Power of the Authority to undertake works (i) In the event the Parties are unable to agree to the proposed Change of Scope Orders in accordance with Clause 13.2, the Authority may, after giving notice to the Contractor and considering its reply thereto, award such Works or services to any person or agency on the basis of open competitive bidding. It is also agreed that the Contractor shall provide assistance and cooperation to the person or agency who undertakes the works or services hereunder. The Contractor shall not be responsible for rectification of any Defects, but the Contractor shall carry out maintenance of such works after completion of Defect Liability Period of work by other person or agency during the remaining period of this agreement without any extra payment. (ii) The Works undertaken in accordance with this Clause 13.5 shall conform to the Specifications and Standards and shall be carried out in a manner that minimises the disruption in operation of the Project Highway. The provisions of this Agreement, insofar as they relate to Works and Tests, shall apply mutatis mutandis to the Works carried out under this Clause 13.5.
No Felony Criminal Convictions Contractor represents that neither Contractor nor any of its employees, agents, or representatives, including any subcontractors and employees, agents, or representative of such subcontractors, have been convicted of a felony criminal offense or that if such a conviction has occurred Contractor has fully advised System Agency in writing of the facts and circumstances surrounding the convictions.
Prohibition on Contracts with Companies Boycotting Israel To the extent that Texas Government Code, Chapter 2271 applies to this Agreement, PROVIDER certifies that (a) it does not currently boycott Israel; and (b) it will not boycott Israel during the term of this Agreement. PROVIDER acknowledges this Agreement may be terminated and payment withheld if this certification is inaccurate.
No Undisclosed Events, Liabilities, Developments or Circumstances No event, liability, development or circumstance has occurred or exists, or is reasonably expected to exist or occur with respect to the Company, any of its Subsidiaries or any of their respective businesses, properties, liabilities, prospects, operations (including results thereof) or condition (financial or otherwise), that (i) would be required to be disclosed by the Company under applicable securities laws on a registration statement on Form S-1 filed with the SEC relating to an issuance and sale by the Company of its Common Stock and which has not been publicly announced, (ii) could have a material adverse effect on any Buyer’s investment hereunder or (iii) could have a Material Adverse Effect.
Our Liability for Failure to Make Transfers If we do not complete a transfer to or from your account on time or in the correct amount according to our agreement with you, we will be liable for your losses or damages. However, there are some exceptions. We will not be liable, for instance:
Agreements; Action (a) Except for agreements explicitly contemplated hereby and agreements between the Company and its employees with respect to the sale of the Company’s outstanding Common Stock, there are no agreements, understandings, or proposed transactions between the Company and any of its officers, directors, employees, affiliates, or any affiliate thereof. (b) There are no agreements, understandings, instruments, contracts, proposed transactions, judgments, orders, writs or decrees to which the Company is a party or to its knowledge by which it is bound which may involve (i) future obligations (contingent or otherwise) of, or payments to, the Company in excess of what is in the “budget” for going public, or (ii) the transfer or license of any patent, copyright, trade secret or other proprietary right to or from the Company (other than licenses by the Company of “off the shelf” or other standard products), or (iii) provisions restricting the development, manufacture or distribution of the Company’s products or services or (iv) indemnification by the Company with respect to infringements of proprietary rights. (c) The Company has not (i) accrued, declared or paid any dividends, or authorized or made any distribution upon or with respect to any class or series of its capital stock, (ii) incurred or guaranteed any indebtedness for money borrowed or any other liabilities (other than trade payables incurred in the ordinary course of business) individually in excess of what is contemplated in the “budget” for going public (iii) made any loans or advances to any person, other than ordinary advances for travel expenses, or (iv) sold, exchanged or otherwise disposed of any of its assets or rights, other than the sale of its inventory in the ordinary course of business. (d) For the purposes of subsections (b) and (c) above, all indebtedness, liabilities, agreements, understandings, instruments, contracts and proposed transactions involving the same person or entity (including persons or entities the Company has reason to believe are affiliated therewith) shall be aggregated for the purpose of meeting the individual minimum dollar amounts of such subsections.
CREDIT UNION LIABILITY FOR FAILURE TO MAKE TRANSFERS If we do not complete a transfer to or from your account on time or in the correct amount according to our agreement with you, we may be liable for your losses or damages. However, we will not be liable for direct or consequential damages in the following events:
NO STRIKES AND NO LOCKOUTS 5:01 The Employer undertakes that there will be no lockout as defined in the Labour Relations Act during the term of this Agreement. The Union undertakes that there will be no strike as defined in the Labour Relations Act during the term of this Agreement.
Contracts (Rights of Third Parties) Act 1999 A person who is not a party to this Agreement will not have any right under the Contracts (Rights of Third Parties) Act 1999 to enforce any of its terms but this will not affect any right or remedy of a third party which exists or is available apart from that Act.
No Rights or Liabilities as a Shareholder This Warrant shall not entitle the holder hereof to any voting rights or other rights as a shareholder of the Company. No provision of this Warrant, in the absence of affirmative action by the holder hereof to purchase Warrant Shares, and no mere enumeration herein of the rights or privileges of the holder hereof, shall give rise to any liability of such holder for the Exercise Price or as a shareholder of the Company, whether such liability is asserted by the Company or by creditors of the Company.