Jurisdictional Disputes 25.01 A jurisdictional xxxx-up meeting will be held when requested in writing at any time on a project basis by either the Union or the contractor. The contractor shall be required to provide a full and detailed description of the scope of work at such xxxx-up meeting. In the event any such work assignments are disputed, at such xxxx-up meetings, the Union shall be permitted ten (10) days in which to present documented argument and evidence as to its claim to the disputed work jurisdiction prior to any final assignments being made by the contractor. Jurisdictional disputes arising following the xxxx-up meeting will be made in accordance with the Procedures, Rules and Regulations of the National Joint Board Building Trades Department, AFL/CIO or its successor.
25.02 In the event such jurisdictional dispute cannot be settled on a Local basis by the Unions involved, such dispute shall be submitted to the International Unions involved for settlement without permitting it to interfere in any way with the progress of the work at any time. In the event the dispute is not settled by the International Unions involved, it shall then be submitted to the National Joint Board for resolution. It is understood and agreed, however, that if the dispute causes any delay in the progress of the work or gives rise to an apprehended delay, any of the Parties hereto may apply to the Labour Relations Board (Nova Scotia) Construction Panel for an Interim Order under Section 50 of the Trade Union Act, Chapter 475, R.S.N.S. 1989, as amended.
25.03 All work assignments given to Carpenters Local 83 by way of xxxx-up meetings to be copied and faxed to the Nova Scotia Construction Labour Relations Association Limited.
Governing Law; Disputes 15.1 The laws of the State of New York, U.S.A. govern this Agreement, and the relationships created by it, except for its laws regarding conflicts of law and arbitrability; the Federal Arbitration Act governs all issues of arbitrability. Neither party may bring a claim more than two years after the underlying cause of action first accrues.
15.2 Each party agrees to give the other prompt written notice of any claim, controversy, or dispute arising under or related to this Agreement, and both parties agree to engage in good faith discussions to resolve the matter. If that fails to resolve the matter promptly, upon the election of either party, the parties will participate in a non-binding mediation before a mutually agreed mediator. Any controversy, claim or dispute which is not resolved through the procedures set forth above within 60 days following the initial notice (or such longer period as the parties may agree) will be resolved by arbitration before a sole arbitrator who is an attorney, under the then-current Commercial Arbitration Rules of the American Arbitration Association. The duty and right to arbitrate will extend to any employee, officer, director, shareholder, agent, or affiliate, of a party to the extent that right or duty arises through a party or is related to this Agreement. The decision and award of the arbitrator will be final and binding, and the award rendered may be entered in any court having jurisdiction. The arbitrator is directed to hear and decide potentially dispositive motions in advance of a hearing on the merits by applying the applicable law to undisputed facts and documents. The arbitration will be held in Atlanta, Georgia, U.S.A. This Section 15.2, and the obligation to mediate and arbitrate, will not apply to claims for infringement, misappropriation or misuse of a party’s intellectual property or Confidential Information, or collection of sums owed to NCR Voyix under this Agreement. A party may at any time seek from a court of competent jurisdiction an injunction or other equitable relief in aid of arbitration. The arbitrator will not have authority to award punitive damages, non- compensatory damages, or any damages other than direct damages, nor have authority to award direct damages inconsistent with the limitations and exclusions set forth in this Agreement. The United Nations Convention for the International Sale of Goods does not apply to this Agreement.
Arbitration and Jurisdiction (a) Any dispute, controversy or claim arising out of or relating to (1) this Agreement, (2) the breach, termination or invalidity hereof or (3) any non-contractual obligations arising out of or in connection with this Agreement shall be settled by arbitration in accordance with the UNCITRAL Arbitration Rules as at present in force. There shall be one arbitrator and the appointing authority shall be LCIA (London Court of International Arbitration). The seat and place of arbitration shall be London, England and the English language shall be used throughout the arbitral proceedings. The parties hereby waive any rights under the Arbitration Xxx 0000 or otherwise to appeal any arbitration award to, or to seek determination of a preliminary point of law by, the courts of England. The arbitral tribunal shall not be authorised to grant, and the Borrower agrees that it shall not seek from any judicial authority, any interim measures or pre-award relief against EBRD, any provisions of the UNCITRAL Arbitration Rules notwithstanding. The arbitral tribunal shall have authority to consider and include in any proceeding, decision or award any further dispute properly brought before it by EBRD (but no other party) insofar as such dispute arises out of any Financing Agreement, but, subject to the foregoing, no other parties or other disputes shall be included in, or consolidated with, the arbitral proceedings. In any arbitral proceeding, the certificate of EBRD as to any amount due to EBRD under any Financing Agreement shall be prima facie evidence of such amount.
(b) Notwithstanding Section 8.09(a), this Agreement and the other Financing Agreements, and any rights of EBRD arising out of or relating to this Agreement or any other Financing Agreement, may, at the option of EBRD, be enforced by EBRD in the courts of England and Wales or in any other courts having jurisdiction. For the benefit of EBRD, the Borrower hereby irrevocably submits to the non-exclusive jurisdiction of the courts of England with respect to any dispute, controversy or claim arising out of or relating to this Agreement or any other Financing Agreement, or the breach, termination or invalidity hereof or thereof. The Borrower hereby irrevocably designates, appoints and empowers Trident Company Services (UK) Limited at its registered office (being, on the date hereof, at 0 Xxxxxxx Xxxxxx, Xxxxxx X0X 0XX, Xxxxxxx) to act as its authorised agent to receive service of process and any other legal summons in England for purposes of any legal action or proceeding brought by EBRD in respect of any Financing Agreement. Failure by a process agent to notify the Borrower of the process will not invalidate the proceedings concerned. The Borrower hereby irrevocably consents to the service of process or any other legal summons out of such courts by mailing copies thereof by registered airmail postage prepaid to its address specified herein. The Borrower covenants and agrees that, so long as it has any obligations under this Agreement, it shall maintain a duly appointed agent to receive service of process and any other legal summons in England for purposes of any legal action or proceeding brought by EBRD in respect of any Financing Agreement and shall keep EBRD advised of the identity and location of such agent. Nothing herein shall affect the right of EBRD to commence legal actions or proceedings against the Borrower in any manner authorised by the laws of any relevant jurisdiction. The commencement by EBRD of legal actions or proceedings in one or more jurisdictions shall not preclude EBRD from commencing legal actions or proceedings in any other jurisdiction, whether concurrently or not. The Borrower irrevocably waives any objection it may now or hereafter have on any grounds whatsoever to the laying of venue of any legal action or proceeding and any claim it may now or hereafter have that any such legal action or proceeding has been brought in an inconvenient forum.
Mediation and jurisdiction The data importer agrees that if the data subject invokes against it third-party beneficiary rights and/or claims compensation for damages under the Clauses, the data importer will accept the decision of the data subject:
Dispute Resolution and Jurisdiction Any controversy or claim arising out of or relating to this Agreement, or the breach thereof shall be settled by arbitration in accordance with the rules of the American Arbitration Association and judgment upon the award rendered by the arbitrator(s) may be entered in any court having jurisdiction thereof, except that arbitration shall not apply to (1) controversies and claims of less than $5,000, nor to (2) claims seeking to collect liquidated amounts, such as the Tuition promised by the student. Any legal dispute (not resolved in arbitration) shall be governed by the laws of the state of California, and that Santa Xxxxxxx courts are the exclusive venue.
Governing Law, Jurisdiction and Dispute Resolution The rights and obligations of the Parties under the Agreement shall be governed by and construed in accordance with the laws of India. The TDSAT, to the exclusion of all other courts, shall have exclusive jurisdiction in respect of any dispute between the Parties arising out of or in connection with or as a result of this Agreement.
Dispute Resolution, Governing Law and Jurisdiction The parties will make good faith efforts to first resolve internally within 30 days any dispute, including over an invoice, relating to the Agreement by escalating it to higher levels of management. If Client withholds an amount more than sixty days Accenture will be permitted to suspend performance until such time as the matter in dispute is resolved. The governing law and jurisdiction are set forth in the Order Form.
Governing Law; Resolution of Disputes This Agreement and the rights and obligations hereunder shall be governed by and construed in accordance with the laws of the State of Wisconsin. Any dispute arising out of this Agreement shall, at the Executive’s election, be determined by arbitration under the rules of the American Arbitration Association then in effect (in which case both parties shall be bound by the arbitration award) or by litigation. Whether the dispute is to be settled by arbitration or litigation, the venue for the arbitration or litigation shall be Milwaukee, Wisconsin or, at the Executive’s election, if the Executive is not then residing or working in the Milwaukee, Wisconsin metropolitan area, in the judicial district encompassing the city in which the Executive resides; provided, that, if the Executive is not then residing in the United States, the election of the Executive with respect to such venue shall be either Milwaukee, Wisconsin or in the judicial district encompassing that city in the United States among the thirty cities having the largest population (as determined by the most recent United States Census data available at the Termination Date) which is closest to the Executive’s residence. The parties consent to personal jurisdiction in each trial court in the selected venue having subject matter jurisdiction notwithstanding their residence or situs, and each party irrevocably consents to service of process in the manner provided hereunder for the giving of notices.
Resolution of Disputes Choice of Law (a) This Transition Agreement shall be construed and enforced in accordance with the laws of the State of California without regard to the principles of conflicts of law.
(b) All suits, actions or proceedings arising out of or relating to this Transition Agreement shall be brought in a state or federal court located in San Francisco County, California, which courts shall be the exclusive forum for all such suits, actions or proceedings. Executive and the Company hereby waive any objection which either of Executive may now or hereafter have to the laying of venue in any such court, including any claim based on the doctrine of forum non conveniens or any similar doctrine, for any such suit, action or proceeding. Executive and the Company each hereby irrevocably consent and submit to the jurisdiction of the federal and state courts located in San Francisco County, California for the purposes of any suit, action or proceeding arising out of relating to this Transition Agreement. If any action is necessary to enforce the terms of this Transition Agreement, the substantially prevailing party will be entitled to reasonable attorneys’ fees, costs and expenses in addition to any other relief to which such prevailing party may be entitled
(c) EXECUTIVE AND THE COMPANY EACH HEREBY WAIVE ANY RIGHT TO A TRIAL BY JURY IN ANY SUIT, ACTION OR PROCEEDING ARISING UNDER THIS TRANSITION AGREEMENT or related in any way to Executive’s employment and/or to the termination of Executive’s employment AND AGREE THAT ANY SUCH SUIT, ACTION OR PROCEEDING SHALL BE TRIED BEFORE A COURT AND NOT BEFORE A JURY.
Governing Law; Venue and Jurisdiction THIS DPA WILL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF THE LEA, WITHOUT REGARD TO CONFLICTS OF LAW PRINCIPLES. EACH PARTY CONSENTS AND SUBMITS TO THE SOLE AND EXCLUSIVE JURISDICTION TO THE STATE AND FEDERAL COURTS FOR THE COUNTY OF THE LEA FOR ANY DISPUTE ARISING OUT OF OR RELATING TO THIS DPA OR THE TRANSACTIONS CONTEMPLATED HEREBY.
