Contract Disputes The Parties shall deal in good faith and attempt to resolve potential disputes informally. If the dispute concerning a question of fact arising under the terms of this Contract is not disposed of in a reasonable period of time by the Contractor’s Supervisor and the County‘s project manager as specified in Article 25. Notices by way of the following process, such matter shall be brought to the attention of the County DPA by way of the following process:
i. The Contractor shall submit to the County DPA a written demand for a final decision regarding the disposition of any dispute between the Parties arising under, related to, or involving this Contract, unless the County, on its own initiative, has already rendered such a final decision.
ii. The Contractor’s written demand shall be fully supported by factual information, and, if such demand involves a cost adjustment to the Contract, the Contractor shall include with the demand a written statement signed by a senior official indicating that the demand is made in good faith, that the supporting data are accurate and complete, and that the amount requested accurately reflects the Contract adjustment for which the Contractor believes the County is liable.
iii. Pending the final resolution of any dispute arising under, related to, or involving this Contract, the Contractor agrees to diligently proceed with the performance of this Contract, including the delivery of goods and/or provision of services. The Contractor’s failure to diligently proceed shall be considered a material breach of this Contract. Any final decision of the County shall be expressly identified as such, shall be in writing, and shall be signed by the County DPA or his designee. If the County fails to render a decision within 90 days after receipt of the Contractor’s demand, it shall be deemed a final decision adverse to the Contractor’s contentions. The County’s final decision shall be conclusive and binding regarding the dispute unless the Contractor commences action in a court of competent jurisdiction to contest such decision within 90 days following the date of the County’s final decision or one year following the accrual of the cause of action, whichever is later.
Arbitration Decisions Unless otherwise agreed by the Parties, the arbitrator(s) shall render a decision within ninety (90) Calendar Days of appointment and shall notify the Parties in writing of such decision and the reasons therefor. The arbitrator(s) shall be authorized only to interpret and apply the provisions of this LGIA and shall have no power to modify or change any provision of this Agreement in any manner. The decision of the arbitrator(s) shall be final and binding upon the Parties, and judgment on the award may be entered in any court having jurisdiction. The decision of the arbitrator(s) may be appealed solely on the grounds that the conduct of the arbitrator(s), or the decision itself, violated the standards set forth in the Federal Arbitration Act or the Administrative Dispute Resolution Act. The final decision of the arbitrator(s) must also be filed with FERC if it affects jurisdictional rates, terms and conditions of service, Interconnection Facilities, or Network Upgrades.
Audit Dispute In the event of a dispute with respect to any audit conducted under Section 6.10.1, Xxxxxxx and Forest shall work in good faith to resolve the disagreement. If the Parties are unable to reach a mutually acceptable resolution of any such dispute within [*] days, the dispute shall be submitted for resolution to a certified public accounting firm jointly selected by each Party’s certified public accountants or to such other Person as the Parties shall mutually agree (the “Accountant”). The decision of the Accountant shall be final and the costs of such arbitration as well as the initial audit shall be borne between the Parties in such manner as the Accountant shall determine. If the Accountant concludes that additional payments were owed, or that excess payments were made during such period, then the Party owing such additional payments shall pay such additional amounts, or the Party that received such excess payments shall reimburse such excess payments, as applicable, in either case, within [*] days after the date on which such decision is made by the Accountant.
Payment Disputes We will not exercise Our rights under Section 6.3 (Overdue Charges) or 6.4 (Suspension of Service and Acceleration) above if You are disputing the applicable charges reasonably and in good faith and are cooperating diligently to resolve the dispute.
Arbitration Decision The arbitrator’s decision will be final and binding. The arbitrator shall issue a written arbitration decision revealing the essential findings and conclusions upon which the decision and/or award is based. A party’s right to appeal the decision is limited to grounds provided under applicable federal or state law.
Informal Dispute Resolution Process 1. In the event there is a dispute under this Centralized Contract, the Contractor, OGS and Authorized User agree to exercise their best efforts to resolve the dispute as soon as possible. The Contractor, OGS and Authorized User shall, without delay, continue to perform their respective obligations under this Centralized Contract which are not affected by the dispute. Primary responsibility for resolving any dispute arising under this Centralized Contract shall rest with the Authorized User’s Contractor Coordinators and the Contractor’s Account Executive and the State & Local Government Regional General Manager.
2. In the event the Authorized User is dissatisfied with the Contractor’s Products provided under this Centralized Contract, the Authorized User shall notify the Contractor in writing pursuant to the terms of the Contract. In the event the Contractor has any disputes with the Authorized User, the Contractor shall so notify the Authorized User in writing. If either party notifies the other of such dispute, the other party shall then make good faith efforts to solve the problem or settle the dispute amicably, including meeting with the party’s representatives to attempt diligently to reach a satisfactory result through negotiation.
3. If negotiation between the Contractor and Authorized User fails to resolve any such dispute to the satisfaction of the parties within fourteen (14) business days or as otherwise agreed to by the Contractor and Authorized User, of such notice, then the matter shall be submitted to the State's Contract Administrator and the Contractor’s senior executive officer representative. Such representatives shall meet in person and shall attempt in good faith to resolve the dispute within the next fourteen (14) business days or as otherwise agreed to by the parties. This meeting must be held before either party may seek any other method of dispute resolution, including judicial or governmental resolutions. Notwithstanding the foregoing, this section shall not be construed to prevent either party from seeking and obtaining temporary equitable remedies, including injunctive relief.
4. The Contractor shall extend the informal dispute resolution period for so long as the Authorized User continues to make reasonable efforts to cure the breach, except with respect to disputes about the breach of payment of fees or infringement of its or its licensors’ intellectual property rights.
Informal Dispute Resolution (a) Prior to the initiation of formal dispute resolution procedures (i.e., arbitration), the Parties shall first attempt to resolve their dispute at the senior manager level. If that level of dispute resolution is not successful, the Parties shall proceed informally, as follows:
(i) Upon the written request of either Party, each Party shall appoint a designated representative who does not otherwise devote substantially full time to performance under this Agreement, whose task it will be to meet for the purpose of endeavoring to resolve such dispute.
(ii) The designated representatives shall meet as often as the Parties reasonably deem necessary in order to gather and furnish to the other all information with respect to the matter in issue that the Parties believe to be appropriate and germane in connection with its resolution. The representatives shall discuss the problem and attempt to resolve the dispute without the necessity of any formal proceeding.
(iii) During the course of discussion, all reasonable requests made by one Party to another for non-privileged non-confidential information reasonably related to this Agreement shall be honored so that each of the Parties may be fully advised of the other's position.
(iv) The specific format for the discussions shall be left to the discretion of the designated representatives.
(b) Prior to instituting formal proceedings, the Parties will first have their chief executive officers meet to discuss the dispute. This requirement shall not delay the institution of formal proceedings past any statute of limitations expiration or for more than fifteen (15) days.
(c) Subject to Subsection (b), formal proceedings for the resolution of a dispute may not be commenced until the earlier of:
(i) The designated representatives concluding in good faith that amicable resolution through continued negotiation of the matter does not appear likely; or
(ii) Thirty (30) days after the initial written request to appoint a designated representative pursuant to Subsection (a), above, (this period shall be deemed to run notwithstanding any claim that the process described in this Section 11.2 was not followed or completed).
(d) This Section 11.2 shall not be construed to prevent a Party from instituting, and a Party is authorized to institute, formal proceedings earlier to avoid the expiration of any applicable limitations period, or to preserve a superior position with respect to other creditors or as provided in Section 11.6(a).
Alternate Dispute Resolution In the event of any issue of controversy under this Agreement, the PARTIES may pursue Alternate Dispute Resolution procedures to voluntarily resolve those issues. These procedures may include, but are not limited to, conciliation, facilitation, mediation, and fact finding.
I2 Dispute Resolution The Parties shall attempt in good faith to negotiate a settlement to any dispute between them arising out of or in connection with the Contract within twenty (20) Working Days of either Party notifying the other of the dispute and such efforts shall involve the escalation of the dispute to the finance director of the Contractor and the commercial director of the Authority.
Formal Dispute Resolution 10.6.1 If the Parties are unable to resolve the dispute through the informal procedure described in Section 10.5, then either Party may invoke the formal Dispute Resolution procedures described in this Section 10.6. Unless agreed among all Parties, formal Dispute Resolution procedures, including arbitration or other procedures as appropriate, may be invoked not earlier than sixty (60) calendar days after receipt of the letter initiating Dispute Resolution under Section 10.3.
