Contractor’s Responsibility for Environmental Costs and Damages Sample Clauses

Contractor’s Responsibility for Environmental Costs and Damages. The Contractor's hazardous materials shall be the sole responsibility of the Contractor and the Contractor shall be solely liable for and responsible for, including without limitation, at the Contractor's sole cost and expense: A. Corrective Action of the Contractor’s hazardous materials as directed by any governmental agency, as required by any law, or as determined by a court of law to be necessary to prevent or eliminate any nuisance, trespass, waste or diminution in the value of the Premises or as necessary to avoid any impairment of the Authority's ability to use the Premises for Airport purposes upon expiration or termination of this Contract; X. Xxxxxxx for injury or death to persons, or injury to property, the Premises and surrounding lands and waters arising out of the Contractor’s hazardous materials; C. Claims resulting therefrom; X. Xxxxx, costs, fees, assessments, taxes, penalties, demands, orders, directives or any other requirements imposed in any manner by any governmental agency asserting jurisdiction, or under any law with respect to the Contractor’s hazardous materials; E. Costs and expenditures for Corrective Action resulting from the Contractor’s hazardous materials; X. Xxxxxxx, costs and expenditures for injury to natural resources resulting from the Contractor’s hazardous materials as required by applicable law; G. Failure to comply with laws regarding the generation, use, storage, transportation, treatment, management or disposal of the Contractor’s hazardous materials; and, H. Any other liability related to the Contractor’s hazardous materials. While the Authority is not required to incur any costs, fees (including attorney, consultant and expert witness fees) or expenses for environmental compliance, or Corrective Action relating to the Contractor's hazardous materials, should the Authority incur any such costs, expenses or fees due to the Contractor’s non-performance of its obligations under this Contract, the Contractor shall within thirty (30) days of demand reimburse the Authority for said costs, expenses, or fees.
Sample 1
AutoNDA by SimpleDocs

Related to Contractor’s Responsibility for Environmental Costs and Damages

  • Responsibility for Damages Contractor is responsible for all damage that occurs as a result of Contractor’s fault or negligence or that of its’ employees, agents, or representatives in connection with the performance of this Contract. Contractor shall immediately report any such damage to people and/or property to the Contract Administrator.

  • CONTRACTOR'S RESPONSIBILITY 1.1. The Basic Services to be performed by CONTRACTOR hereunder is the Citywide Landscape Maintenance. 1.2. The CONTRACTOR agrees to obtain and maintain throughout the period of this Agreement all such licenses as are required to do business in the State of Florida, the City of Naples, and in Xxxxxxx County, Florida, including, but not limited to, all licenses required by the respective state boards and other governmental agencies responsible for regulating and licensing the professional services to be provided and performed by the CONTRACTOR pursuant to this Agreement. 1.3. The CONTRACTOR agrees that, when the services to be provided hereunder relate to a professional service which, under Florida Statutes, requires a license, certificate of authorization or other form of legal entitlement to practice such services, it shall employ and/or retain only qualified personnel to provide such services. 1.4. CONTRACTOR agrees to employ and designate, in writing, within five (5) calendar days after receiving its Notice to Proceed, a qualified licensed professional to serve as the CONTRACTOR's project manager (hereinafter referred to as the "Project Manager"). The Project Manager shall be authorized and responsible to act on behalf of the CONTRACTOR with respect to directing, coordinating and administering all aspects of the services to be provided and performed under this Agreement. 1.5. The CONTRACTOR has represented to the OWNER that it has expertise in the type of professional services that will be required for the Project. The CONTRACTOR agrees that all services to be provided by CONTRACTOR pursuant to this Agreement shall be subject to the OWNER's review and approval and shall be in accordance with the generally accepted standards of professional practice in the State of Florida, as well as in accordance with all published laws, statutes, ordinances, codes, rules, regulations and requirements of any governmental agencies which regulate or have jurisdiction over the Project or the services to be provided and performed by CONTRACTOR hereunder. In the event of any conflicts in these requirements, the CONTRACTOR shall notify the OWNER of such conflict and utilize its best professional judgment to advise OWNER regarding resolution of the conflict. 1.6. CONTRACTOR agrees not to divulge, furnish or make available to any third person, firm or organization, without OWNER's prior written consent, or unless incident to the proper performance of the CONTRACTOR's obligations hereunder, or in the course of judicial or legislative proceedings where such information has been properly subpoenaed, any non-public information concerning the services to be rendered by CONTRACTOR hereunder, and CONTRACTOR shall require all of its employees, agents, subconsultants and subcontractors to comply with the provisions of this paragraph.

  • Responsibility for Environmental Contamination 5.20.1 Neither Party shall be liable to the other for any costs whatsoever resulting from the presence or release of any Environmental Hazard that either Party did not introduce to the affected Work Location. Both Parties shall defend and hold harmless the other, its officers, directors and employees from and against any losses, damages, claims, demands, suits, liabilities, fines, penalties and expenses (including reasonable attorneys' fees) that arise out of or result from (i) any Environmental Hazard that the Indemnifying Party, its contractors or agents introduce to the Work Locations or (ii) the presence or release of any Environmental Hazard for which the Indemnifying Party is responsible under Applicable Law. 5.20.2 In the event any suspect materials within Qwest-owned, operated or leased facilities are identified to be asbestos containing, CLEC will ensure that to the extent any activities which it undertakes in the facility disturb such suspect materials, such CLEC activities will be in accordance with applicable local, state and federal environmental and health and safety statutes and regulations. Except for abatement activities undertaken by CLEC or equipment placement activities that result in the generation of asbestos-containing material, CLEC does not have any responsibility for managing, nor is it the owner of, nor does it have any liability for, or in connection with, any asbestos-containing material. Qwest agrees to immediately notify CLEC if Qwest undertakes any asbestos control or asbestos abatement activities that potentially could affect CLEC personnel, equipment or operations, including, but not limited to, contamination of equipment.

  • Contractor Responsibility for System Agency’s Termination Costs If the System Agency terminates the Contract for cause, the Contractor shall be responsible to the System Agency for all costs incurred by the System Agency and the State of Texas to replace the Contractor. These costs include, but are not limited to, the costs of procuring a substitute vendor and the cost of any claim or litigation attributable to Contractor’s failure to perform any Work in accordance with the terms of the Contract.

  • ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9. § 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage. § 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage. § 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages

  • Responsibility for Damage Resident is solely responsible for any damage, defacement or loss arising within the assigned bedroom space. All assigned residents of an apartment are jointly and severally responsible for any damage, defacement or loss to common areas, other parts of the Property, fixtures or appliances, except for the portion of damages over $100,000 where it is finally established that Resident or one or more other residents of the apartment were solely at fault for the entire loss, in which case such person(s) will be solely responsible. Resident is fully responsible for the conduct of Resident’s guests, visitors, licensees and invitees (“Guests”), including without limitation harm to individuals or damage or defacement of any part of the Property or its fixtures or property of third parties (including other residents) by such Guests.

  • Engineers Responsibility The Engineer shall be responsible for the accuracy of its work and shall promptly make necessary revisions or corrections resulting from its errors, omissions, or negligent acts without compensation. The Engineer will not be relieved of the responsibility for subsequent correction of any such errors or omissions or for clarification of any ambiguities until after the construction phase of the project has been completed.

  • Contractor’s Responsibilities Unless stated specifically to the contrary in the tender with full supporting explanations, the contractor will be deemed to have concurred as a practical manufacturer with the design and layout of the works as being sufficient to ensure reliability and safety in operation, freedom from undue stresses and satisfactory performance in all other essentials as a working material.

  • Responsibility for Costs The Servicer is responsible for collection from such Borrower of any recording or similar costs or expenses incidental to the granting of relief with respect to a delinquent Mortgage Loan.

  • Supplier’s Responsibilities 14.1 The Supplier shall supply all the Goods and Related Services included in the Scope of Supply in accordance with GCC Clause 12, and the Delivery and Completion Schedule, as per GCC Clause 13.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!