Liquor Liability Inception and expiration dates will be the same as the underlying policies. Drop down coverage will be provided for reduction or exhaustion of underlying aggregate limits and will provide a duty to defend for any insured.] [Note: Limit amount should be adequate to cover University’s exposure. Appropriate limit will depend on the subject matter of this Agreement.]
Contractor’s Liability If the Contractor fails to comply with any applicable laws, rules, or regulations, and that failure results in a site or worker contamination, the Contractor will be held solely responsible for all costs involved in any required corrective actions, and shall defend, indemnify, and hold harmless the District, pursuant to the indemnification provisions of the Contract, for all damages and other claims arising therefrom. If lead disturbance is anticipated in the Work, only persons with appropriate accreditation, registrations, licenses, and training shall conduct this Work. It shall be the responsibility of the Contractor to properly dispose of any and all waste products, including, but not limited to, paint chips, any collected residue, or any other visual material that may occur from the prepping of any painted surface. It will be the responsibility of the Contractor to provide the proper disposal of any hazardous waste by a certified hazardous waste hauler. This company shall be registered with the Department of Transportation (DOT) and shall be able to issue a current manifest number upon transporting any hazardous material from any school site within the District. The Contractor shall provide the District with any sample results prior to beginning Work, during the Work, and after the completion of the Work. The District may request to examine, prior to the commencement of the Work, the lead training records of each employee of the Contractor. I acknowledge and certify under penalty of perjury, that:
Customer Liability Customer is solely liable in respect of any loss or cost (including losses or costs suffered by third parties) due to goods not being stored or handled in accordance with this clause 8.
Our Liability (a) The quality and reliability of your electricity supply and the quality, pressure and continuity of your gas supply is subject to a variety of factors that are beyond our control as your retailer, including accidents, emergencies, weather conditions, vandalism, system demand, the technical limitations of the distribution system and the acts of other persons (such as your distributor), including at the direction of a relevant authority.
Contractor’s Pollution Liability insurance covering losses caused by pollution conditions that arise from the operations of the Contractor. Contractors Pollution Liability insurance shall be written in an amount of at least $1,000,000 per loss, with an annual aggregate of at least $1,000,000. Contractors Pollution Liability shall cover bodily injury, property damage, cleanup costs and defense including costs and expenses incurred in the investigation, defense, or settlement of claims. If the Contractors Pollution Liability insurance is written on a claims-made basis, the Contractor warrants that any retroactive date applicable to coverage under the policy precedes the effective date of this contract; and that continuous coverage will be maintained or an extended discovery period will be exercised for a period of three (3) years beginning from the time that work under the contract is completed. The City shall be named by endorsement as an additional insured on the Contractors Pollution Liability insurance policy. If the scope of services as defined in this contract includes the disposal of any hazardous materials from the job site, the Contractor must furnish to the City evidence of Pollution Liability insurance maintained by the disposal site operator for losses arising from the insured facility accepting waste under this contract. Coverage certified to the Public Entity under this paragraph must be maintained in minimum amounts of $1,000,000 per loss, with an annual aggregate of at least $1,000,000. Pollution Liability coverage at least as broad as that provided under ISO Pollution Liability- Broadened Coverage for Covered Autos Endorsement CA 99 48 shall be provided, and the Motor Carrier Act Endorsement (MCS 90) shall be attached.
Contractor Claims In the event of any demand by Contractor for (A) a time extension, including, without limitation, for relief from damages or penalties for delay assessed by the District under the Contract, (B) payment by the District of money or damages arising from work done by, or on behalf of, the Contractor pursuant to the Contract and payment of which is not otherwise expressly provided for or to which Contractor is not otherwise entitled to, or (C) an amount of payment disputed by the District, the parties shall attempt to resolve the dispute by those procedures set forth in Public Contract Code section 9204 and/or Article 1.5 (commencing with section 20104) of Chapter 1, Part, 3, Division 2, of the Public Contract Code, if applicable, the provisions of which are each attached hereto and incorporated herein by this reference. If a claim, or any portion thereof, remains in dispute upon satisfaction of all applicable dispute resolution requirements, the Contractor shall comply with all claims presentation requirements as provided in Chapter 1 (commencing with section 900) and Chapter 2 (commencing with section 910) of Part 3 of Division 3.6 of Title 1 of Government Code as a condition precedent to the Contractor’s right to bring a civil action against the District. For purposes of those provisions, the running of the time within which a claim must be presented to the District shall be tolled from the time the Contractor submits its written claim until the time the claim is denied, including any time utilized by any applicable meet and confer process. Pending resolution of the dispute, Contractor and its subcontractors shall continue to perform the Work under the Contract and shall not cause a delay of the Work during any dispute, claim, negotiation, mediation, or arbitration proceeding, except by written agreement of the District.
Liability for Use of Equipment City shall not be liable for any damage to persons or property as a result of the use, misuse or failure of any equipment used by Contractor, or any of its subcontractors, or by any of their employees, even though such equipment is furnished, rented or loaned by City.
Personal Property Damage Upon submission of reasonable proof the Employer shall repair or indemnify with respect to damage to the chattels of an employee while on duty caused by the actions of a patient, resident or client provided such personal property is an article of use or wear of a type suitable for use while on duty.
Engineer's Liability Acceptance of the final plans by City shall not constitute nor be deemed a release of the responsibility and liability of Engineer, its employees, associates, agents or consultants for the accuracy and competency of their designs, working drawings, specifications or other documents and work; nor shall such acceptance be deemed an assumption of responsibility by City for any defect in the designs, working drawings, specifications, or other documents and work; nor shall such acceptance be deemed an assumption of responsibility or liability by City for any defect in the designs, working drawings, specifications, or other documents prepared by said Engineer, its employees, subcontractor, agents and consultants.
Joint Account Owner Liability If an item deposited in a joint account is returned unpaid, a joint account is overdrawn, or if we do not receive final payment on a transaction, the owners, jointly and severally, are liable to us for the amount of the returned item, overdraft, or unpaid amount and any charges, regardless of who initiated or benefited from the transaction. If any account owner is indebted to us, we may enforce our rights against any account of the indebted owner, including all funds in the joint account, regardless of who contributed the funds.
