Conduct of Indemnification Proceedings Any person entitled to indemnification hereunder shall (i) give prompt notice to the indemnifying party of any claim with respect to which it seeks indemnification and (ii) permit such indemnifying party to assume the defense of such claim with counsel reasonably satisfactory to the indemnified party; provided that any person entitled to indemnification hereunder shall have the right to employ separate counsel and to participate in the defense of such claim, but the fees and expenses of such counsel shall be at the expense of such person unless (a) the indemnifying party has agreed to pay such fees or expenses, or (b) the indemnifying party shall have failed to assume the defense of such claim and employ counsel reasonably satisfactory to such person or (c) in the reasonable judgment of any such person, based upon written advice of its counsel, a conflict of interest exists between such person and the indemnifying party with respect to such claims (in which case, if the person notifies the indemnifying party in writing that such person elects to employ separate counsel at the expense of the indemnifying party, the indemnifying party shall not have the right to assume the defense of such claim on behalf of such person); and provided, further, that the failure of any indemnified party to give notice as provided herein shall not relieve the indemnifying party of its obligations hereunder, except to the extent that such failure to give notice shall materially adversely affect the indemnifying party in the defense of any such claim or litigation. It is understood that the indemnifying party shall not, in connection with any proceeding in the same jurisdiction, be liable for fees or expenses of more than one separate firm of attorneys at any time for all such indemnified parties. No indemnifying party will, except with the consent of the indemnified party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such indemnified party of a release from all liability in respect of such claim or litigation.
Indemnification Proceedings Each party entitled to indemnification pursuant to this Section 13 (the "Indemnified Party") shall give notice to the party required to provide indemnification pursuant to this Section 13 (the "Indemnifying Party") promptly after such Indemnified Party acquires actual knowledge of any claim as to which indemnity may be sought, and shall permit the Indemnifying Party (at its expense) to assume the defense of any claim or any litigation resulting therefrom; provided that counsel for the Indemnifying Party, who shall conduct the defense of such claim or litigation, shall be acceptable to the Indemnified Party, and the Indemnified Party may participate in such defense at such party's expense; and provided, further, that the failure by any Indemnified Party to give notice as provided in this paragraph (c) shall not relieve the Indemnifying Party of its obligations under Section 13 except to the extent that the failure results in a failure of actual notice to the Indemnifying Party and such Indemnifying Party is damaged solely as a result of the failure to give notice. No Indemnifying Party, in the defense of any such claim or litigation, shall, except with the consent of each Indemnified Party, consent to entry of any judgment or enter into any settlement which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect to such claim or litigation. The reimbursement required by this Section 13 shall be made by periodic payments during the course of the investigation or defense, as and when bills are received or expenses incurred.
Defense and Indemnification 12.1 Consultant agrees to indemnify, defend (with attorneys approved by City), and hold harmless the City, and its officers, officials, agents and employees (the “Indemnified Parties”) from any and all claims, demands, costs or liability that arise out of, or pertain to, or relate to the Consultant, its employees, agents, and subcontractors performance of services under this Agreement. Consultant’s duty to indemnify under this section shall not include liability for damages for death or bodily injury to persons, injury to property, or other loss, damage or expense arising from the sole negligence or willful misconduct by the City or its elected officials, officers, agents, and employees. Consultant's indemnification obligations shall not be limited by the insurance provisions of this Agreement. The Parties expressly agree that any payment, attorney's fees, costs or expense City incurs or makes to or on behalf of an injured employee under the City's self-administered workers' compensation is included as a loss, expense, or cost for the purposes of this section, and that this section will survive the expiration or early termination of this Agreement.
12.2 This indemnity is in addition to any other rights or remedies which City may have under the law or this Agreement. In the event of any claim or demand made against any party which is entitled to be indemnified hereunder, City may, at its sole discretion, reserve, retain or apply any monies due to Consultant under this Agreement for the purpose of resolving such claims; provided however, that City may release such funds if Consultant provides City with reasonable assurances of protection of the City's interest. The City shall, in its sole discretion determine whether such assurances are reasonable.
12.3 Consultant agrees that its duty to defend arises upon an allegation of liability based upon the performance of services under this Agreement by Consultant, its officers, agents, representatives, employees, sub-consultants, or anyone for whom Consultant is liable and that an adjudication of Consultant’s liability is not a condition precedent to Consultant's duty to defend.
Indemnification and Defense 16.1 To the fullest extent permitted by California law, Developer shall indemnify, keep and hold harmless the District, the Architect(s) and Construction Manager(s), their respective consultants, separate contractors, board members, officers, representatives, agents, and employees, in both individual and official capacities (“Indemnitees”), against all suits, claims, injury, damages, losses, and expenses (“Claims”), including but not limited to attorney’s fees and costs, caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Contract by Developer or its Subcontractors, vendors and/or suppliers. However, Developer’s indemnification and hold harmless obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent the Claim(s) is/are caused wholly by the active negligence or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. This indemnification and hold harmless obligation of Developer shall not be construed to negate, abridge, or otherwise reduce any right or obligation of indemnity that would otherwise exist or arise as to any Indemnitee or other person described herein. This indemnification and hold harmless obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any law and/or provision of the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developers obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR.
16.2 To the furthest extent permitted by California law, Developer shall also defend Indemnitees, at its own expense, including but not limited to attorneys’ fees and costs, against all Claims caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Facilities Lease by Developer, its Subcontractors, vendors, or suppliers. However, without impacting Developer’s obligation to provide an immediate and ongoing defense of Indemnitees, Developer’s defense obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent caused by the sole negligence, active negligence, or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. The District shall have the right to accept or reject any legal representation that Xxxxxxxxx proposes to defend the Indemnitees. If any Indemnitee provides its own defense due to failure to timely respond to tender of defense, rejection of tender of defense, or conflict of interest of proposed counsel, Developer shall reimburse such Indemnitee for any expenditures. Developer’s defense obligation shall not be construed to negate, abridge, or otherwise reduce any right or obligation of defense that would otherwise exist as to any Indemnitee or other person described herein. Developer’s defense obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any provision of law, any failure or alleged failure to timely and properly fulfill all of its obligations under the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developer’s obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR. Developer shall give prompt notice to the District in the event of any Claim(s).
16.3 Without limitation of the provisions herein, if Xxxxxxxxx’s obligation to indemnify and hold harmless the Indemnitees or its obligation to defend Indemnitees as provided herein shall be determined to be void or unenforceable, in whole or in part, it is the intention of the Parties that these circumstances shall not otherwise affect the validity or enforceability of Developer’s agreement to indemnify, defend, and hold harmless the rest of the Indemnitees, as provided herein. Further, Developer shall be and remain fully liable on its agreements and obligations herein to the fullest extent permitted by law.
Indemnification in Third Party Proceedings Subject to Section 10 below, the Company shall indemnify Indemnitee to the fullest extent permitted by the Code, as the same may be amended from time to time (but, only to the extent that such amendment permits Indemnitee to broader indemnification rights than the Code permitted prior to adoption of such amendment), if Indemnitee is a party to or threatened to be made a party to or otherwise involved in any proceeding, for any and all expenses, actually and reasonably incurred by Indemnitee in connection with the investigation, defense, settlement or appeal of such proceeding.
Indemnification Procedure Any party entitled to indemnification under this Article VI (an “indemnified party”) will give written notice to the indemnifying party of any matters giving rise to a claim for indemnification; provided, that the failure of any party entitled to indemnification hereunder to give notice as provided herein shall not relieve the indemnifying party of its obligations under this Article VI except to the extent that the indemnifying party is actually prejudiced by such failure to give notice. In case any action, proceeding or claim is brought against an indemnified party in respect of which indemnification is sought hereunder, the indemnifying party shall be entitled to participate in and, unless in the reasonable judgment of the indemnified party a conflict of interest between it and the indemnifying party may exist with respect of such action, proceeding or claim, to assume the defense thereof with counsel reasonably satisfactory to the indemnified party. In the event that the indemnifying party advises an indemnified party that it will contest such a claim for indemnification hereunder, or fails, within thirty (30) days of receipt of any indemnification notice to notify, in writing, such person of its election to defend, settle or compromise, at its sole cost and expense, any action, proceeding or claim (or discontinues its defense at any time after it commences such defense), then the indemnified party may, at its option, defend, settle or otherwise compromise or pay such action or claim. In any event, unless and until the indemnifying party elects in writing to assume and does so assume the defense of any such claim, proceeding or action, the indemnified party’s costs and expenses arising out of the defense, settlement or compromise of any such action, claim or proceeding shall be losses subject to indemnification hereunder. The indemnified party shall cooperate fully with the indemnifying party in connection with any negotiation or defense of any such action or claim by the indemnifying party and shall furnish to the indemnifying party all information reasonably available to the indemnified party which relates to such action or claim. The indemnifying party shall keep the indemnified party fully apprised at all times as to the status of the defense or any settlement negotiations with respect thereto. If the indemnifying party elects to defend any such action or claim, then the indemnified party shall be entitled to participate in such defense with counsel of its choice at its sole cost and expense. The indemnifying party shall not be liable for any settlement of any action, claim or proceeding effected without its prior written consent. Notwithstanding anything in this Article VI to the contrary, the indemnifying party shall not, without the indemnified party’s prior written consent, settle or compromise any claim or consent to entry of any judgment in respect thereof which imposes any future obligation on the indemnified party or which does not include, as an unconditional term thereof, the giving by the claimant or the plaintiff to the indemnified party of a release from all liability in respect of such claim. The indemnification required by this Article VI shall be made by periodic payments of the amount thereof during the course of investigation or defense, as and when bills are received or expense, loss, damage or liability is incurred, so long as the indemnified party irrevocably agrees to refund such moneys if it is ultimately determined by a court of competent jurisdiction that such party was not entitled to indemnification. The indemnity agreements contained herein shall be in addition to (a) any cause of action or similar rights of the indemnified party against the indemnifying party or others, and (b) any liabilities the indemnifying party may be subject to pursuant to the law.
LIABILITIES AND INDEMNIFICATION SMC shall be liable for any actual losses, claims, damages or expenses (including any reasonable counsel fees and expenses) resulting from SMC's bad faith, willful misfeasance, reckless disregard of its obligations and duties, negligence or failure to properly perform any of its responsibilities or duties under this agreement. SMC shall not be liable and shall be indemnified and held harmless by the Fund, for any claim, demand or action brought against it arising out of, or in connection with:
A. Bad faith, willful misfeasance, reckless disregard of its duties or negligence of the Board of Directors of the Fund, or SMC's acting upon any instructions properly executed and authorized by the Board of Directors of the Fund;
B. SMC acting in reliance upon advice given by independent counsel retained by the Board of Directors of the Fund. In the event that SMC requests the Fund to indemnify or hold it harmless hereunder, SMC shall use its best efforts to inform the Fund of the relevant facts concerning the matter in question. SMC shall use reasonable care to identify and promptly notify the Fund concerning any matter which presents, or appears likely to present, a claim for indemnification against the Fund. The Fund shall have the election of defending SMC against any claim which may be the subject of indemnification hereunder. In the event the Fund so elects, it will so notify SMC and thereupon the Fund shall take over defenses of the claim, and (if so requested by the Fund, SMC shall incur no further legal or other claims related thereto for which it would be entitled to indemnity hereunder provided, however, that nothing herein contained shall prevent SMC from retaining, at its own expense, counsel to defend any claim. Except with the Fund's prior consent, SMC shall in no event confess any claim or make any compromise in any matter in which the Fund will be asked to indemnify or hold SMC harmless hereunder. PUNITIVE DAMAGES. SMC shall not be liable to the Fund, or any third party, for punitive, exemplary, indirect, special or consequential damages (even if SMC has been advised of the possibility of such damages) arising from its obligations and the services provided under this agreement, including but not limited to loss of profits, loss of use of the shareholder accounting system, cost of capital and expenses of substitute facilities, programs or services. FORCE MAJEURE. Anything in this agreement to the contrary notwithstanding, SMC shall not be liable for delays or errors occurring by reason of circumstances beyond its control, including but not limited to acts of civil or military authority, national emergencies, work stoppages, fire, flood, catastrophe, earthquake, acts of God, insurrection, war, riot, failure of communication or interruption.
Expenses Indemnification Procedure (a) Advancement of Expenses. The Company shall advance all expenses incurred by Indemnitee in connection with the investigation, defense, settlement or appeal of any civil or criminal action, suit or proceeding referenced in Section 1(a) or (b) hereof (but not amounts actually paid in settlement of any such action, suit or proceeding). Indemnitee hereby undertakes to repay such amounts advanced only if, and to the extent that, it shall ultimately be determined that Indemnitee is not entitled to be indemnified by the Company as authorized hereby. The advances to be made hereunder shall be paid by the Company to Indemnitee within thirty (30) days following delivery of a written request therefor by Indemnitee to the Company.
ADVISER’S LIABILITIES AND INDEMNIFICATION (a) The Adviser shall have responsibility for the accuracy and completeness (and liability for the lack thereof) of the statements in the Fund’s offering materials (including the prospectus, the statement of additional information, and advertising and sales materials), except for information supplied by the administrator or the Trust or another third party for inclusion therein.
(b) The Adviser shall be liable to the Fund for any loss (including brokerage charges) incurred by the Fund as a result of any improper investment made by the Adviser in contradiction of the Investment Policies.
(c) In the absence of willful misfeasance, bad faith, negligence, or reckless disregard of the obligations or duties hereunder on the part of the Adviser, the Adviser shall not be subject to liability to the Trust or the Fund or to any shareholder of the Fund for any act or omission in the course of, or connected with, rendering services hereunder or for any losses that may be sustained in the purchase, holding or sale of any security by the Fund. Notwithstanding the foregoing, federal securities laws and certain state laws impose liabilities under certain circumstances on persons who have acted in good faith, and therefore nothing herein shall in any way constitute a waiver or limitation of any rights which the Trust, the Fund or any shareholder of the Fund may have under any federal securities law or state law.
(d) Each party to this Agreement shall indemnify and hold harmless the other party and the shareholders, directors, officers and employees of the other party (any such person, an “Indemnified Party”) against any loss, liability, claim, damage or expense (including the reasonable cost of investigating and defending any alleged loss, liability, claim, damage or expenses and reasonable counsel fees incurred in connection therewith) arising out of the Indemnified Party’s performance or non-performance of any duties under this Agreement; provided, however, that nothing herein shall be deemed to protect any Indemnified Party against any liability to which such Indemnified Party would otherwise be subject by reason of willful misfeasance, bad faith or negligence in the performance of duties hereunder or by reason of reckless disregard of obligations and duties under this Agreement.
(e) No provision of this Agreement shall be construed to protect any Trustee or officer of the Trust, or officer of the Adviser, from liability in violation of Sections 17(h) and (i) of the Investment Company Act.
Indemnification Process and Appeal (a) To obtain indemnification under this Agreement, Indemnitee shall submit to the Company a written request to the Secretary of the Company, including therein or therewith such documentation and information as is reasonably available to Indemnitee and is reasonably necessary to determine whether and to what extent Indemnitee is entitled to indemnification. The Secretary of the Company shall, promptly upon receipt of such a request for indemnification, advise the Board in writing that Indemnitee has requested indemnification.
(b) Upon written request by Indemnitee for indemnification pursuant to the first sentence of Section 4(a) hereof, a determination, if required by applicable law, with respect to Indemnitee's entitlement thereto shall be made in the specific case: (i) if a Change in Control shall have occurred, by Independent Counsel in a written opinion to the Board, a copy of which shall be delivered to Indemnitee; or (ii) if a Change of Control shall not have occurred, (A) by a majority vote of the Disinterested Directors, even though less than a quorum of the Board, or (B) if there are no such Disinterested Directors and, if required by applicable law, or, if such Disinterested Directors so direct, by Independent Counsel in a written opinion to the Board, a copy of which shall be delivered to Indemnitee or (C) if so directed by the Board, by the stockholders of the Company (any such party referenced in (A), (B) or (C) above is referred to herein as the "Reviewing Party"); and, if it is so determined that Indemnitee is entitled to indemnification, payment to Indemnitee shall be made within ten (10) days after such determination. Indemnitee shall cooperate with the person, persons or entity making such determination with respect to Indemnitee's entitlement to indemnification, including providing to such person, persons or entity upon reasonable advance request any documentation or information which is not privileged or otherwise protected from disclosure and which is reasonably available to Indemnitee and reasonably necessary to such determination. Such determination shall be made as promptly as is reasonably practicable, taking into account all facts and circumstances. Any reasonable costs or expenses (including reasonable attorneys' fees and disbursements) actually incurred by Indemnitee in so cooperating with the person, persons or entity making such determination shall be borne by the Company (irrespective of the determination as to Indemnitee's entitlement to indemnification) and the Company hereby indemnifies and agrees to hold Indemnitee harmless therefrom.
(c) In the event the determination of entitlement to indemnification is to be made by Independent Counsel pursuant to Section 4(b) hereof, the Independent Counsel shall be selected as provided in this Section 4(c). If a Change of Control shall not have occurred, the Board shall select the Independent Counsel, and the Company shall give written notice to Indemnitee advising him of the identity of the Independent Counsel so selected. If a Change of Control shall have occurred, the Independent Counsel shall be selected by Indemnitee (unless Indemnitee shall request that such selection be made by the Board, in which event the preceding sentence shall apply), and Indemnitee shall give written notice to the Company advising it of the identity of the Independent Counsel so selected. In either event, Indemnitee or the Company, as the case may be, may, within ten (10) days after such written notice of selection shall have been given, deliver to the Company or to Indemnitee, as the case may be, a written objection to such selection; provided, however, that such objection may be asserted only on the ground that the Independent Counsel so selected does not meet the requirements of "Independent Counsel" as defined in Section 1 of this Agreement, and the objection shall set forth with particularity the factual basis of such assertion. If such written objection is so made and substantiated, the Independent Counsel so selected may not serve as Independent Counsel unless and until such objection is withdrawn or a court has determined that such objection is without merit. If, within 20 days after submission by Indemnitee of a written request for indemnification pursuant to Section 4(a) hereof, no Independent Counsel shall have been selected and not objected to, either the Company or Indemnitee may petition any court of competent jurisdiction for resolution of any objection which shall have been made by the Company or Indemnitee to the other's selection of Independent Counsel and/or for the appointment as Independent Counsel of a person selected by the court or by such other person as the court shall designate, and the person with respect to whom all objections are so resolved or the person so appointed shall act as Independent Counsel under Section 4(b) hereof. The Company shall pay any and all reasonable fees and Expenses of Independent Counsel incurred by such Independent Counsel in connection with acting pursuant to Section 4(b) hereof, and the Company shall pay all reasonable fees and Expenses incident to the procedures of this Section 4(c), regardless of the manner in which such Independent Counsel was selected or appointed. Upon the due commencement of any judicial proceeding or arbitration pursuant to Section 4(d) of this Agreement, Independent Counsel shall be discharged and relieved of any further responsibility in such capacity (subject to the applicable standards of professional conduct then prevailing).
