Completion by Lessor Sample Clauses

Completion by Lessor. If, after a default by Lessee, Lessor shall perform any of such work, then Lessor may withdraw funds held by the Depository for application to the cost thereof. In withdrawing such funds Lessor need not comply with any of the preceding requirements, but must only comply with the requirements hereafter set forth. Such withdrawals shall be made not more often than at thirty (30) day intervals. At the time of each withdrawal request Lessor shall deliver to the Depository, a certificate from either the Architect or other architect selected by Lessor stating that the sum then requested to be withdrawn either has been paid by Lessor, and/or is justly due, to contractors, subcontractors, materialmen, engineers, architects or to other persons (whose names and addresses shall be stated) who have rendered or furnished services or materials for the work, and giving a brief description of such services and materials and the respective amounts so paid or due to each of said persons in respect thereof. Such certificate shall also state that no part of the cost of the services or materials described therein has been or is the basis of a withdrawal of funds in any previous or pending application.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Completion by Lessor. The premises shall be is complete and in good and workmanlike manner.
Sample 1

Related to Completion by Lessor

  • Inspection by Lessor Upon reasonable advance notice, Lessee, during reasonable business hours and subject to Lessee's security requirements, will make the Equipment and its related log and maintenance records available to Lessor for inspection.

  • Termination by Lessor Lessor may terminate the lease at any time if any of the following shall happen:

  • Termination by Lessee Subject to Subparagraph 18D, and without limiting any other rights and remedies to which Lessee may be entitled by common law, statutory law, or as elsewhere provided in this Lease, this Lease may be terminated by Lessee at any time after the happening, and during the existence, of one of more of the following events: i. The City’s permanent abandonment of the Premises at the Airport; ii. The lawful assumption by the United States Government, or any authorized agency thereof, of the operation, control, or use of the Airport, or any substantial part or parts thereof, that substantially restricts any sublessee from operating for at least one hundred fifty (150) calendar days; iii. The issuance by any court of competent jurisdiction of an injunction that prevents or restrains the use of the Airport or the Premises, that continues for at least one hundred fifty (150) calendar days; iv. The default by the City in the performance of any covenant or obligation on the part of the City to be performed, and the failure of the City to remedy the default for sixty (60) calendar days after receipt from Lessee of written notice to remedy the same; or v. Lessee’s decision to terminate the Lease as provided in Paragraph 11(B) of the Lease.

  • ENTRY BY LESSOR 17.01 Lessor and Lessor's authorized representatives shall have the right to enter the Demised Premises with 24 hour prior verbal notice unless in cases of emergency at reasonable hours for any of the following purposes: (a) To examine and inspect the Demised Premises; (b) To supply any service to be provided by Lessor to Lessee hereunder; (c) To perform any necessary maintenance or repairs that Lessor is required or permitted to perform hereunder; (d) To serve, post or keep posted any notices required or allowed under the provisions of this Lease; (e) To post "for sale" signs at any time during the term, to post "for rent" or "for lease" signs during the last one hundred twenty (120) days of the Lease term, or during any period while Lessee is in default; (f) To show the Demised Premises to prospective tenants, buyers, lenders or other persons at any time during the Lease term; (g) To do any other act or thing necessary for the safety or preservation of the Demised Premises or the Industrial Center. 17.02 Lessor shall at all times have and retain a key with which to unlock all of the doors in, on or about the Demised Premises (excluding Lessee's vaults, safes and other secured areas designated in writing by Lessee in advance); and Lessor shall have the right to use any and all means which Lessor may deem proper to open said doors in an emergency in order to obtain entry to the Demised Premises, and any entry to the Demised Premises obtained by Lessor by any of said means, or otherwise, shall not under any circumstances be construed or deemed to be a forcible or unlawful entry into or a detainer of the Demised Premises, or an eviction, actual or constructive, of Lessee from the Demised Premises, or any portion thereof.

  • Completion of Project This Grant Agreement shall terminate upon completion of the project and payment of the last invoice.

  • Inspection by Landlord Landlord shall have the right to inspect the Tenant Improvements at all times, provided however, that Landlord’s failure to inspect the Tenant Improvements shall in no event constitute a waiver of any of Landlord’s rights hereunder nor shall Landlord’s inspection of the Tenant Improvements constitute Landlord’s approval of the same. Should Landlord disapprove any portion of the Tenant Improvements, Landlord shall notify Tenant in writing of such disapproval and shall specify the items disapproved. Any defects or deviations in, and/or disapproval by Landlord of, the Tenant Improvements shall be rectified by Tenant at no expense to Landlord, provided however, that in the event Landlord determines that a defect or deviation exists or disapproves of any matter in connection with any portion of the Tenant Improvements and such defect, deviation or matter might adversely affect the mechanical, electrical, plumbing, heating, ventilating and air conditioning or life-safety systems of the Building, the structure or exterior appearance of the Building or any other tenant’s use of such other tenant’s leased premises, Landlord may, take such action as Landlord deems necessary, at Tenant’s expense and without incurring any liability on Landlord’s part, to correct any such defect, deviation and/or matter, including, without limitation, causing the cessation of performance of the construction of the Tenant Improvements until such time as the defect, deviation and/or matter is corrected to Landlord’s satisfaction.

  • Removal of Tenant Property by Tenant Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.

  • Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.

  • Construction of the Tenant Improvements (a) Tenant shall construct and install the Tenant Improvements in a good and workmanlike manner, in compliance with all Laws and in accordance with this Exhibit B. Tenant’s proposed architect/engineer, general contractor, and fire protection, plumbing, HVAC and electrical subcontractors are subject to Landlord’s prior approval. Promptly following the selection and approval of the architect/engineer, Tenant shall forward to said architect/engineer (and copy Landlord on the transmittal) Landlord’s building standards heretofore delivered to Tenant, and Tenant shall cause said architect/engineer to comply with said building standards. Promptly following the selection and approval of the general contractor, Tenant shall forward to said general contractor (and copy Landlord on the transmittal) Landlord’s fire protection, plumbing, HVAC and electrical specifications and Landlord’s rules of conduct, all of which have been delivered to Tenant prior to the date of this Lease, and Tenant shall cause said general contractor to comply with said specifications and rules of conduct. At Landlord’s request, Tenant shall coordinate a meeting among Landlord (who will reasonably make its representative available for such meeting), Tenant and Tenant’s general contractor to discuss the Building systems and other matters related to the construction of the Tenant Improvements. (b) Promptly following the date hereof, Tenant shall prepare and submit to Landlord a set of permittable construction drawings (the “CDs”), based on the preliminary plans attached hereto as Exhibit B-2 and made a part hereof (the “Preliminary Plans”), covering all work to be performed by Tenant in constructing the Tenant Improvements. Tenant shall have no right to make any Tenant Improvements that would materially alter the exterior appearance of the Building or the Building systems without Landlord’s prior approval. Landlord shall have fifteen (15) days after receipt of the CDs in which to review the CDs and in which to give Tenant written notice of its approval of the CDs or its requested changes to the CDs in reasonably sufficient detail so as to allow Tenant to make the requested changes (provided that Landlord shall not be permitted to request a change that is inconsistent with the Preliminary Plans). If Landlord requests any changes to the CDs, Tenant shall make such changes and shall, within fifteen (15) days of its receipt of Landlord’s requested changes (if any), submit the revised portion of the CDs to Landlord. Landlord shall have five (5) business days after receipt of the revised CDs in which to review said revised CDs and in which to give to Tenant written notice of its approval of the revised CDs or its requested changes thereto. This process shall continue until such time, if at all, that Landlord approves the CDs in accordance with this Section 2. Tenant shall at all times in its preparation of the CDs, and of any revisions thereto, act reasonably and in good faith. Landlord shall at all times in its review of the CDs, and any revisions thereto, act reasonably and in good faith.

  • Condition of Premises Lessor makes no warranty or representation as to the Premises. Lessee acknowledges and agrees that it has occupied and familiarized itself with the Premises and has had adequate opportunity to investigate and inspect the condition of the Premises, and enters into this Lease upon the basis of its own review, and is leasing the Premises in their “AS IS, WHERE IS” CONDITION WITH ALL FAULTS, WHETHER PREVIOUSLY EXISTING OR ARISING FROM OR PERTAINING TO ANY CONSTRUCTION, RENOVATION, RELOCATION OR IMPROVEMENT OF ANY PORTION OF THE PREMISES PERFORMED BY LESSOR OR OTHERS, INCLUDING BUT NOT LIMITED TO BOTH LATENT AND PATENT DEFECTS. EXCEPT AS EXPRESSLY SET FORTH TO THE CONTRARY IN THIS LEASE, NO WARRANTIES, EXPRESS OR IMPLIED, ARE MADE BY LESSOR OR ANY OF ITS AFFILIATES CONCERNING SUCH ITEMS, INCLUDING BUT NOT LIMITED TO, WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE. LESSEE HEREBY WAIVES AND DISCLAIMS ANY WARRANTIES THAT MAY ARISE BY OPERATION OF LAW. Lessee further acknowledges and agrees that it has had an opportunity to review and to discuss with various agents and/or representatives of Lessor the environmental condition of the Premises. Lessee has investigated and has knowledge of operative or proposed governmental laws and regulations including, without limitation, environmental laws and regulations to which the Premises are or may be subject and enters into this Lease upon the basis of its review and determination of the applicability and effect of such laws and regulations. Lessee acknowledges that Lessor expressly disclaims any representations or warranties of any kind or nature, express or implied, as to the condition (financial or otherwise), value or quality of the products, assets or properties of the Premises. Lessee hereby accepts the Premises in their condition existing as of the date hereof, subject to all applicable zoning, municipal, county and state laws, ordinances and regulations governing and regulating the use of the Premises, and accepts this Lease subject thereto and to all matters disclosed thereby and by any exhibits attached hereto. Lessee hereby agrees that all furniture, equipment, machinery and all other personal property, excepting any computers, that are located on or in the Premises as of the date hereof shall remain on the Premises as and when Lessee evacuates the Premises on the Termination Date or any extension thereof.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!