Consideration Maintenance and Support Sample Clauses

Open Split View

Download

Share

Cite

Consideration Maintenance and Support 

Sample 1Sample 2

Save

Copy

Related to Consideration Maintenance and Support

• Maintenance and Support NCR Voyix is solely responsible for providing any maintenance and support services with respect to the Software as specified in the Agreement, or as required under applicable law. The parties acknowledge that Apple has no obligation whatsoever to furnish any maintenance and support services with respect to the Software.

• Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.

• Service and Support 1. Brainlab shall be responsible for providing service and support for the Brainlab Technology in all Fields of Use. Brainlab shall be responsible for providing Xxxxx 0 and Level 2 service and support to customers for Products sold by Brainlab in the Therapeutic Delivery Field of Use and for Integrated Products sold by Brainlab in the MR Guided Stereotactic Placement Field of Use. Level 1 support shall include onsite training, help desk services, reseller interfacing, problem isolation and diagnosis, and Level 2 support shall include loading bug fixes, patches, and minor repair services. To the extent relating to SurgiVision Technology, SurgiVision shall provide Level 3 support, which shall include backup support services to assist Brainlab in meeting Level 1 and Level 2 support obligations by addressing certain technical support issues that are beyond the scope of Brainlab’s expertise. Brainlab will pay SurgiVision for Xxxxx 0 support services at standard rates as described in Appendix C, provided that such services were not required for Co-Development and Distribution Agreement between SurgiVision, Inc. and Brainlab Aktiengesellschaft CONFIDENTIAL warranty repair as contemplated in section X.3 below. Appendix C may be changed from time to time, as appropriate upon the mutual agreement of Brainlab and SurgiVision. SurgiVision will provide spare parts and other items for service to Brainlab at a price equal to [***]. Brainlab reserves the right to offer service packages to the end customer at its discretion. 2. SurgiVision shall be responsible for providing service and support to customers in the United States for ClearPoint Products sold in the MR Guided Stereotactic Placement Field of Use; provided, however, that SurgiVision shall be responsible for attending only the initial clinical cases using the ClearPoint Products (to the extent attendance is requested by the customer). For the avoidance of any doubt, the foregoing obligation does not apply to Integrated Products. To the extent Brainlab has a service package with the end user customer that covers ClearPoint Products (not including Integrated Products), SurgiVision shall be entitled to reasonable compensation from Brainlab under such arrangement in an amount to be agreed. 3. SurgiVision shall provide training on the ClearPoint Products, including joint attendance of SurgiVision and Brainlab personnel in initial clinical cases in the applicable region, to Brainlab personnel to enable Brainlab personnel to provide service and support to customers outside of the United States.

• Payments for Distribution Assistance and Administrative Support Services (a) Payments to the Distributor. In consideration of the payments made by the Fund to the Distributor under this Plan, the Distributor shall provide administrative support services and distribution services to the Fund. Such services include distribution assistance and administrative support services rendered in connection with Shares (1) sold in purchase transactions, (2) issued in exchange for shares of another investment company for which the Distributor serves as distributor or sub-distributor, or (3) issued pursuant to a plan of reorganization to which the Fund is a party. If the Board believes that the Distributor may not be rendering appropriate distribution assistance or administrative support services in connection with the sale of Shares, then the Distributor, at the request of the Board, shall provide the Board with a written report or other information to verify that the Distributor is providing appropriate services in this regard. For such services, the Fund will make the following payments to the Distributor:

• Services and Support 1.1 In exchange for your continued compliance with this Agreement, and any modification to this Agreement made by Intuit in accordance with Sections A.1.1, you shall have access to the Software/Subscription in accordance with the following provisions: (a) If you purchased a Subscription based license for the Software, which generally means that you will be paying for your use of the Software and Services on a monthly or annual basis, you shall receive as part of your active Subscription, so long as Intuit is receiving the applicable payment from you: (i) access to the features of the Software subscribed to by you; (ii) Updates and Enhancements; (iii) Version Protection, each defined in Section B.1.2 below; and (iv) additional products, services and/or discounts when and if they should be made available to you. If you have purchased a subscription that includes Support you will also be entitled to receive Support Services as defined below. Software licenses obtained through a subscription are eligible for Enhancements during the active subscription period only. The Subscription is cancellable by you in accordance with this Agreement, but you will not be entitled to any refunds if you cancel after the 60-Day Money Back Guarantee period, as defined in Section B.6. If you cancel your Subscription or if we do not receive the payment for your Subscription, or if the Subscription is in any way terminated in accordance with the terms of this Agreement, you will no longer have access to the Software and all related Services defined above upon the expiration of the current Subscription term, but you will retain access to your company data file stored on your device, which can be reinstated to a readable QuickBooks format upon reactivation of your Subscription or with the purchase of a license on the Software. (b) If you purchased your license to the Software under a one-time, upfront payment at retail or directly from Intuit and not under a Subscription, you shall receive: (i) a license to the specific version of the Software product you have selected that, subject to the license grant and restrictions in Section A.1.1, allows you access to the features of the Software; and (ii) Updates and Enhancements to the Software in accordance with the terms of the Termination provisions. Intuit's obligations under this Section B.1.1 are contingent upon you installing all updates and error corrections within thirty (30) days of being notified of their availability by Intuit (or its Representatives). QuickBooks 2015 Software purchased on a separate standalone basis are eligible for enhancements on a when-and-if available basis through May 31, 2018, which is the current support period for QuickBooks 2015.

• Network Maintenance and Management 38.1 The Parties will work cooperatively to implement this Agreement. The Parties will exchange appropriate information (for example, maintenance contact numbers, network information, information required to comply with law enforcement and other security agencies of the government, escalation processes, etc.) to achieve this desired result. 38.2 Each Party will administer its network to ensure acceptable service levels to all users of its network services. Service levels are generally considered acceptable only when End Users are able to establish connections with little or no delay encountered in the network. Each Party will provide a twenty four (24)-hour contact number for Network Traffic Management issues to the other’s surveillance management center. 38.3 Each Party maintains the right to implement protective network traffic management controls, such as “cancel to”, “call gapping” or seven (7)-digit and ten (10)-digit code gaps, to selectively cancel the completion of traffic over its network, including traffic destined for the other Party’s network, when required to protect the public-switched network from congestion as a result of occurrences such as facility failures, switch congestion or failure or focused overload. Each Party shall immediately notify the other Party of any protective control action planned or executed. 38.4 Where the capability exists, originating or terminating traffic reroutes may be implemented by either Party to temporarily relieve network congestion due to facility failures or abnormal calling patterns. Reroutes shall not be used to circumvent normal trunk servicing. Expansive controls shall be used only when mutually agreed to by the Parties. 38.5 The Parties shall cooperate and share pre-planning information regarding cross-network call-ins expected to generate large or focused temporary increases in call volumes to prevent or mitigate the impact of these events on the public-switched network, including any disruption or loss of service to the other Party’s End Users. Facsimile (FAX) numbers must be exchanged by the Parties to facilitate event notifications for planned mass calling events. 38.6 Neither Party shall use any Interconnection Service provided under this Agreement or any other service related thereto or used in combination therewith in any manner that interferes with or impairs service over any facilities of AT&T-21STATE, its affiliated companies or other connecting telecommunications carriers, prevents any carrier from using its Telecommunications Service, impairs the quality or the privacy of Telecommunications Service to other carriers or to either Party’s End Users, causes hazards to either Party’s personnel or the public, damage to either Party’s or any connecting carrier’s facilities or equipment, including any malfunction of ordering or billing systems or equipment. Upon such occurrence either Party may discontinue or refuse service, but only for so long as the other Party is violating this provision. Upon any such violation, either Party shall provide the other Party notice of the violation at the earliest practicable time. 38.7 AT&T TENNESSEE hereby commits to provide Disaster Recovery to CLEC according to the plan below. 38.7.1 AT&T TENNESSEE Disaster Recovery Plan 38.7.2 In the unlikely event of a disaster occurring that affects AT&T TENNESSEE’s long-term ability to deliver traffic to a CLEC, general procedures have been developed by AT&T TENNESSEE to hasten the recovery process in accordance with the Telecommunications Service Priority (TSP) Program established by the FCC to identify and prioritize telecommunication services that support national security or emergency preparedness (NS/EP) missions. A description of the TSP Program as it may be amended from time to time is available on AT&T TENNESSEE’s Wholesale – Southeast Region Web site. Since each location is different and could be affected by an assortment of potential problems, a detailed recovery plan is impractical. However, in the process of reviewing recovery activities for specific locations, some basic procedures emerge that appear to be common in most cases. 38.7.3 These general procedures should apply to any disaster that affects the delivery of traffic for an extended time period. Each CLEC will be given the same consideration during an outage, and service will be restored as quickly as possible. AT&T TENNESSEE reserves the right to make changes to these procedures as improvements become available or as business conditions dictate. 38.7.4 This plan will cover the basic recovery procedures that would apply to every CLEC.

• Support and Maintenance Services Information about Teradici’s support and maintenance for the Licensed Product may be found at xxxxx://xxxx.xxxxxxxx.xxx.

• TAX SUPPORT SERVICES BNY Mellon shall provide the following tax support services for each Fund:  Provide various data and reports as agreed upon in the SLDs to support TRP’s tax reporting and tax filing obligations, including: · Wash sales reporting; · QDI reporting; · DRD reporting; · PFIC analysis; · Straddle analysis; · Paydown adjustments; · Equalization debit adjustments · Tax compliance under §851, §817(h); · Foreign bond sale analysis (§988); · Troubled debt analysis; · Estimation of income for excise tax purposes; · Swap analysis; · Inflation adjustments; · §1256 adjustments; · Market discount analysis; OID adjustments; · CPDI analysis; · Shareholder tax reporting information (e.g. FTC, UGG income, foreign source income by country, exempt income by state);  Provide data, and reports based on such data, maintained by BNY Mellon on its fund accounting platform as reasonably requested by TRP to support TRP’s obligations to comply with requests from tax authorities and TRP’s tax reporting and tax filing obligations.  Assist with other tax-related data needs as mutually agreed upon in writing from time-to-time.

• Record Maintenance and Retention A. Grantee shall keep and maintain under GAAP or GASB, as applicable, full, true, and complete records necessary to fully disclose to the System Agency, the Texas State Auditor’s Office, the United States Government, and their authorized representatives sufficient information to determine compliance with the terms and conditions of this Grant Agreement and all state and federal rules, regulations, and statutes. B. Grantee shall maintain and retain legible copies of this Grant Agreement and all records relating to the performance of the Grant Agreement, including supporting fiscal documents adequate to ensure that claims for grant funds are in accordance with applicable State of Texas requirements. These records shall be maintained and retained by the Grantee for a minimum of seven (7) years after the Grant Agreement expiration date or seven (7) years after all audits, claims, litigation or disputes involving the Grant Agreement are resolved, whichever is later.

• Office and Support Staff During the Employment Period, the Executive shall be entitled to an office or offices of a size and with furnishings and other appointments, and to exclusive personal secretarial and other assistance, at least equal to the most favorable of the foregoing provided to the Executive by the Company and its affiliated companies at any time during the 120-day period immediately preceding the Effective Date or, if more favorable to the Executive, as provided generally at any time thereafter with respect to other peer executives of the Company and its affiliated companies.