Common use of Cooperation and Harmony on Site Clause in Contracts

Cooperation and Harmony on Site. (a) This PLA is intended to establish and xxxxxx continued close cooperation between management and labor. The Councils shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Project Labor Coordinator, together with the Contractors, to complete construction of the Covered Projects economically, efficiently, continuously, and without any interruption, delays, or work stoppages. (b) The Contractors, Unions, and Contractor employees collectively and individually, realize the importance of maintaining continuous and uninterrupted performance of Covered Projects, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 or 8. (c) The Project Labor Coordinator shall observe the processing of grievances under this Article and Articles 7 and 8, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the grievance parties to ensure the time limits and deadlines are met.

Cooperation and Harmony on Site. (a) 9.1.1 This PLA Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Councils Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Project Labor Community Workforce Coordinator, together with the Contractors, to complete the construction of the Covered Projects Project economically, efficiently, continuously, continuously and without any interruption, delays, delays or work stoppages. (b) 9.1.2 The Community Workforce Coordinator, the Contractors, Unions, and Contractor employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance of Covered ProjectsProject Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 6 or 87. (c) 9.1.3 The Project Labor Community Workforce Coordinator shall observe oversee the processing of grievances under this Article and Articles 7 and 8Article 6, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the grievance principal parties to ensure any pending grievance to insure the time limits and deadlines are met.

Cooperation and Harmony on Site. (a) This PLA is intended to establish and xxxxxx continued close cooperation between management and labor. The Councils Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Project Labor Coordinator, together with the Contractors, to complete construction of the Covered Projects Project Work economically, efficiently, continuously, and without any interruption, delays, or work stoppages. (b) The Project Labor Coordinator, the Contractors, Unions, and Contractor employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance of Covered ProjectsProject Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 or 8. (c) The Project Labor Coordinator shall observe the processing of grievances under this Article and Articles 7 and 8, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the principal Parties to any pending grievance parties to ensure the time limits and deadlines are met.

Cooperation and Harmony on Site. (a) This PLA is intended to establish and xxxxxx continued close cooperation between management and labor. The Councils Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Project Labor Coordinator, together with the Contractors, to complete the construction of the Covered Projects Project Work economically, efficiently, continuously, continuously and without any interruption, delays, delays or work stoppages. (b) The Project Labor Coordinator, the Contractors, Unions, and Contractor employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance of Covered ProjectsProject Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 8 or 810. (c) The Project Labor Coordinator shall observe the processing of grievances under this Article and Articles 7 8 and 810, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the principal Parties to any pending grievance parties to ensure insure the time limits and deadlines are met.

Cooperation and Harmony on Site. (a) This PLA CBA is intended to establish and xxxxxx continued close cooperation between management and labor. The Councils Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Project Labor Coordinator, together with the Contractors, to complete construction of the Covered Projects economically, efficiently, continuously, and without any interruption, delays, or work stoppages. (b) The SANDAG, the Contractors, Unions, and Contractor employees collectively and individually, realize the importance of maintaining continuous and uninterrupted performance of Covered Projects, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 or 8. (c) The Project Labor Coordinator shall observe the processing of grievances under this Article and Articles 7 and 8, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the grievance parties to ensure the time limits and deadlines are met.

Cooperation and Harmony on Site. (a) This PLA Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Councils Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Project Labor Coordinator, together with the Contractorscontractors, to complete the construction of the Covered Projects Project economically, efficientlyefficiency, continuously, continuously and without any interruption, delays, delays or work stoppages. (b) The ContractorsProject Labor Coordinator, the contractors, Unions, and Contractor employees collectively and individually, realize the importance to all parties of maintaining continuous and uninterrupted performance of Covered ProjectsProject Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 or 8. (c) The Project Labor Coordinator shall observe oversee the processing of grievances under this Article and Articles 7 and 8, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the grievance principal parties to ensure any pending grievance to insure the time limits and deadlines are met.

Cooperation and Harmony on Site. (a) This PLA Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Councils Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Project Labor Coordinator, together with the Contractors, to complete the construction of the Covered Projects Project economically, efficientlyefficiency, continuously, continuously and without any interruption, delays, delays or work stoppages. (b) The Project Labor Coordinator, the Contractors, Unions, and Contractor employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance of Covered ProjectsProject Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 6 or 87. (c) The Project Labor Coordinator shall observe oversee the processing of grievances under this Article and Articles 7 6 and 87, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the grievance principal parties to ensure any pending grievance to insure the time limits and deadlines are met.

Cooperation and Harmony on Site. (a) This PLA Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Councils Trades Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Project Labor CoordinatorPLA Administrator, together with the Contractors, to complete the construction of the Covered Projects Project economically, efficiently, continuously, continuously and without any interruption, delays, delays or work stoppages. (b) The PLA Administrator, the Contractors, Unions, and Contractor employees collectively and individually, realize the importance to all parties of maintaining continuous and uninterrupted performance of Covered ProjectsProject Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article Articles 7 or 8. (c) The Project Labor Coordinator PLA Administrator shall observe oversee the processing of grievances under this Article and Articles 7 and 8, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the grievance principal parties to ensure any pending grievance to insure the time limits and deadlines are met.

Cooperation and Harmony on Site. (a) This PLA is intended to establish and xxxxxx continued close cooperation between management and labor. The Councils Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Project Labor Coordinator, together with the Contractors, to complete construction of the Covered Projects economically, efficiently, continuously, and without any interruption, delays, or work stoppages. (b) The Water Authority, the Contractors, Unions, and Contractor employees collectively and individually, realize the importance of maintaining continuous and uninterrupted performance of Covered Projects, and agree to resolve disputes related to matters covered by this PLA in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 or 8. (c) The Project Labor Coordinator shall observe the processing of grievances under this Article and Articles 7 and 8, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the grievance parties to ensure the time limits and deadlines are met.

Cooperation and Harmony on Site. (a) 9.1.1 This PLA Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Councils Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Project Labor Coordinator, together with the Contractors, to complete the construction of the Covered Projects Project economically, efficientlyefficiency, continuously, continuously and without any interruption, delays, delays or work stoppages. (b) 9.1.2 The Project Labor Coordinator, the Contractors, Unions, and Contractor employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance of Covered ProjectsProject Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 or 8. (c) 9.1.3 The Project Labor Coordinator shall observe oversee the processing of grievances under this Article and Articles 7 6 and 87, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the grievance principal parties to ensure any pending grievance to insure the time limits and deadlines are met.

Cooperation and Harmony on Site. (a) This PLA is intended to establish and xxxxxx continued close cooperation between management and labor. The Councils Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Project Labor Coordinator, together with the Contractors, to complete the construction of the Covered Projects Project Work economically, efficiently, continuously, continuously and without any interruption, delays, delays or work stoppages. (b) The Project Labor Coordinator, the Contractors, Unions, and Contractor employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance of Covered ProjectsProject Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 8 or 810. (c) The Project Labor Coordinator shall observe the processing of grievances under this Article and Articles 7 8 and 810, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-agreed- upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the principal Parties to any pending grievance parties to ensure insure the time limits and deadlines are met.

Cooperation and Harmony on Site. (a) This PLA Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Councils Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Project Labor Coordinator, together with the Contractors, to complete the construction of the Covered Projects Project economically, efficientlyefficiency, continuously, continuously and without any interruption, delays, delays or work stoppages. (b) The Project Labor Coordinator, the Contractors, Unions, and Contractor employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance of Covered ProjectsProject Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article Articles 7 or 8. (c) The Project Labor Coordinator shall observe oversee the processing of grievances under this Article and Articles 7 and 8, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the grievance principal parties to ensure any pending grievance to insure the time limits and deadlines are met.

Cooperation and Harmony on Site. (a) This PLA Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Councils Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Project Labor Coordinator, together with the Contractors, to complete the construction of the Covered Projects Project economically, efficientlyefficiency, continuously, continuously and without any interruption, delays, delays or work stoppages. (b) The Project Labor Coordinator, the Contractors, Unions, and Contractor employees collectively and individually, realize the importance to all parties of maintaining continuous and uninterrupted performance of Covered ProjectsProject Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 or 8. (c) The Project Labor Coordinator shall observe oversee the processing of grievances under this Article and Articles 7 and 8, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the grievance principal parties to ensure any pending grievance to insure the time limits and deadlines are met.

Cooperation and Harmony on Site. (a) This PLA Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Councils Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Project Labor Coordinator, together with the Contractors, to complete the construction of the Covered Projects Project economically, efficientlyefficiency, continuously, continuously and without any interruption, delays, delays or work stoppages. (b) The Project Labor Coordinator, the Contractors, Unions, and Contractor employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance of Covered ProjectsProject Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 or 8. (c) The Project Labor Coordinator shall observe oversee the processing of grievances under this Article and Articles 7 and 8, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the grievance principal parties to ensure any pending grievance to insure the time limits and deadlines are met.

Cooperation and Harmony on Site. (a) This PLA Agreement is intended to establish and xxxxxx continued close cooperation between management and labor. The Councils Council shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Project Labor CoordinatorPLA Administrator, together with the Contractors, to complete the construction of the Covered Projects Project economically, efficiently, continuously, continuously and without any interruption, delays, delays or work stoppages. (b) The PLA Administrator, the Contractors, Unions, and Contractor employees collectively and individually, realize the importance to all parties of maintaining continuous and uninterrupted performance of Covered ProjectsProject Work, and agree to resolve disputes in accordance with the grievance provisions set forth in this Article Article, or, as appropriate, those of Article Articles 7 or 8. (c) The Project Labor Coordinator PLA Administrator shall observe oversee the processing of grievances under this Article and Articles 7 and 8, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the grievance principal parties to ensure any pending grievance to insure the time limits and deadlines are met.

Cooperation and Harmony on Site. (a) This PLA is intended to establish and xxxxxx continued close cooperation between management and labor. The Councils shall assign a representative to this Project for the purpose of assisting the local Unions, and working with the Project Labor Coordinator, together with the Contractors, to complete construction of the Covered Projects economically, efficiently, continuously, and without any interruption, delays, or work stoppages. (b) The Project Labor Coordinator, the Contractors, Unions, and Contractor employees collectively and individually, realize the importance to all Parties of maintaining continuous and uninterrupted performance of Covered ProjectsProject Work, and agree to resolve all disputes in accordance with the grievance provisions set forth in this Article or, as appropriate, those of Article 7 or 8. (c) The Project Labor Coordinator shall observe the processing of grievances under this Article and Articles 7 and 8, including the scheduling and arrangements of facilities for meetings, selection of the arbitrator from the agreed-upon panel to hear the case, and any other administrative matters necessary to facilitate the timely resolution of any dispute; provided, however, it is the responsibility of the principal Parties to any pending grievance parties to ensure the time limits and deadlines are met.