ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9. § 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage. § 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage. § 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages
Project Deliverables The Contractor shall provide each of the following deliverables in writing to the City for review and approval to achieve the project objectives. C.1. <Title> Deliverable 1
Detailed Description of Services / Statement of Work Describe fully the services that Contractor will provide, or add and attach Exhibit B to this Agreement.
SCOPE OF ARCHITECT’S BASIC SERVICES 3.1 The Architect’s Basic Services consist of those described in this Article 3 and include usual and customary structural, mechanical, and electrical engineering services. Services not set forth in this Article 3 are Supplemental or Additional Services. § 3.1.1 The Architect shall manage the Architect’s services, research applicable design criteria, attend Project meetings, communicate with members of the Project team, and report progress to the Owner. § 3.1.2 The Architect shall coordinate its services with those services provided by the Owner and the Owner’s consultants. The Architect shall be entitled to rely on, and shall not be responsible for, the accuracy, completeness, and timeliness of, services and information furnished by the Owner and the Owner’s consultants. The Architect shall provide prompt written notice to the Owner if the Architect becomes aware of any error, omission, or inconsistency in such services or information. § 3.1.3 As soon as practicable after the date of this Agreement, the Architect shall submit for the Owner’s approval a schedule for the performance of the Architect’s services. The schedule initially shall include anticipated dates for the commencement of construction and for Substantial Completion of the Work as set forth in the Initial Information. The schedule shall include allowances for periods of time required for the Owner’s review, for the performance of the Owner’s consultants, and for approval of submissions by authorities having jurisdiction over the Project. Once approved by the Owner, time limits established by the schedule shall not, except for reasonable cause, be exceeded by the Architect or Owner. With the Owner’s approval, the Architect shall adjust the schedule, if necessary, as the Project proceeds until the commencement of construction. § 3.1.4 The Architect shall not be responsible for an Owner’s directive or substitution, or for the Owner’s acceptance of non-conforming Work, made or given without the Architect’s written approval. § 3.1.5 The Architect shall contact governmental authorities required to approve the Construction Documents and entities providing utility services to the Project. The Architect shall respond to applicable design requirements imposed by those authorities and entities. § 3.1.6 The Architect shall assist the Owner in connection with the Owner’s responsibility for filing documents required for the approval of governmental authorities having jurisdiction over the Project.
Information Systems Acquisition Development and Maintenance a. Client Data – Client Data will only be used by State Street for the purposes specified in this Agreement.
SERVICES & DELIVERABLES Seller agrees to perform the services ("Services") and/or provide the goods ("Goods", which term shall include goods provided as part of any Services), described in any PO, in accordance with the applicable PO and with this Agreement. Acceptance of a PO and this Agreement shall occur (i) within five (5) days of receipt by the Seller; or, (ii) upon shipment of Goods; or, (iii) upon commencement of a Service, (whichever is the earlier). Seller shall be bound by the provisions of this Agreement, including all provisions set forth on the face of any applicable PO, whether Seller acknowledges or otherwise signs this Agreement or the PO, unless Seller objects to such terms in writing within five (5) days of receiving the Agreement and/or the PO, prior to shipping Goods or prior to commencing Services. This writing does not constitute a firm offer and may be revoked at any time prior to acceptance. This Agreement may not be added to, modified, superseded, or otherwise altered, except by a writing signed by an authorized Apple representative and specifically stated to be an amendment of this Agreement. Any terms or conditions contained in any acknowledgment, invoice, or other communication of Seller which are inconsistent with the terms and conditions of this Agreement, are hereby rejected. To the extent that this Agreement might be treated as an acceptance of Seller's prior offer, such acceptance is expressly made on condition of assent by Seller to the terms hereof and shipment of the Goods or beginning performance of any Services by Seller shall constitute such acceptance. Apple hereby reserves the right to reschedule any delivery or cancel any PO issued at any time prior to shipment of the Goods or prior to commencement of any Services. Apple shall not be subject to any charges or other fees as a result of such cancellation.
Contractor’s Project Manager and Key Personnel Contractor shall appoint a Project Manager to direct the Contractor’s efforts in fulfilling Contractor’s obligations under this Contract. This Project Manager shall be subject to approval by the County and shall not be changed without the written consent of the County’s Project Manager, which consent shall not be unreasonably withheld. The Contractor’s Project Manager shall be assigned to this project for the duration of the Contract and shall diligently pursue all work and services to meet the project time lines. The County’s Project Manager shall have the right to require the removal and replacement of the Contractor’s Project Manager from providing services to the County under this Contract. The County’s Project manager shall notify the Contractor in writing of such action. The Contractor shall accomplish the removal within five (5) business days after written notice by the County’s Project Manager. The County’s Project Manager shall review and approve the appointment of the replacement for the Contractor’s Project Manager. The County is not required to provide any additional information, reason or rationale in the event it The County is not required to provide any additional information, reason or rationale in the event it requires the removal of Contractor’s Project Manager from providing further services under the Contract.
Professional Engineering and Architect’s Services Professional Engineering and Architect’s Services are not permitted to be provided under this Agreement. Texas statutes prohibit the procurement of Professional Engineering and Architect’s Services through a cooperative agreement.
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Contractor Responsibility for System Agency’s Termination Costs If the System Agency terminates the Contract for cause, the Contractor shall be responsible to the System Agency for all costs incurred by the System Agency and the State of Texas to replace the Contractor. These costs include, but are not limited to, the costs of procuring a substitute vendor and the cost of any claim or litigation attributable to Contractor’s failure to perform any Work in accordance with the terms of the Contract.