Construction Manager The individual, partnership, corporation, joint venture, or any combination thereof, or its authorized representative, named as such by the District. If no Construction Manager is used on the Project that is the subject of this Contract, then all references to Construction Manager herein shall be read to refer to District.
Construction Representatives Landlord appoints the following person(s) as Landlord's representative ("Landlord's Representative") to act for Landlord in all matters covered by this Work Letter: ------------------------ ------------------------ ------------------------ Tenant appoints the following person(s) as Tenant's representative ("Tenant Representative") to act for Tenant in all matters covered by this Work Letter. ------------------------ ------------------------ ------------------------ All communications with respect to the matters covered by this Work Letter are to be made to Landlord's Representative or Tenant's Representative, as the case may be, in writing, in compliance with the notice provisions of the Lease. Either party may change its representative under this Work Letter at any time by written notice to the other party in compliance with the notice provisions of the Lease.
Property Manager Any entity that has been retained to perform and carry out property rental, leasing, operation and management services at one or more of the Properties, excluding persons, entities or independent contractors retained or hired to perform facility management or other services or tasks at a particular Property.
Documentation Agent and Syndication Agent Neither the Documentation Agent nor the Syndication Agent shall have any duties or responsibilities hereunder in its capacity as such.
MANAGING AGENT The Seller will be entitled to appoint the first Managing Agent, which appointment shall be valid and binding on the Body Corporate for a period of 1 (one) year after the date of the first annual general meeting of the Body Corporate, provided that such appointment complies with section 6(2) of the Rules. Insofar as it may be necessary, the Purchaser hereby grants the Seller the irrevocable power to make such appointment.
Other Agents; Arrangers and Managers None of the Lenders or other Persons identified on the facing page or signature pages of this Agreement as a “syndication agent,” “documentation agent,” “co-agent,” “book manager,” “lead manager,” “arranger,” “lead arranger” or “co-arranger” shall have any right, power, obligation, liability, responsibility or duty under this Agreement other than, in the case of such Lenders, those applicable to all Lenders as such. Without limiting the foregoing, none of the Lenders or other Persons so identified shall have or be deemed to have any fiduciary relationship with any Lender. Each Lender acknowledges that it has not relied, and will not rely, on any of the Lenders or other Persons so identified in deciding to enter into this Agreement or in taking or not taking action hereunder.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
The Agent Each of the Lenders hereby irrevocably appoints the Agent as its agent and authorizes the Agent to take such actions on its behalf and to exercise such powers as are delegated to the Agent by the terms of the Loan Documents, together with such actions and powers as are reasonably incidental thereto. In the event the institution serving as the Agent hereunder shall also be a Lender, it shall have the same rights and powers in its capacity as a Lender as any other Lender and may exercise the same as though it were not the Agent, and such institution and its Affiliates may accept deposits from, lend money to and generally engage in any kind of business with Level 3, the Borrower or any Subsidiary or Affiliate thereof as if it were not the Agent hereunder. The Agent shall not have any duties or obligations except those expressly set forth in the Loan Documents. Without limiting the generality of the foregoing, (a) the Agent shall not be subject to any fiduciary or other implied duties, regardless of whether a Default has occurred and is continuing, (b) the Agent shall not have any duty to take any discretionary action or exercise any discretionary powers, except discretionary rights and powers expressly contemplated by the Loan Documents that the Agent is required to exercise in writing by the Required Lenders (or such other number or percentage of the Lenders as shall be necessary under the circumstances as provided in Section 9.02), and shall not have any duty to take any action or exercise any powers that would result in the incurrence by it of costs or expenses unless arrangements satisfactory to it to ensure the prompt payment of all such costs or expenses shall have been made by the Lenders, and (c) except as expressly set forth in the Loan Documents, the Agent shall not have any duty to disclose, and shall not be liable for the failure to disclose, any information relating to Xxxxx 0, the Borrower or any of the Subsidiaries of Level 3 that is communicated to or obtained by the institution serving as Agent or any of its Affiliates in any capacity. The Agent shall not be liable for any action taken or not taken by it with the consent or at the request of the Required Lenders (or such other number or percentage of the Lenders as shall be necessary under the circumstances as provided in Section 9.02) or in the absence of its own gross negligence or willful misconduct. The Agent shall be deemed not to have knowledge of any Default unless and until written notice thereof is given to the Agent by Xxxxx 0, the Borrower or a Lender, and the Agent shall not be responsible for or have any duty to ascertain or inquire into (i) any statement, warranty or representation made in or in connection with any Loan Document, (ii) the contents of any certificate, report or other document delivered thereunder or in connection therewith, (iii) the performance or observance of any of the covenants, agreements or other terms or conditions set forth in any Loan Document, (iv) the validity, enforceability, effectiveness or genuineness of any Loan Document or any other agreement, instrument or document, or (v) the satisfaction of any condition set forth in Article IV or elsewhere in any Loan Document, other than to confirm receipt of items expressly required to be delivered to the Agent. As to any matters not expressly provided for by this Agreement and the other Loan Documents (including enforcement or collection), the Administrative Agent and the Collateral Agent shall not be required to exercise any discretion or take any action, but shall be required to act or to refrain from acting (and shall be fully protected in so acting or refraining from acting) upon the instructions of the Requisite Lenders, and such instructions shall be binding upon all Lenders, provided, however, that the Administrative Agent and the Collateral Agent shall not be required to take any action that (i) the Administrative Agent or the Collateral Agent in good faith believes exposes it to personal liability unless it receives an indemnification satisfactory to it from the Lenders with respect to such action or (ii) is contrary to this Agreement or applicable law. The Agent shall be entitled to rely upon, and shall not incur any liability for relying upon, any notice, request, certificate, consent, statement, instrument, document or other writing believed by it to be genuine and to have been signed or sent by the proper Person. The Agent also may rely upon any statement made to it orally or by telephone and believed by it to be made by the proper Person, and shall not incur any liability for relying thereon. The Agent may consult with legal counsel (who may be counsel for Level 3 or the Borrower), independent accountants and other experts selected by it, and shall not be liable for any action taken or not taken by it in accordance with the advice of any such counsel, accountants or experts. The Agent may perform any and all its duties and exercise its rights and powers by or through any one or more sub-agents appointed by the Agent. The Agent and any such sub-agent may perform any and all its duties and exercise its rights and powers through their respective Related Parties. The exculpatory provisions of the preceding paragraphs shall apply to any such sub-agent and to the Related Parties of each Agent and any such sub-agent, and shall apply to their respective activities in connection with the syndication of the credit facilities provided for herein as well as activities as Agent. Subject to the appointment and acceptance of a successor as provided in this paragraph, the Agent may resign at any time by notifying the Lenders and Level 3. Upon any such resignation, the Required Lenders shall have the right, with, so long as no Default or Event of Default shall have occurred and be continuing, the consent of Level 3 (which consent shall not be unreasonably withheld or delayed) to appoint a successor. If no successor shall have been so appointed by the Required Lenders and shall have accepted such appointment within 30 days after the retiring Agent gives notice of its resignation, then the retiring Agent may, on behalf of the Lenders, appoint a successor Agent which shall be a Lender or a bank with an office in New York, New York, or an Affiliate of such Lender or any such bank. Upon the acceptance of its appointment as Agent hereunder by a successor, such successor shall succeed to and become vested with all the rights, powers, privileges and duties of the retiring Agent, and the retiring Agent shall be discharged from its duties and obligations hereunder. The fees payable by Level 3 and the Borrower to a successor Agent shall be the same as those payable to its predecessor unless otherwise agreed with such successor. After the Agent’s resignation hereunder, the provisions of this Article and Section 9.03 shall continue in effect for the benefit of such retiring Agent, its sub-agents and their respective Related Parties in respect of any actions taken or omitted to be taken by any of them while it was acting as Agent. Each Lender acknowledges that it has, independently and without reliance upon the Agent or any other Lender and based on such documents and information as it has deemed appropriate, made its own credit analysis and decision to enter into this Agreement. Each Lender also acknowledges that it will, independently and without reliance upon the Agent or any other Lender and based on such documents and information as it shall from time to time deem appropriate, continue to make its own decisions in taking or not taking action under or based upon this Agreement, any other Loan Document or related agreement or any document furnished hereunder or thereunder.
The Administrative Agent and the Collateral Agent Each of the Lenders and the Issuing Bank hereby irrevocably appoints the Administrative Agent and the Collateral Agent (for purposes of this Article VIII, the Administrative Agent and the Collateral Agent are referred to collectively as the "Agents") its agent and authorizes the Agents to take such actions on its behalf and to exercise such powers as are delegated to such Agent by the terms of the Loan Documents, together with such actions and powers as are reasonably incidental thereto. Without limiting the generality of the foregoing, the Agents are hereby expressly authorized to execute any and all documents (including releases) with respect to the Collateral and the rights of the Secured Parties with respect thereto, as contemplated by and in accordance with the provisions of this Agreement and the Security Documents. The bank serving as the Administrative Agent and/or the Collateral Agent hereunder shall have the same rights and powers in its capacity as a Lender as any other Lender and may exercise the same as though it were not an Agent, and such bank and its Affiliates may accept deposits from, lend money to and generally engage in any kind of business with Holdings, the Borrower or any Subsidiary or other Affiliate thereof as if it were not an Agent hereunder. Neither Agent shall have any duties or obligations except those expressly set forth in the Loan Documents. Without limiting the generality of the foregoing, (a) neither Agent shall be subject to any fiduciary or other implied duties, regardless of whether a Default has occurred and is continuing, (b) neither Agent shall have any duty to take any discretionary action or exercise any discretionary powers, except discretionary rights and powers expressly contemplated hereby that such Agent is required to exercise in writing by the Required Lenders (or such other number or percentage of the Lenders as shall be necessary under the circumstances as provided in Section 9.08), and (c) except as expressly set forth in the Loan Documents, neither Agent shall have any duty to disclose, nor shall it be liable for the failure to disclose, any information relating to Holdings, the Borrower or any of the Subsidiaries that is communicated to or obtained by the bank serving as Administrative Agent and/or Collateral Agent or any of its Affiliates in any capacity. Neither Agent shall be liable for any action taken or not taken by it with the consent or at the request of the Required Lenders (or such other number or percentage of the Lenders as shall be necessary under the circumstances as provided in Section 9.08) or in the absence of its own gross negligence or wilful misconduct. Neither Agent shall be deemed to have knowledge of any Default unless and until written notice thereof is given to such Agent by Holdings, the Borrower or a Lender, and neither Agent shall be responsible for or have any duty to ascertain or inquire into (i) any statement, warranty or representation made in or in connection with any Loan Document, (ii) the contents of any certificate, report or other document delivered thereunder or in connection therewith, (iii) the performance or observance of any of the covenants, agreements or other terms or conditions set forth in any Loan Document, (iv) the validity, enforceability, effectiveness or genuineness of any Loan Document or any other agreement, instrument or document, or (v) the satisfaction of any condition set forth in Article IV or elsewhere in any Loan Document, other than to confirm receipt of items expressly required to be delivered to such Agent. Each Agent shall be entitled to rely upon, and shall not incur any liability for relying upon, any notice, request, certificate, consent, statement, instrument, document or other writing believed by it to be genuine and to have been signed or sent by the proper person. Each Agent may also rely upon any statement made to it orally or by telephone and believed by it to have been made by the proper person, and shall not incur any liability for relying thereon. Each Agent may consult with legal counsel (who may be counsel for the Borrower), independent accountants and other experts selected by it, and shall not be liable for any action taken or not taken by it in accordance with the advice of any such counsel, accountants or experts. Each Agent may perform any and all its duties and exercise its rights and powers by or through any one or more sub-agents appointed by it. Each Agent and any such sub-agent may perform any and all its duties and exercise its rights and powers by or through their respective Related Parties. The exculpatory provisions of the preceding paragraphs shall apply to any such sub-agent and to the Related Parties of each Agent and any such sub-agent, and shall apply to their respective activities in connection with the syndication of the credit facilities provided for herein as well as activities as Agent. Subject to the appointment and acceptance of a successor Agent as provided below, either Agent may resign at any time by notifying the Lenders, the Issuing Bank and the Borrower. Upon any such resignation, the Required Lenders shall have the right, in consultation with the Borrower and, unless an Event of Default shall have occurred and be continuing, with the consent of the Borrower (which shall not be unreasonably withheld), to appoint a successor. If no successor shall have been so appointed by the Required Lenders and shall have accepted such appointment within 30 days after the retiring Agent gives notice of its resignation, then the retiring Agent may, on behalf of the Lenders and the Issuing Bank, appoint a successor Agent which shall be a bank with an office in New York, New York, or an Affiliate of any such bank. Upon the acceptance of its appointment as Agent hereunder by a successor, such successor shall succeed to and become vested with all the rights, powers, privileges and duties of the retiring Agent, and the retiring Agent shall be discharged from its duties and obligations hereunder. The fees payable by the Borrower to a successor Agent shall be the same as those payable to its predecessor unless otherwise agreed between the Borrower and such successor. After an Agent's resignation hereunder, the provisions of this Article and Section 9.05 shall continue in effect for the benefit of such retiring Agent, its sub-agents and their respective Related Parties in respect of any actions taken or omitted to be taken by any of them while acting as Agent. Each Lender acknowledges that it has, independently and without reliance upon the Agents or any other Lender and based on such documents and information as it has deemed appropriate, made its own credit analysis and decision to enter into this Agreement. Each Lender also acknowledges that it will, independently and without reliance upon the Agents or any other Lender and based on such documents and information as it shall from time to time deem appropriate, continue to make its own decisions in taking or not taking action under or based upon this Agreement or any other Loan Document, any related agreement or any document furnished hereunder or thereunder.
The Trustee and the Collateral Agent Neither the Trustee nor the Collateral Agent make any representation or warranty as to the validity or sufficiency of this Supplemental Indenture or with respect to the recitals contained herein, all of which recitals are made solely by the other parties hereto.
