Use of Subconsultants If Attachment B of an Approved Service Order authorizes the use of one or more subconsultants, then it will identify the name of each such subconsultant and the portion of Work each such subconsultant will perform. The Director’s prior written consent is required for the Consultant to remove, replace or add to the subconsultants identified in Attachment B.
Use of Subcontractors Nothing in this Appendix 2 shall prevent the Interconnection Parties from utilizing the services of subcontractors as they deem appropriate to perform their respective obligations hereunder, provided, however, that each Interconnection Party shall require its subcontractors to comply with all applicable terms and conditions of this Appendix 2 in providing such services.
Subconsultants Whichever of the following is marked applies to this Approved Service Order: The Consultant can not use any subconsultants. The Consultant can use the following subconsultants to assist in providing the required services and deliverables:
2. 3.
EMPLOYEES, SUBCONTRACTORS & AGENTS All employees, Subcontractors or agents performing work under the Contract must be trained staff or technicians who meet or exceed the professional, technical and training qualifications set forth in the Bid Specifications or the Bid Documents, whichever is more restrictive, and must comply with all security and administrative requirements of the Authorized User. The Commissioner reserves the right to conduct a security background check or otherwise approve any employee, Subcontractor or agent furnished by Contractor and to refuse access to or require replacement of any personnel for cause based on, including but not limited to, professional, technical or training qualifications, quality of work or change in security status or non- compliance with Authorized User’s security or other requirements. Such approval shall not relieve the Contractor of the obligation to perform all work in compliance with the Contract terms. The Commissioner reserves the right to reject and/or bar from the facility for cause any employee, Subcontractor, or agents of the Contractor.
Use of Sub-Contractors If the Applicant requires the use of a Sub-Contractor in order to adequately complete the Project, a collaboration letter, contract or agreement between the Applicant and the Sub-Contractor must be in place prior to the Applicant proceeding with any Milestone which requires assistance from the Sub-Contractor. Applicant shall: (a) identify the Sub-Contractor to Alberta Innovates; (b) provide a copy of such Sub- Contractor agreement to Alberta Innovates upon request, and on a strictly confidential basis; and (c) ensure that dealings with the Sub-Contractor are not prohibited under any Applicable Laws Including any Anti- Bribery, Anti-Corruption and Sanctions Laws or Export Control Laws. Alberta Innovates may request the Applicant to provide evidence that it has paid the Sub-Contractor for such services. If the Applicant is using a Sub-Contractor: (aa) nothing in this Investment Agreement creates any employment, contract, agency relationship, or other direct or indirect, relationship of any kind between Alberta Innovates and such Sub-Contractor; and (bb) the Applicant shall be solely responsible for all work, acts, claims, defaults and liabilities relating to the Sub-Contractor.
Architects, Consultants and Contractors Landlord and Tenant hereby acknowledge and agree that: (i) the general contractor and any subcontractors for the Tenant Improvements shall be selected by Landlord, subject to Tenant’s approval, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) DGA shall be the architect (the “TI Architect”) for the Tenant Improvements.
Contractor’s Employees and Subcontractors (a) Contractor shall only disclose PII to Contractor’s employees and subcontractors who need to know the PII in order to provide the Services and the disclosure of PII shall be limited to the extent necessary to provide such Services. Contractor shall ensure that all such employees and subcontractors comply with the terms of this DPA.
(b) Contractor must ensure that each subcontractor performing functions pursuant to the Service Agreement where the subcontractor will receive or have access to PII is contractually bound by a written agreement that includes confidentiality and data security obligations equivalent to, consistent with, and no less protective than, those found in this DPA.
(c) Contractor shall examine the data security and privacy measures of its subcontractors prior to utilizing the subcontractor. If at any point a subcontractor fails to materially comply with the requirements of this DPA, Contractor shall: notify the EA and remove such subcontractor’s access to PII; and, as applicable, retrieve all PII received or stored by such subcontractor and/or ensure that PII has been securely deleted and destroyed in accordance with this DPA. In the event there is an incident in which the subcontractor compromises PII, Contractor shall follow the Data Breach reporting requirements set forth herein.
(d) Contractor shall take full responsibility for the acts and omissions of its employees and subcontractors.
(e) Contractor must not disclose PII to any other party unless such disclosure is required by statute, court order or subpoena, and the Contractor makes a reasonable effort to notify the EA of the court order or subpoena in advance of compliance but in any case, provides notice to the EA no later than the time the PII is disclosed, unless such disclosure to the EA is expressly prohibited by the statute, court order or subpoena.
Replacement of Key Personnel The Engineer must notify the State in writing as soon as possible, but no later than three business days after a project manager or other key personnel is removed from association with this contract, giving the reason for removal.
Employees and Subcontractors It is understood that, from time to time, it may become necessary for the Contractor to replace an individual working as an employee or subcontractor of the Contractor. All such removals or replacements shall be subject to Owner’s prior approval. Owner reserves the right to approve a replacement, which approval shall not be unreasonably withheld, or terminate the Work, either partially or in its entirety without further obligation to the Contractor thereunder other than to remit payment for the Work rendered up to the termination date. Contractor agrees that Owner may, at any time, with cause, require Contractor to remove an individual from the performance of the Work. An election by Owner of any of its rights under this Section 19 shall not affect the Contractor’s responsibilities, liabilities or warranties under this Agreement.
Contractor’s Services shall be performed in accordance with generally accepted professional practices and principles and in a manner consistent with the level of care and skill ordinarily exercised by members of Contractor’s profession currently practicing under similar conditions. Contractor shall comply with the profession’s standard of performance, applicable laws, regulations, and industry standards. By delivery of completed work, Contractor certifies that the work conforms to the requirements of this Agreement and all applicable federal, state and local laws. If Contractor is retained to perform services requiring a license, certification, registration or other similar requirement under California law, Contractor shall maintain that license, certification, registration or other similar requirement throughout the term of this Agreement.
