Contractor Obligation to Mitigate Delay Sample Clauses

Contractor Obligation to Mitigate Delay. Contractor shall not be entitled to any adjustment to the Project Schedule or adjustment to the Contract Price for any portion of delay to the extent Contractor could have taken, but failed to take, reasonable actions to mitigate such delay.
Sample 1Sample 2Sample 3See All (24)
AutoNDA by SimpleDocs
Contractor Obligation to Mitigate Delay. With respect to Sections 6.7 and 6.8, in no event shall Contractor be entitled to any adjustment to the Key Dates or adjustment to the Contract Price for (i) that portion of delay to the extent Contractor could have taken, but failed to take, reasonable actions to mitigate such delay or (ii) that portion of delay that would nevertheless been experienced had such delay event in Section 6.7 or 6.8 not occurred.
Sample 1Sample 2Sample 3See All (8)
Contractor Obligation to Mitigate Delay. In no event shall Contractor be entitled to any adjustment to the Key Milestone Schedule, Guaranteed Substantial Completion Date, Required Final Completion Date and the Contract Price for that portion of delay to the extent Contractor could have taken, but failed to take, commercially reasonable actions to mitigate such delay.
Sample 1Sample 2
Contractor Obligation to Mitigate Delay. Contractor shall not be entitled to any adjustment to the Project Schedule or adjustment to the Contract Price for any portion of delay to the extent Contractor could have taken, but failed to take, reasonable actionsaction to mitigate such delay. Notwithstanding anything to the contrary in this Agreement, (i) Contractor shall mitigate the cost and schedule impact of COVID-19 or other epidemics, pandemics or plagues using the Outbreak Standard of Care, provided however, if Contractor incurs costs in an effort to meet the Outbreak Standard of Care prior to the issuance of a Change Order, Contractor shall not be prevented from recovering such costs under the applicable Change Order due to the restrictions set forth in Section 6.7, and (ii) Owner will not challenge Contractor’s mitigation efforts to the extent Contractor complies with the Outbreak Standard of Care. The Parties agree that Section 6.12 is added to the Phase 1 EPC Agreement (blue text are additions and red text are deletions) as follows:
Sample 1

Related to Contractor Obligation to Mitigate Delay

  • Obligation to Mitigate Each Lender (which term shall include Issuing Bank for purposes of this Section 2.21) agrees that, as promptly as practicable after the officer of such Lender responsible for administering its Loans or Letters of Credit, as the case may be, becomes aware of the occurrence of an event or the existence of a condition that would cause such Lender to become an Affected Lender or that would entitle such Lender to receive payments under Section 2.18, 2.19 or 2.20, it will, to the extent not inconsistent with the internal policies of such Lender and any applicable legal or regulatory restrictions, use reasonable efforts to (a) make, issue, fund or maintain its Credit Extensions, including any Affected Loans, through another office of such Lender, or (b) take such other measures as such Lender may deem reasonable, if as a result thereof the circumstances which would cause such Lender to be an Affected Lender would cease to exist or the additional amounts which would otherwise be required to be paid to such Lender pursuant to Section 2.18, 2.19 or 2.20 would be materially reduced and if, as determined by such Lender in its sole discretion, the making, issuing, funding or maintaining of such Revolving Commitments, Loans or Letters of Credit through such other office or in accordance with such other measures, as the case may be, would not otherwise adversely affect such Revolving Commitments, Loans or Letters of Credit or the interests of such Lender; provided, such Lender will not be obligated to utilize such other office or take such other measures pursuant to this Section 2.21 unless Borrower agrees to pay all reasonable incremental expenses incurred by such Lender as a result of utilizing such other office or take such other measures as described above. A certificate as to the amount of any such expenses payable by Borrower pursuant to this Section 2.21 (setting forth in reasonable detail the basis for requesting such amount) submitted by such Lender to Borrower (with a copy to Administrative Agent) shall be conclusive absent manifest error.

  • No Obligation to Mitigate Damages Employee shall not be required to mitigate damages or the amount of any payment provided for under this Agreement by seeking other employment or otherwise, nor shall the amount of any payment provided for under this Agreement be reduced by any compensation earned by Employee as a result of employment by another employer or by retirement benefits after the Date of Termination, or otherwise, except to the extent provided in Section 3 above.

  • No Obligation to Mitigate Executive shall not be required to seek other employment or otherwise to mitigate Executive's damages upon any termination of employment; provided, however, that, to the extent Executive receives from a subsequent employer health or other insurance benefits that are substantially similar to the benefits referred to in Section 5(b) hereof, any such benefits to be provided by the Company to Executive following the Term shall be correspondingly reduced.

  • No Mitigation Obligation The Company hereby acknowledges that it will be difficult, and may be impossible, for the Executive to find reasonably comparable employment following the Date of Termination. The payment of the severance compensation by the Company to the Executive in accordance with the terms of this Agreement will be liquidated damages, and the Executive will not be required to mitigate the amount of any payment provided for in this Agreement by seeking other employment or otherwise, nor will any profits, income, earnings, or other benefits from any source whatsoever create any mitigation, offset, reduction, or any other obligation on the part of the Executive hereunder or otherwise.

  • Mitigation Obligations If any Lender requests compensation under Section 9.03, or if the Borrower is required to pay any additional amount to any Lender or any Governmental Authority for the account of any Lender pursuant to Section 9.05, then such Lender shall use reasonable efforts to designate a different lending office for funding or booking its Loans hereunder or to assign its rights and obligations hereunder to another of its offices, branches or affiliates, if, in the judgment of such Lender, such designation or assignment (i) would eliminate or reduce amounts payable pursuant to Section 9.03 or 9.05, as the case may be, in the future and (ii) would not subject such Lender to any unreimbursed cost or expense and would not otherwise be disadvantageous to such Lender. The Borrower hereby agrees to pay all reasonable costs and expenses incurred by any Lender in connection with any such designation or assignment.

  • Exception to Obligations Neither Party's obligations under this Section shall apply to the extent the infringement is caused by: (i) modification of the facilities or equipment (including software) by the indemnitee; (ii) use by the indemnitee of the facilities or equipment (including software) in combination with equipment or facilities (including software) not provided or authorized by the indemnitor, provided the facilities or equipment (including software) would not be infringing if used alone; (iii) conformance to specifications of the indemnitee which would necessarily result in infringement; or (iv) continued use by the indemnitee of the affected facilities or equipment (including software) after being placed on notice to discontinue use as set forth herein.

  • Conditions to Obligations of Each Party Under This Agreement The respective obligations of each party to effect the Merger and the other transactions contemplated herein shall be subject to the satisfaction at or prior to the Effective Time of the following conditions, any or all of which may be waived, in whole or in part, to the extent permitted by applicable Law:

  • Parallel Operation Obligations Once the Small Generating Facility has been authorized to commence parallel operation, the Interconnection Customer shall abide by all rules and procedures pertaining to the parallel operation of the Small Generating Facility in the applicable control area, including, but not limited to: (1) the rules and procedures concerning the operation of generation set forth in the NYISO tariffs or ISO Procedures or the Connecting Transmission Owner’s tariff; (2) any requirements consistent with Good Utility Practice or that are necessary to ensure the safe and reliable operation of the Transmission System or Distribution System; and (3) the Operating Requirements set forth in Attachment 5 of this Agreement.

  • Contractor Responsibility for System Agency’s Termination Costs If the System Agency terminates the Contract for cause, the Contractor shall be responsible to the System Agency for all costs incurred by the System Agency and the State of Texas to replace the Contractor. These costs include, but are not limited to, the costs of procuring a substitute vendor and the cost of any claim or litigation attributable to Contractor’s failure to perform any Work in accordance with the terms of the Contract.

  • OBLIGATION TO NEGOTIATE 50.01 The Employer and the Union acknowledge that during negotiations which preceded this Agreement, each had the unlimited right and opportunity to make demands and proposals with respect to any subject or matter not removed by law from the area of collective bargaining/negotiations and that the understandings and agreements arrived at by the parties after the exercise of that right and opportunity are set forth in this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!