO Services Tariff.
A-E Compensation and Extra Work 1.5.1. For the PROJECTS/SERVICES authorized under this CONTRACT, A-E shall be compensated in accordance with the following: 1.5.2. For completion and approval of all PROJECTS/SERVICES where “Extra Work” (defined as changes in approved portions of the PROJECT/SERVICES required by and ordered in writing by DIRECTOR which changes constitute a change in or departure from said approved portions of PROJECTS/SERVICES) is not authorized, compensation including reimbursables shall be described and payable as stipulated in Fee Schedule, herein after referred to as “Attachment B”, attached hereto and incorporated herein by reference. 1.5.3. Where extra work is authorized for PROJECTS/SERVICES: a. The amount for Extra Work shall be determined using Attachment B. Extra Work shall be required by and ordered in writing by DIRECTOR. If this CONTRACT is not approved by the Board of Supervisors, any change that increases the cumulative CONTRACT price beyond $100,000 must be approved by the Board. Increases in the CONTRACT amount for services within the existing scope of work may be granted by the DIRECTOR where the amount does not exceed 25 percent of the existing CONTRACT price or $100,000, whichever is less. b. A-E's billing for the Extra Work shall include but not be limited to names of A- E's staff employed in the Extra Work, classification of employees and number of hours worked. 1.5.4. For partial completion of work of PROJECTS/SERVICES followed by default on part of A-E: a. For failure to complete and secure approval of the first required submittal, there shall be no compensation. b. For failure to complete and secure approval of other authorized phases, A-E shall, upon completion of PROJECTS/SERVICES by others, be entitled to receive compensation based on approved work of PROJECTS/SERVICES not to exceed the amounts specified in Attachment A for that particular submittal, plus the reasonable value as determined by COUNTY of the non-approved work; provided, however, that if the cost to COUNTY to complete the contract exceeds the amount specified herein, A-E shall be liable to COUNTY for such excess costs attributable to A-E's breach of the CONTRACT.
Additional Compensation Notwithstanding anything in this Memorandum of Understanding to the contrary when in the judgment of the Board, it becomes necessary or desirable to utilize the services of County employees in capacities other than those for which they are regularly employed, the Board may authorize and, if appropriate, fix an additional rate of compensation for such employees.
No Additional Compensation Notwithstanding any other provision of this Agreement, the obligation of Agency to return Referred Accounts, provide current status reports of all such accounts or information reasonably required by Client shall be without right to any additional Contingent Fee, administrative fees or other compensation of any kind or type whatsoever after such termination date, including, without limitation, in quantum meruit, for any Services rendered prior to termination (except on recoveries received and remitted to Client pursuant to this Agreement prior to termination) whether or not said Services result in or contribute to recoveries received after termination.
Compensation for Basic Services A. Owner shall make payment for Part I and Part II services monthly. The payments shall be in proportion to the progress of Engineer's work. Final payment for each phase shall become due and payable upon completion and approval by Owner of that phase of Engineer's work. B. Owner shall make payment for Construction Phase services not more frequently than monthly in proportion to the amount of the gross progress payments to Contractor(s). C. Owner shall make no deduction from Engineer's compensation on account of penalties, liquidated damages or other sums withheld from Contractor(s) through no fault of Engineer. D. Owner shall make payment for Construction Completion Phase services upon completion of the requirements set forth in subsections II. F. 1, 2 and 3. E. Engineer shall submit requests for payment monthly on forms provided and in a manner prescribed by Owner.
Contract Duration and Annual Salary 1. The College hereby employs the Administrator in the capacity of Director - Marketing Services, Associate Professor for one year, commencing on July 1, 2024 and terminating on June 30, 2025. The Administrator accepts such employment on the conditions hereinafter set forth, and any applicable provisions of the Board of Trustees Policy Manual. In the event of conflict between Board Policy and this Contract, the Contract shall govern. 2. For the 2024-2025 contract year, the Administrator shall receive an annual salary of $178,054.00 subject to applicable deductions, to be paid in bi-weekly installments as full compensation for all rights granted and service performed under this Contract.
Payment and Year-End Adjustment Amounts accrued pursuant to this Agreement shall be payable to the Adviser as of the last day of each month. If necessary, on or before the last day of the first month of each fiscal year, an adjustment payment shall be made by the appropriate party in order that the actual Fund Operating Expenses of a Fund for the prior fiscal year (including any reimbursement payments hereunder with respect to such fiscal year) do not exceed the Maximum Annual Operating Expense Limit.
Interconnection Customer Compensation for Actions During Emergency Condition The CAISO shall compensate the Interconnection Customer in accordance with the CAISO Tariff for its provision of real and reactive power and other Emergency Condition services that the Interconnection Customer provides to support the CAISO Controlled Grid during an Emergency Condition in accordance with Article 11.6.
